CONDITIONS FOR TERMINATION OF LIQUIDATED DAMAGES Sample Clauses

CONDITIONS FOR TERMINATION OF LIQUIDATED DAMAGES. Except as waived by the Contracting Officer, no liquidated damages imposed on the contractor shall be terminated or suspended until the contractor issues a written notice of correction to the Contracting Officer certifying the correction of condition(s) for which liquidated damages were imposed and until all contractor corrections have been subjected to system testing or other verification at the discretion of the Contracting Officer. Liquidated damages shall cease on the day of the contractor's certification only if subsequent testing of the correction establishes that, indeed, the correction has been made in the manner and at the time certified to by the contractor. A. The contractor shall provide the necessary system time to system test any correction the Contracting Officer deems necessary. B. The Contracting Officer shall determine whether the necessary level of documentation has been submitted to verify corrections. The Contracting Officer shall be the sole judge of the sufficiency and accuracy of any documentation. C. System corrections shall be sustained for a reasonable period of at least ninety (90) days from State acceptance; otherwise, liquidated damages may be reimposed without a succeeding grace period within which to correct. D. Contractor use of resources to correct deficiencies shall not be allowed to cause other system problems.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
CONDITIONS FOR TERMINATION OF LIQUIDATED DAMAGES. VII-28 7.16.7 EPSDT PERFORMANCE STANDARDS .................................. VII-28 7.16.8 DEPARTMENT OF HEALTH AND HUMAN SERVICES CIVIL MONEY PENALTIES. VII-31 7.16.8.1 FEDERAL STATUTES.............................................. VII-31 7.16.8.2 FEDERAL PENALTIES............................................. VII-31 7.17 STATE SANCTIONS ....................................................... VII-32 7.18 APPEAL PROCESS......................................................... VII-33 7.19 ASSIGNMENTS............................................................ VII-33
Sample 1
CONDITIONS FOR TERMINATION OF LIQUIDATED DAMAGES. X.3.1 As determined appropriate by the Agency, the following are the conditions under which the Contractor may obtain relief from the continued assessment of liquidated damages that have been imposed. X.3.2 Except as waived in writing by the Agency, no liquidated damages imposed shall be terminated or suspended until the Contractor issues a written notice verifying the corrections of the condition(s) for which liquidated damages were imposed and all the Contractor corrections have been subject to verification at the discretion of the Agency. X.3.3 If appropriate, the Contractor shall conduct systems testing of any correction as the Agency deems necessary. Such testing shall be developed jointly by the Agency and the Contractor and approved by the Agency including the test script, test environment and the test result. X.3.4 The documentation necessary for verification and approval shall be determined by the Agency. The Agency shall be the sole judge of the accuracy of any documentation provided. X.3.5 A Contractor notice of correction will not be accepted until the correction is verified by the Agency.
Sample 1
CONDITIONS FOR TERMINATION OF LIQUIDATED DAMAGES. Except as waived by the Contracting Officer, no liquidated damages imposed on the Contractor will be terminated or suspended until the Contractor issues a written notice of correction to the Contracting Officer certifying, under penalty of perjury, the correction of condition(s) for which liquidated damages were imposed. Liquidated damages will cease on the day of the Contractor's certification only if subsequent verification of the correction by DHS establishes that the correction has been made in the manner and at the time certified to by the Contractor. The Contracting Officer will determine whether the necessary level of documentation has been submitted to verify corrections. The Contracting Officer will be the sole judge of the sufficiency and accuracy of any documentation. Corrections must be sustained for a reasonable period of at least ninety (90) days from DHS acceptance; otherwise, liquidated damages may be reimposed without a succeeding grace period within which to correct. The Contractor's use of resources to correct deficiencies will not be allowed to cause other contract compliance problems.
Sample 1
CONDITIONS FOR TERMINATION OF LIQUIDATED DAMAGES. As determined appropriate by the Lottery, the following are the conditions under which Contractor may obtain relief from the continued assessment of liquidated damages that have been imposed. Except as waived in writing by the Lottery, no liquidated damages imposed shall be terminated or suspended until Contractor issues a written notice verifying the correction of the condition(s) for which liquidated damages were imposed, and all corrections have been subjected to System testing or other verification at the discretion of the Lottery.
Sample 1
CONDITIONS FOR TERMINATION OF LIQUIDATED DAMAGES. If any portion of the liquidated damages provisions is determined to be unenforceable in one or more applications, that portion remains in effect in all applications not determined to invalid and is severable from the invalid applications. If any portion of the liquidated damages provisions is determined to be unenforceable, the other provision or provisions shall remain in full force and effect.
Sample 1
CONDITIONS FOR TERMINATION OF LIQUIDATED DAMAGES. Except as waived by the Contracting Officer, no liquidated damages imposed on the contractor shall be terminated or suspended until the contractor issues a written notice of correction to the Contracting Officer certifying the correction of condition(s) for which liquidated damages were imposed and until all contractor corrections have been subjected to system testing or other verification at the discretion of the Contracting Officer. Liquidated damages shall cease on the day of the contractor’s certification only if subsequent testing of the correction establishes that, indeed, the correction has been made in the manner and at the time certified to by the contractor. A. the contractor shall provide the necessary system time to system test any correction the Contracting Officer deems necessary. Iv Achievement of less than 30 percent lead screening rate: refund of $5 per enrollee for all enrollees under age 3 not screened.
Sample 1
AutoNDA by SimpleDocs

