Events of Tenant’s Default Tenant shall be in default of its obligations under this Lease if any of the following events occurs (an "Event of Tenant's Default"):
(a) Tenant shall have failed to pay Base Rent or Additional Charges when due, and such failure is not cured within five (5) days after delivery of written notice from Landlord specifying such failure to pay; or
(b) Tenant shall have failed to perform any term, covenant, or condition of this Lease except those requiring the payment of Base Rent or Additional Charges, and Tenant shall have failed to cure such breach within thirty (30) days after written notice from Landlord specifying the nature of such breach where such breach could reasonably be cured within said thirty (30) day period, or if such breach could not be reasonably cured within said thirty (30) day period, Tenant shall have failed to commence such cure within said thirty (30) day period and thereafter continue with due diligence to prosecute such cure to completion within such time period as is reasonably needed.
(c) Tenant shall have sublet the Premises or assigned its interest in the Lease in violation of the provisions contained in Section 14; or
(d) Tenant shall have abandoned the Premises or left the Premises substantially vacant for thirty (30) consecutive days; or
(e) The occurrence of the following: (i) the making by Tenant of any general arrangements or assignments for the benefit of creditors; (ii) Tenant becomes a "debtor" as defined in 11 U.S.
Consequences of Events of Default (a) If an Event of Default of the type described in Section 3.1(a) or (b) has occurred and continued for 15 days or any other Event of Default has occurred, the interest rate on this Note will increase immediately by an increment of two percentage points to the extent permitted by law. Thereafter, until such time as no Event of Default exists, the interest rate on this Note will increase automatically at the end of each succeeding fiscal quarter by an additional increment of one percentage points to the extent permitted by law (but in no event will the interest rate exceed 18 percent per annum). Any increase of the interest rate resulting from the operation of this Section 3.2(a) will terminate as of the close of business on the date on which no Events of Default exist (subject to subsequent increases pursuant to this Section).
(b) If an Event of Default of the type described in Section 3.1(d) has occurred, the principal amount of this Note (together with all accrued interest thereon and all other amounts payable in connection therewith) will become immediately due and payable without any action on the part of the Holder, and the Companies will immediately pay to the Holder all amounts due and payable with respect to this Note.
(c) If an Event of Default of the type described in Section 3.1(a) or (b) has occurred and continued for 15 days and if an Event of Default of the type described in Section 3.1(b) has occurred and continued for 30 days, or any other Event of Default (other than under Section 3.1(d)) has occurred, the Holder may declare all or any portion of the outstanding principal amount of this Note (together with all accrued interest thereon and all other amounts due in connection therewith) due and payable and demand immediate payment of all or any portion of such amount. If the Holder demands immediate payment and all or any portion of the amounts due under this Note, the Companies will immediately pay to the Holder all amounts demanded to be paid with respect to this Note.
(d) The Holder will also have any other rights which it may have been afforded under any contract or agreement at any time and any other rights which the Holder may have pursuant to applicable law.
(e) Each Company hereby waives diligence, presentment, protest and demand and notice of protest and demand, dishonor and nonpayment of this Note, and expressly agrees that this Note, or any payment hereunder, may be extended from time to time and that the Holder may accept security for this Note or release security for this Note, all without in any way affecting the liability of the Companies hereunder.
Consequences of Event of Default (a) Upon the occurrence of an Event of Default, the Company will promptly deliver written notice thereof to the Holder. If one or more Events of Default will have occurred and be continuing (whatever the reason for such Event of Default and whether it will be voluntary or involuntary or be effected by operation of law or pursuant to any judgment, decree or order of any court or any order, rule or regulation of any Governmental Authority), then, and in each and every such case (other than an Event of Default specified in Section 2.4(g) or Section 2.4(h) with respect to the Company or any of its Subsidiaries), unless the principal of this Note will have already become due and payable, the Holder may, by notice in writing to the Company, declare 100% of the outstanding principal of this Note to be due and payable immediately, and upon any such declaration the same will become and will automatically be immediately due and payable. If an Event of Default specified in Section 2.4(g) or Section 2.4(h) with respect to the Company or any of its Subsidiaries occurs and is continuing, 100% of the outstanding principal of this Note will become and will automatically be immediately due and payable without any action on the part of the Holder.
(b) Subsection (a) above, however, is subject to the conditions that if, at any time after the outstanding principal of this Note will have been so declared due and payable, and before any judgment or decree for the payment of the monies due will have been obtained or entered as hereinafter provided, the Company will pay or will deposit with the Holder a sum sufficient to pay the outstanding principal of this Note that will have become due otherwise than by acceleration, and if (1) rescission would not conflict with any judgment or decree of a court of competent jurisdiction and (2) any and all existing Events of Default under this Note, other than the nonpayment of the principal on this Note that will have become due solely by such acceleration, will have been cured or waived, then and in every such case the Holder, by written notice to the Company, may waive all defaults or Events of Default with respect to this Note and rescind and annul such declaration and its consequences and such default will cease to exist, and any Event of Default arising therefrom will be deemed to have been cured for every purpose of this Note; but no such waiver or rescission and annulment will extend to or will affect any subsequent Event of Default, or will impair any right consequent thereon.
