Consequences of change orders Sample Clauses

Consequences of change orders. If the Customer requires a change, the Contractor shall have the right to require adjustments to the contract price and progress plan or other matters, cf. clause 3.2, caused by the change requirement of the Customer. Adjustments to the contract price shall be calculated on the basis of the hourly charges or other unit prices set out in Appendix 7, provided that the work occasioned by the change is, in the main, similar to work for which hourly charges or unit prices have been specified. If it is not possible to calculate the change based on the hourly rates or unit prices in Appendix 7, the Contractor shall present a quote in respect of the addition or deduction for the changes. The offer shall reflect the general price level of this Agreement. If any changes and/or additions requested would, as a general rule, have resulted in an adjustment to the agreed date on which the solution will be ready for the acceptance test or delivery date, the Contractor shall, to the extent practicable, seek to accelerate implementation in order that the agreed deadlines may nevertheless be observed. In such case, acceleration shall be deemed to constitute a change to be dealt with pursuant to the rules set out in chapter 3. The change order shall be implemented without undue delay when received by the Contractor. This shall apply irrespective of whether the effect of the change order in terms of the contract price, the progress plan or other terms and conditions of the Agreement have been finally resolved, cf. clause 3.6.
Sample 1Sample 2Sample 3See All (9)
AutoNDA by SimpleDocs
Consequences of change orders. If the Customer requires a change, the Contractor shall have the right to require adjustments to the Estimated total cost and milestone plan and other matters, cf. clause 3.3, caused by the change requirement of the Customer. Adjustments to the Estimated total cost shall be calculated on the basis of the hourly rates or other unit prices set out in Appendix 7, provided that the work occasioned by the change is, in the main, similar to work for which hourly rates or unit prices have been specified. In cases other than those mentioned in the previous paragraph, the Contractor must submit an offer, specifying the additions or reductions resulting from the changes. The change shall be implemented when the Customer wishes, irrespective of whether the effect of the change order in terms of the Estimated total cost, milestone plan or other terms and conditions of the Agreement have been finally resolved, cf. clause 3.7.
Sample 1
Consequences of change orders. If the Customer requires a Change, the Supplier shall have the right to require adjustments to the contract price and progress plan or other matters caused by the Change. Adjustments to the contract price shall be calculated on the basis of the hourly charges or other unit prices set out in Appendix 6, provided that the work occasioned by the Change is, in the main, similar to work for which hourly charges or unit prices have been specified. If it is not possible to calculate the adjustments based on the hourly rates or unit prices in Appendix 6, the Supplier shall present a quote in respect of the addition or deduction for the Changes. The offer shall reflect the general price level of this MSA. A Change Oorder shall be implemented without undue delay when received by the Supplier, unless otherwise is agreed. This shall apply irrespective of whether the effect of the Change Order in terms of the contract price, the progress plan or other terms and conditions of the MSA, have been finally resolved.
Sample 1

Related to Consequences of change orders

  • Consequences of non-compliance If a beneficiary breaches any of its obligations under this Article, the grant may be reduced (see Article 43). Such breaches may also lead to any of the other measures described in Chapter 6.

  • Consequences of Events of Default (a) If an Event of Default of the type described in Section 3.1(a) or (b) has occurred and continued for 15 days or any other Event of Default has occurred, the interest rate on this Note will increase immediately by an increment of two percentage points to the extent permitted by law. Thereafter, until such time as no Event of Default exists, the interest rate on this Note will increase automatically at the end of each succeeding fiscal quarter by an additional increment of one percentage points to the extent permitted by law (but in no event will the interest rate exceed 18 percent per annum). Any increase of the interest rate resulting from the operation of this Section 3.2(a) will terminate as of the close of business on the date on which no Events of Default exist (subject to subsequent increases pursuant to this Section). (b) If an Event of Default of the type described in Section 3.1(d) has occurred, the principal amount of this Note (together with all accrued interest thereon and all other amounts payable in connection therewith) will become immediately due and payable without any action on the part of the Holder, and the Companies will immediately pay to the Holder all amounts due and payable with respect to this Note. (c) If an Event of Default of the type described in Section 3.1(a) or (b) has occurred and continued for 15 days and if an Event of Default of the type described in Section 3.1(b) has occurred and continued for 30 days, or any other Event of Default (other than under Section 3.1(d)) has occurred, the Holder may declare all or any portion of the outstanding principal amount of this Note (together with all accrued interest thereon and all other amounts due in connection therewith) due and payable and demand immediate payment of all or any portion of such amount. If the Holder demands immediate payment and all or any portion of the amounts due under this Note, the Companies will immediately pay to the Holder all amounts demanded to be paid with respect to this Note. (d) The Holder will also have any other rights which it may have been afforded under any contract or agreement at any time and any other rights which the Holder may have pursuant to applicable law. (e) Each Company hereby waives diligence, presentment, protest and demand and notice of protest and demand, dishonor and nonpayment of this Note, and expressly agrees that this Note, or any payment hereunder, may be extended from time to time and that the Holder may accept security for this Note or release security for this Note, all without in any way affecting the liability of the Companies hereunder.