Related to CONDITIONS FOR TERMINATION OF LIQUIDATED DAMAGES

  • Reasons for Termination Executive’s employment hereunder may or will be terminated during the Employment Period under the following circumstances:

  • CONDITIONS OF SETTLEMENT, EFFECT OF DISAPPROVAL, CANCELLATION OR TERMINATION 9.1. The Effective Date of this Settlement Agreement shall not occur unless and until each and every one of the following events occurs: (a) This Agreement has been signed by the Parties and Class Counsel, and the individual settlement agreements with Xxxxxxxxx Xxxxx, the heirs of Xxxxx Xxxxx, Xxxxxx Xxxxxxxxx, and Xxxxxx Xxxxxxxx-Xxx have been fully executed; (b) The Court has entered an order granting Preliminary Approval of the Agreement; (c) The Court has entered a Final Approval Order finally approving the Agreement, or a judgment substantially consistent with this Settlement Agreement that has become final and unappealable, following Notice and a Final Approval Hearing, as provided in the Federal Rules of Civil Procedure; and (d) In the event that the Court enters an approval order and final judgment in a form other than that provided above (“Alternative Approval Order”) to which the Parties have consented, that Alternative Approval Order has become final and unappealable. 9.2. If some or all of the conditions specified in Paragraph 9.1 are not met, or in the event that this Settlement Agreement is not approved by the Court, or the settlement set forth in this Agreement is terminated or fails to become effective in accordance with its terms, then this Settlement Agreement shall be canceled and terminated subject to Paragraph 9.3, unless Class Counsel and Defendant’s Counsel mutually agree in writing to proceed with this Agreement. If any Party is in material breach of the terms hereof, any other Party, provided that it is in substantial compliance with the terms of this Agreement, may terminate this Agreement on notice to all other Parties. Notwithstanding anything herein, the Parties agree that the Court’s decision as to the amount of the Illinois Fee Award and Ohio Fee Award to Class Counsel set forth above or the incentive award to the Class Representatives, regardless of the amounts awarded, shall not prevent the Agreement from becoming effective, nor shall it be grounds for termination of the Agreement. 9.3. If this Agreement is terminated or fails to become effective for the reasons set forth in Paragraphs 6.1, 6.2, 9.1, or 9.2 above, the Parties shall be restored to their respective positions in the Action as of the date of the signing of this Agreement. In such event, any Final Approval Order or other order entered by the Court in accordance with the terms of this Agreement shall be treated as vacated, nunc pro tunc, and the Parties shall be returned to the status quo ante with respect to the Actions as if this Agreement had never been entered into, including Defendant’s right to seek to compel arbitration as to the Plaintiffs named in the Second Amended Complaint. 9.4. In the event the Settlement is terminated or fails to become effective for any reason, the Illinois Settlement Fund and Ohio Settlement Fund, together with any earnings thereon at the same rate as earned, less any taxes paid or due, less Settlement Administrative Expenses actually incurred and paid or payable from the Settlement Fund, shall be returned to Defendant or its Insurer within thirty (30) calendar days after written notification of such event in accordance with instructions provided by Defendant’s Counsel to the Settlement Administrator.