Consequences of Default Upon the occurrence of any Event of Default, as defined in the Revenue Sharing Agreement:
6.1 Any unpaid amounts under section 2 shall bear interest at one and one-quarter percent (1.25%) per month;
Consequences of Force Majeure Subject to clauses 24.4, 24.5 and 24.6, if by reason of a Force Majeure Event a Party (Affected Party) is affected in the performance of any obligation or clause under this Agreement:
(a) that Party will be excused during the time, and to the extent that, such performance is so affected; and
(b) that Party will not, to that extent, be liable to the other Party for any Damage of any kind arising out of, or in any way connected with, that non-performance.
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
(i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord;
(ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed;
(iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord;
(iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed;
(v) Construction of any Change Requests;
(vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible);
(vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein;
(viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord;
(ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or
(x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Consequences of Termination If this Agreement is terminated pursuant to this Article, the Funder may:
(a) cancel all further Funding instalments;
(b) demand the repayment of any Funding remaining in the possession or under the control of the HSP;
(c) through consultation with the HSP, determine the HSP’s reasonable costs to wind down the Services; and
Consequences of an Event of Default (a) If an Event of Default specified in subsections (a) through (l), (o), (p) or (q) of Section 7.01 shall occur and, be continuing or shall exist, then, in addition to all other rights and remedies which the Administrative Agent or any Lender may have hereunder or under any other Loan Document, at law, in equity or otherwise, the Lenders shall be under no further obligation to make Loans hereunder, and the Administrative Agent may, and, upon the written request of the Required Lenders shall, by notice to the Borrower, from time to time do any or all of the following:
(i) Declare the Commitments terminated, whereupon the Commitments will terminate and any fees hereunder shall be immediately due and payable without presentment, demand, protest or further notice of any kind, all of which are hereby waived, and an action therefor shall immediately accrue.
(ii) Declare the unpaid principal amount of the Loans, interest accrued thereon and all other obligations to be immediately due and payable without presentment, demand, protest or further notice of any kind, all of which are hereby waived, and an action therefor shall immediately accrue.
(b) If an Event of Default specified in subsection (m) or (n) of Section 7.01 shall occur or exist, then, in addition to all other rights and remedies which the Administrative Agent or any Lender may have hereunder or under any other Loan Document, at law, in equity or otherwise, the Commitments shall automatically terminate and the Lenders shall be under no further obligation to make Loans, and the unpaid principal amount of the Loans, interest accrued thereon and all other obligations shall become immediately due and payable without presentment, demand, protest or notice of any kind, all of which are hereby waived, and an action therefor shall immediately accrue.
TENANT’S DEFAULTS In addition to any other event of default set forth in this Lease, the occurrence of any one or more of the following events shall constitute a default by Tenant:
(a) The failure by Tenant to make any payment of rent or additional rent required to be made by Tenant, as amid when due, where the failure continues for a period of five (5) days after written notice from Landlord to Tenant; provided, however, that any such notice shall be in lieu of, and not in addition to, any notice required under California Code of Civil Procedure Section 1161 and 1161(a) as amended. For purposes of these default and remedies provisions, the term “additional rent” shall be deemed to include all amounts of any type whatsoever other than Basic Rent to be paid by Tenant pursuant to the terms of this Lease.
(b) Assignment, sublease, encumbrance or other transfer of the Lease by Tenant, either voluntarily or by operation of law, whether by judgment, execution, transfer by intestacy or testacy, or other means, without the prior written consent of Landlord.
(c) The discovery by Landlord that any financial statement provided by Tenant, or by any affiliate, successor or guarantor of Tenant, was materially false.
(d) The failure of Tenant to timely and fully provide any subordination agreement, estoppel certificate or financial statements in accordance with the requirements of Article XIII.
(e) The failure or inability by Tenant to observe or perform any of the express or implied covenants or provisions of this Lease to be observed or performed by Tenant, other than as specified in any other subsection of this Section, where the failure continues for a period of thirty (30) days after written notice from Landlord to Tenant or such shorter period as is specified in any other provision of this Lease; provided, however, that any such notice shall be in lieu of, and not in addition to, any notice required under California Code of Civil Procedure Section 1161 and 1161(a) as amended. However, if the nature of the failure is such that more than thirty (30) days are reasonably required for its cure, then Tenant shall not be deemed to be in default if Tenant commences the cure within thirty (30) days, and thereafter diligently pursues the cure to completion.
(i) The making by Tenant of any general assignment for the benefit of creditors; (ii) the filing by or against Tenant of a petition to have Tenant adjudged a Chapter 7 debtor under the Bankruptcy Code or to have debts discharged or a petition for reorganization or arrangement under any law relating to bankruptcy (unless, in the case of a petition filed against Tenant, the same is dismissed within thirty (30) days); (iii) the appointment of a trustee or receiver to take possession of substantially all of Tenant’s assets located at the Premises or of Tenant’s interest in this Lease, if possession is not restored to Tenant within thirty (30) days; (iv) the attachment, execution or other judicial seizure of substantially all of Tenant’s assets located at the Premises or of Tenant’s interest in this Lease, where the seizure is not discharged within thirty (30) days; or (v) Tenant’s convening of a meeting of its creditors for the purpose of effecting a moratorium upon or composition of its debts. Landlord shall not be deemed to have knowledge of any event described in this subsection unless notification in writing is received by Landlord, nor shall there be any presumption attributable to Landlord of Tenant’s insolvency. In the event that any provision of this subsection is contrary to applicable law, the provision shall be of no force or effect.