  • Consequences of Default Upon the occurrence of any Event of Default, as defined in the Revenue Sharing Agreement: 6.1 Any unpaid amounts under section 2 shall bear interest at one and one-quarter percent (1.25%) per month;

  • Consequences of Breach Without prejudice to any rights that may be available to the Principal/Owner under law or the Contract or its established policies and laid down procedures, the Principal/Owner shall have the following rights in case of breach of this Integrity Pact by the Tenderer(s)/Contractor(s) and the Tenderer/ Contractor accepts and undertakes to respect and uphold the Principal/Owner’s absolute right: 1) If the Tenderer(s)/Contractor(s), either before award or during execution of Contract has committed a transgression through a violation of Article 2 above or in any other form, such as to put his reliability or credibility in question, the Principal/Owner after giving 14 days notice to the contractor shall have powers to disqualify the Tenderer(s)/ Contractor(s) from the Tender process or INTEGRITYPACT terminate/determine the Contract, if already executed or exclude the Tenderer/Contractor from future contract award processes. The imposition and duration of the exclusion will be determined by the severity of transgression and determined by the Principal/Owner. Such exclusion may be forever or for a limited period as decided by the Principal/Owner. 2) Forfeiture of EMD/Performance Guarantee/Security Deposit: If the Principal/Owner has disqualified the Tenderer(s) from the Tender process prior to the award of the Contract or terminated/determined the Contract or has accrued the right to terminate/determine the Contract according to Article 3(1), the Principal/Owner apart from exercising any legal rights that may have accrued to the Principal/Owner, may in its considered opinion forfeit the entire amount of Xxxxxxx Money Deposit, Performance Guarantee and Security Deposit of the Tenderer/Contractor.

  • Consequences of Force Majeure Subject to clauses 24.4, 24.5 and 24.6, if by reason of a Force Majeure Event a Party (Affected Party) is affected in the performance of any obligation or clause under this Agreement: (a) that Party will be excused during the time, and to the extent that, such performance is so affected; and (b) that Party will not, to that extent, be liable to the other Party for any Damage of any kind arising out of, or in any way connected with, that non-performance.

  • Consequences of Event of Default (a) Upon the occurrence of an Event of Default, the Company will promptly deliver written notice thereof to the Holder. If one or more Events of Default will have occurred and be continuing (whatever the reason for such Event of Default and whether it will be voluntary or involuntary or be effected by operation of law or pursuant to any judgment, decree or order of any court or any order, rule or regulation of any Governmental Authority), then, and in each and every such case (other than an Event of Default specified in Section 2.4(g) or Section 2.4(h) with respect to the Company or any of its Subsidiaries), unless the principal of this Note will have already become due and payable, the Holder may, by notice in writing to the Company, declare 100% of the outstanding principal of this Note to be due and payable immediately, and upon any such declaration the same will become and will automatically be immediately due and payable. If an Event of Default specified in Section 2.4(g) or Section 2.4(h) with respect to the Company or any of its Subsidiaries occurs and is continuing, 100% of the outstanding principal of this Note will become and will automatically be immediately due and payable without any action on the part of the Holder. (b) Subsection (a) above, however, is subject to the conditions that if, at any time after the outstanding principal of this Note will have been so declared due and payable, and before any judgment or decree for the payment of the monies due will have been obtained or entered as hereinafter provided, the Company will pay or will deposit with the Holder a sum sufficient to pay the outstanding principal of this Note that will have become due otherwise than by acceleration, and if (1) rescission would not conflict with any judgment or decree of a court of competent jurisdiction and (2) any and all existing Events of Default under this Note, other than the nonpayment of the principal on this Note that will have become due solely by such acceleration, will have been cured or waived, then and in every such case the Holder, by written notice to the Company, may waive all defaults or Events of Default with respect to this Note and rescind and annul such declaration and its consequences and such default will cease to exist, and any Event of Default arising therefrom will be deemed to have been cured for every purpose of this Note; but no such waiver or rescission and annulment will extend to or will affect any subsequent Event of Default, or will impair any right consequent thereon.