  • Grounds for Termination This Agreement may be terminated at any time prior to the Closing Date: (a) by mutual written agreement of Albertson’s and Buyer; (b) by either Albertson’s or Buyer if the Closing shall not have been consummated on or before September 22, 2006 (the “Termination Date”); provided that the right to terminate this Agreement pursuant to this Section 12.01(b) shall not be available to the party seeking to terminate if any action of such party or the failure of such party to perform any of its obligations under this Agreement required to be performed at or prior to the Closing has been the cause of, or resulted in, the failure of the Closing to occur on or before the Termination Date and such action or failure to perform constitutes a breach of this Agreement; provided, further, that the right to terminate this Agreement pursuant to this Section 12.01(b) shall not be available to Albertson’s if neither Albertson’s nor SUPERVALU shall have exercised its termination right under Section 8.1(c) of the Merger Agreement; (c) by either Albertson’s or Buyer if there shall be any Law, regulation or nonappealable final order, decree or judgment of any court or governmental body having competent jurisdiction that would make the consummation of the transactions contemplated hereby illegal or otherwise prohibited; (d) by Albertson’s if there shall have been a material breach of any representation, warranty, covenant or agreement on the part of Buyer contained in this Agreement such that the condition set forth in Section 10.03(a) would not be satisfied and which shall not have been cured prior to the earlier of (i) 20 Business Days following notice of such breach and (ii) the Termination Date; (e) by Buyer if there shall have been a material breach of any representation, warranty, covenant or agreement on the part of any Seller contained in this Agreement such that the condition set forth in Section 10.02(a) would not be satisfied and which shall not have been cured prior to the earlier of (i) 20 Business Days following notice of such breach and (ii) the Termination Date; or (f) by Albertson’s or Buyer if the Merger Agreement is terminated. The party desiring to terminate this Agreement pursuant to clauses 12.01(b), (c), (d), (e) or (f) shall give notice of such termination to the other party.

  • Exercise of Option and Provisions for Termination (a) Except as otherwise provided herein and subject to the right of cumulation provided herein, this option may be exercised, prior to the tenth anniversary date, as to not more than the following number of shares covered by this option during the respective periods set forth below: No shares from and after the date of grant and prior to the first anniversary date; shares from and after the first anniversary date and prior to the second anniversary date; shares from and after the second anniversary date and prior to the third anniversary date; shares from and after the third anniversary date and prior to the fourth anniversary date; shares from and after the fourth anniversary date and prior to the fifth anniversary date; and shares from and after the fifth anniversary date. The right of exercise provided herein shall be cumulative so that if the option is not exercised to the maximum extent permissible during any such period it shall be exercisable, in whole or in part, with respect to all shares not so purchased at any time during any subsequent period prior until the expiration or termination of this option. This option may not be exercised at any time after the tenth anniversary date. (b) Subject to the conditions hereof, this option shall be exercisable by the Employee giving written notice of exercise to the Company, specifying the number of shares to be purchased and the purchase price to be paid therefor and accompanied by payment in accordance with Section 3 hereof. Such exercise shall be effective upon receipt by the Treasurer of the Company of the written notice together with the required payment. The Employee shall be entitled to purchase less than the number of shares covered hereby, provided that no partial exercise of this option shall be for less than 10 whole shares. (c) If the Employee ceases to be employed by the Company or one of its subsidiaries for any reason, including retirement but other than death, this option shall immediately terminate; provided, however, that any portion of this option which was otherwise exercisable on the date of termination of the Employee’s employment may be exercised within the three-month period following the date on which the Employee ceased to be so employed, but in no event after the tenth anniversary date. Any such exercise may be made only to the extent of the number of shares subject to this option which are purchasable upon the date of such termination of employment. If the Employee dies during such three-month period, this option shall be exercisable by the Employee’s personal representatives, heirs or legatees to the same extent and during the same period that the Employee could have exercised this option on the date of his or her death. (d) If the Employee dies while an employee of the Company or any subsidiary of the Company, this option shall be exercisable, by the Employee’s personal representatives, heirs or legatees, to the same extent that the Employee could have exercised this option on the date of his or her death. This option or any unexercised portion hereof shall terminate unless so exercised prior to the earlier of the expiration of six months from the date of such death or the tenth anniversary date. (e) Notwithstanding any other provision hereof, this option may not be exercised to the extent such an exercise would violate Section 422(d)(1) of the Code, which provides that the aggregate fair market value (determined at the time the option is granted) of the Common Stock with respect to which incentive stock options are exercisable for the first time by the Employee during any calendar year (under all of the plans of the Company, its parent, if any, or its subsidiaries, if any) shall not exceed $100,000.

  • Notice Requirement for Termination No termination of this Agreement will be effective unless and until the Party terminating this Agreement gives prior written notice to the other Party to this Agreement of its intent to terminate, and such notice shall set forth the basis for such termination. Furthermore: (a) in the event that any termination is based upon the provisions of Sections 6.1(a) or 6.1(e) hereof, such prior written notice shall be given at least six (6) months in advance of the effective date of termination unless a shorter time is agreed to by the Parties hereto; (b) in the event that any termination is based upon the provisions of Sections 6.1(b) or 6.1(c) hereof, such prior written notice shall be given at least ninety (90) days in advance of the effective date of termination unless a shorter time is agreed to by the Parties hereto; and (c) in the event that any termination is based upon the provisions of Sections 6.1(d), 6.1(f), 6.1(g), 6.1(h) or 6.1(i) hereof, such prior written notice shall be given as soon as possible within twenty-four (24) hours after the terminating Party learns of the event causing termination to be required.

  • Performance of Service; Limitation of Liability A. PFS shall exercise reasonable care in the performance of its duties under this Agreement. PFS shall not be liable for any error of judgment or mistake of law or for any loss suffered by the Trust in connection with matters to which this Agreement relates, including losses resulting from mechanical breakdowns or the failure of communication or power supplies beyond PFS's control, except a loss arising out of or relating to PFS's refusal or failure to comply with the terms of this Agreement or from bad faith, negligence, or willful misconduct on its part in the performance of its duties under this Agreement. Notwithstanding any other provision of this Agreement, if PFS has exercised reasonable care in the performance of its duties under this Agreement, the Trust shall indemnify and hold harmless PFS from and against any and all claims, demands, losses, expenses, and liabilities (whether with or without basis in fact or law) of any and every nature (including reasonable attorneys' fees) which PFS may sustain or incur or which may be asserted against PFS by any person arising out of any action taken or omitted to be taken by it in performing the services hereunder, except for any and all claims, demands, losses, expenses, and liabilities arising out of or relating to PFS's refusal or failure to comply with the terms of this Agreement or from bad faith, negligence or from willful misconduct on its part in performance of its duties under this Agreement, (i) in accordance with the foregoing standards, or (ii) in reliance upon any written or oral instruction provided to PFS by any duly authorized officer of the Trust, such duly authorized officer to be included in a list of authorized officers furnished to PFS and as amended from time to time in writing by resolution of the Board of Trustees of the Trust. PFS shall indemnify and hold the Trust harmless from and against any and all claims, demands, losses, expenses, and liabilities (whether with or without basis in fact or law) of any and every nature (including reasonable attorneys' fees) which the Trust may sustain or incur or which may be asserted against the Trust by any person arising out of any action taken or omitted to be taken by PFS as a result of PFS's refusal or failure to comply with the terms of this Agreement, its bad faith, negligence, or willful misconduct. In the event of a mechanical breakdown or failure of communication or power supplies beyond its control, PFS shall take all reasonable steps to minimize service interruptions for any period that such interruption continues beyond PFS's control. PFS will make every reasonable effort to restore any lost or damaged data and correct any errors resulting from such a breakdown at the expense of PFS. PFS agrees that it shall, at all times, have reasonable contingency plans with appropriate parties, making reasonable provision for emergency use of electrical data processing equipment to the extent appropriate equipment is available. Representatives of the Trust shall be entitled to inspect PFS's premises and operating capabilities at any time during regular business hours of PFS, upon reasonable notice to PFS. B. In order that the indemnification provisions contained in this section shall apply, it is understood that if in any case the indemnitor may be asked to indemnify or hold the indemnitee harmless, the indemnitor shall be fully and promptly advised of all pertinent facts concerning the situation in question, and it is further understood that the indemnitee will use all reasonable care to notify the indemnitor promptly concerning any situation which presents or appears likely to present the probability of a claim for indemnification. The indemnitor shall have the option to defend the indemnitee against any claim which may be the subject of this indemnification. In the event that the indemnitor so elects, it will so notify the indemnitee and thereupon the indemnitor shall take over complete defense of the claim, and the indemnitee shall in such situation initiate no further legal or other expenses for which it shall seek indemnification under this section. The indemnitee shall in no case confess any claim or make any compromise in any case in which the indemnitor will be asked to indemnify the indemnitee except with the indemnitor's prior written consent. C. PFS is hereby expressly put on notice of the limitation of shareholder, Trustee, officer, employee or agent liability as set forth in the Declaration of Trust of the Trust and agrees that obligations assumed by the Trust pursuant to this Agreement shall be limited in all cases to the Trust and its assets, and if the liability relates to one or more Funds, the obligations hereunder shall be limited to the respective assets of such Fund. PFS further agrees that it shall not seek satisfaction of any such obligation from any shareholder of a Fund, nor from any Trustee, officer, employee or agent of the Trust.