  • Consequences for Non-Compliance If the Department has reason to believe that the District is not in substantial compliance with one or more of the statutory or regulatory requirements applicable to the District, the Department shall notify the District that it has ninety (90) days after the date of notice to come into compliance. If, at the end of the ninety-day period, the Department finds the District is not substantially in compliance with the applicable statutory or regulatory requirements, meaning that the District has not yet taken the necessary measures to ensure that it meets the applicable legal requirements as soon as practicable, the District may be subject to the interventions specified in sections 00-00-000 through 00-00-000, C.R.S. If the District has failed to comply with the provisions of article 44 of title 22 or article 45 of title 22, the District does not remedy the noncompliance within ninety (90) days and loss of accreditation is required to protect the interests of the students and parents of students enrolled in the District public schools, the Department may recommend to the State Board that the State Board remove the District’s accreditation. If the Department determines that the District has substantially failed to meet requirements specified in this accreditation contract and that immediate action is required to protect the interests of the students and parents of students enrolled in the District’s public schools, the Department may lower the District’s accreditation category.

  • Consequences of a Servicer Default If a Servicer Default shall occur and be continuing, either the Indenture Trustee or the Noteholders whose Notes evidence not less than a majority of the Outstanding Amount of the Controlling Class as of the close of the preceding Distribution Date (or, if the Notes have been paid in full and the Indenture has been discharged in accordance with its terms, by the Owner Trustee or the Majority Certificateholders as of the close of the preceding Distribution Date) by notice then given in writing to the Servicer and the Owner Trustee (and to the Indenture Trustee if given by the Noteholders or the Certificateholders) may terminate all of the rights and obligations of the Servicer under this Agreement. On or after the receipt by the Servicer of such written notice, all authority and power of the Servicer under this Agreement, whether with respect to the Notes, the Certificates or the Receivables or otherwise, shall pass to and be vested in the Indenture Trustee pursuant to and under this Section 7.02. The Indenture Trustee is hereby authorized and empowered to execute and deliver, on behalf of the Servicer, as attorney-in-fact or otherwise, any and all documents and other instruments, and to do or accomplish all other acts or things necessary or appropriate to effect the purposes of such notice of termination, whether to complete the transfer and endorsement of the Receivables and related documents, or otherwise. The Servicer agrees to cooperate with the Indenture Trustee and the Owner Trustee in effecting the termination of the responsibilities and rights of the Servicer under this Agreement, including the transfer to the Indenture Trustee or the Owner Trustee for administration by it of all cash amounts that shall at the time be held by the Servicer for deposit, or that shall have been deposited by the Servicer in the Collection Account, or the Note Distribution Account or thereafter received with respect to the Receivables that shall at that time be held by the Servicer.

  • Resolution of Differences Over Breaches of Agreement Except as otherwise provided herein, in the event of any controversy, dispute or claim arising out of, or relating to this Agreement, or the breach thereof, or arising out of any other matter relating to the Employee’s employment with the Company or the termination of such employment, the parties may seek recourse only for temporary or preliminary injunctive relief to the courts having jurisdiction thereof and if any relief other than injunctive relief is sought, the Company and the Employee agree that such underlying controversy, dispute or claim shall be settled by arbitration conducted in Pittsburgh, Pennsylvania in accordance with this Section 11 of this Agreement and the Commercial Arbitration Rules of the American Arbitration Association (“AAA”). The matter shall be heard and decided, and awards rendered by a panel of three (3) arbitrators (the “Arbitration Panel”). The Company and the Employee shall each select one arbitrator from the AAA National Panel of Commercial Arbitrators (the “Commercial Panel”) and AAA shall select a third arbitrator from the Commercial Panel. The award rendered by the Arbitration Panel shall be final and binding as between the parties hereto and their heirs, executors, administrators, successors and assigns, and judgment on the award may be entered by any court having jurisdiction thereof.

  • Voluntariness and Consequences of Consent Denial or Withdrawal The Participant’s participation in the Plan and the Participant’s grant of consent is purely voluntary. The Participant may deny or withdraw his or her consent at any time. If the Participant does not consent, or if the Participant withdraws his or her consent, the Participant cannot participate in the Plan. This would not affect the Participant’s salary as an employee or his or her career; the Participant would merely forfeit the opportunities associated with the Plan.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!