  • Contract Remedies and Early Termination 15 9.1 CONTRACT REMEDIES 15 9.2 TERMINATION FOR CONVENIENCE 16 9.3 TERMINATION FOR CAUSE 16 9.4 COSTS 16

  • Indemnification Provisions for Benefit of the Buyer (i) In the event the Seller breaches (or in the event any third party alleges facts that, if true, would mean the Seller has breached) any of its representations, warranties, and covenants contained herein, and, if there is an applicable survival period pursuant to Section 8(a) above, provided that the Buyer makes a written claim for indemnification against the Seller within such survival period, then the Seller shall indemnify the Buyer from and against the entirety of any Adverse Consequences the Buyer may suffer through and after the date of the claim for indemnification (including any Adverse Consequences the Buyer may suffer after the end of any applicable survival period) resulting from, arising out of, relating to, in the nature of, or caused by the breach (or the alleged breach). (ii) The Seller shall indemnify the Buyer from and against the entirety of any Adverse Consequences the Buyer may suffer resulting from, arising out of, relating to, in the nature of, or caused by any Liability of the Company (whether or not accrued or otherwise disclosed) (x) for any Taxes of the Company with respect to any Tax year or portion thereof ending on or before the Closing Date (or for any Tax year beginning before and ending after the Closing Date to the extent allocable to the portion of such period beginning before and ending on the Closing Date) and (y) for the unpaid Taxes of any Person (other than the Company) under Section 1.1502-6 of the Regulations adopted under the Code (or any similar provision of state, local, or foreign law), as a transferee or successor, by contract, or otherwise. (iii) The Seller shall indemnify the Buyer from and against the entirety of any Liabilities arising out of the ownership of the Shares or operation of the Company prior to the Closing. (iv) The Seller shall indemnify the Buyer from and against the entirety of any Adverse Consequences the Buyer may suffer resulting from, arising out of, relating to, in the nature of, or caused by any Indebtedness of the Company existing as of the Closing Date after adjustment pursuant to Section 2(d).

  • PROVISIONS SURVIVING EXPIRATION OR TERMINATION Notwithstanding the expiration or termination (by agreement, breach, or operation of time) of this Agreement, the provisions of this Agreement regarding payments (including liquidated damages and tax payments), reports, records, and dispute resolution of the Agreement shall survive the termination or expiration dates of this Agreement until the following occurs: A. all payments, including liquidated damage and tax payments, have been made; B. all reports have been submitted; C. all records have been maintained in accordance with Section 8.6.A; and D. all disputes in controversy have been resolved.

  • DETERMINATION OF BREACH AND TERMINATION OF AGREEMENT A. Prior to making a determination that the Applicant has failed to comply in any material respect with the terms of this Agreement or to meet any material obligation under this Agreement, the District shall provide the Applicant with a written notice of the facts which it believes have caused the breach of this Agreement, and if cure is possible, the cure proposed by the District. After receipt of the notice, the Applicant shall be given ninety (90) days to present any facts or arguments to the Board of Trustees showing that it is not in breach of its obligations under this Agreement, or that it has cured or undertaken to cure any such breach. B. If the Board of Trustees is not satisfied with such response or that such breach has been cured, then the Board of Trustees shall, after reasonable notice to the Applicant, conduct a hearing called and held for the purpose of determining whether such breach has occurred and, if so, whether such breach has been cured. At any such hearing, the Applicant shall have the opportunity, together with their counsel, to be heard before the Board of Trustees. At the hearing, the Board of Trustees shall make findings as to: i. whether or not a breach of this Agreement has occurred; ii. whether or not such breach is a Material Breach; iii. the date such breach occurred, if any;

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!