Construction; Absence of Presumption Sample Clauses

Construction; Absence of Presumption. (a) For the purposes of this Agreement: (i) words (including capitalized terms defined herein) in the singular shall be held to include the plural and vice versa and words (including capitalized terms defined herein) of one gender shall be held to include the other gender as the context requires; (ii) the terms “hereof,” “herein” and “herewith” and words of similar import shall, unless otherwise stated, be construed to refer to this Agreement as a whole (including all of the Exhibits) and not to any particular provision of this Agreement, and Article, Section, paragraph and Exhibit references are to the Articles, Sections, paragraphs and Exhibits to this Agreement, unless otherwise specified; (iii) the word “including” and words of similar import when used in this Agreement means “including without limitation”; (iv) “commercially reasonable efforts,” “reasonable best efforts” and “reasonable efforts” shall not require a waiver by any Party of any material rights or any action or omission that would be a breach of this Agreement; (v) all references to any period of days shall be deemed to be to the relevant number of calendar days unless otherwise specified; and (vi) all references herein to “$” or dollars shall refer to United States dollars, unless otherwise specified. (b) The Parties hereby acknowledge that each Party and its counsel have reviewed and revised this Agreement and that no rule of construction to the effect that any ambiguities are to be resolved against the drafting Party shall be employed in the interpretation of this Agreement (including all of the Exhibits) or any amendments hereto or thereto. (c) The Parties hereby acknowledge and agree that to the extent that there is a conflict between any (i) general provision of this Agreement and (ii) provision specifically relating to Tax matters, the terms of the specific Tax provision shall control.
Sample 1Sample 2See All (22)
AutoNDA by SimpleDocs
Construction; Absence of Presumption. 10.1.1 For the purposes of this Agreement, (a) words (including capitalized terms defined herein) in the singular shall be held to include the plural and vice versa and words (including capitalized terms defined herein) of one gender shall be held to include the other gender as the context requires, (b) the terms “hereof,” “herein” and “herewith” and words of similar import shall, unless otherwise stated, be construed to refer to this Agreement as a whole (including all Appendices) and not to any particular provision of this Agreement, and Article, Section, paragraph, and Appendix references are to the Articles, Sections, paragraphs, and Appendices to this Agreement, unless otherwise provided, (c) the words “including” and “such as” and words of similar import when used in this Agreement shall mean “including, without limitation”, and (d) all references to any period of days shall be deemed to be to the relevant number of calendar days unless otherwise provided. 10.1.2 The Parties hereby acknowledge that each Party and its counsel have reviewed and revised this Agreement in good faith and that no rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall be employed in the interpretation of this Agreement (including all Appendices) or any amendments hereto or thereto.
Sample 1Sample 2See All (7)
Construction; Absence of Presumption. (a) For the purposes of this Agreement, (i) words (including capitalized terms defined herein) in the singular shall be held to include the plural and vice versa, and words (including capitalized terms defined herein) of one gender shall be held to include the other gender as the context requires; (ii) the terms “hereof,” “herein” and “hereby” and words of similar import shall, unless otherwise stated, be construed to refer to this Agreement as a whole and not to any particular provision of this Agreement; (iii) Article and Section references are to the Articles and Sections to this Agreement, unless otherwise specified; (iv) the word “including” and words of similar import when used in this Agreement shall mean “including, without limitation”; (v) all references to any period of days shall be deemed to be to the relevant number of calendar days unless otherwise specified; and (vi) all references herein to “$” or “dollars” shall refer to United States dollars.
Sample 1Sample 2Sample 3See All (4)
Construction; Absence of Presumption. (a) For the purposes of this Agreement: (i) words (including capitalized terms defined herein) in the singular shall be held to include the plural and vice versa and words (including capitalized terms defined herein) of one gender shall be held to include the other gender as the context requires; (ii) the terms "hereof," "herein" and "herewith" and words of similar import shall, unless otherwise stated, be construed to refer to this Agreement as a whole (including all of the Exhibits) and not to any particular provision of this Agreement, and Article, Section, paragraph and Exhibit references are to the Articles, Sections, paragraphs and Exhibits to this Agreement, unless otherwise specified; (iii) the word "including" and words of similar import when used in this Agreement shall mean "including, without limitation"; (iv) "commercially reasonable efforts" shall not require a waiver by any Party of any material rights or any action or omission that would be a breach of this Agreement; (v) all references to any period of days shall be deemed to be to the relevant number of calendar days unless otherwise specified; and
Sample 1Sample 2Sample 3See All (4)
Construction; Absence of Presumption. (a) For the purposes of this Agreement: (i) words (including capitalized terms defined herein) in the singular shall be deemed to include the plural and vice versa and words (including capitalized terms defined herein) of one gender shall be deemed to include the other
Sample 1
Construction; Absence of Presumption. (a) For the purposes of this Agreement: (i) words (including capitalized terms defined herein) in the singular shall be held to include the plural and vice versa and words (including capitalized terms defined herein) of one gender shall be held to include the other gender as the context requires; (ii) the terms “hereof”, “herein”, “hereunder” and “herewith” and words of similar import shall, unless otherwise stated, be construed to refer to this Agreement as a whole (including all of the Exhibits) and not to any particular provision of this Agreement, and Article, Section, paragraph and Exhibit references are to the Articles, Sections, paragraphs and Exhibits to this Agreement, unless otherwise specified; (iii) the word “including” and words of similar import when used in this Agreement means “including without limitation”; (iv) all references to any period of days shall be deemed to be to the relevant number of calendar days unless otherwise specified; (v) the word “or” shall not be deemed to be exclusive, unless otherwise specified; (vi) the phrase “taxable year” includes, where the context permits, an accounting period; (vii) the word “extent” in the phrase “to the extent” means the degree to which a subject or other thing extends, and such phrase shall not mean simply “if”; (viii) except
Sample 1
Construction; Absence of Presumption. (a) For the purposes of this Agreement, (i) words (including capitalized terms defined herein) in the singular shall be held to include the plural and vice versa and words (including capitalized terms defined herein) of one gender shall be held to include the other gender as the context requires; (ii) the terms “hereof,” “herein” and “herewith” and words of similar import shall, unless otherwise stated, be construed to refer to this Agreement as a whole (including all of the Schedules, Exhibits and Addenda) and not to any particular provision of this Agreement, and Article, Section, paragraph, Schedule, Exhibit and Addendum references are to the Articles, Sections, paragraphs, Schedules, Exhibits and Addenda to this Agreement, unless otherwise provided; (iii) the word “including” and words of similar import when used in this Agreement shall mean
Sample 1
AutoNDA by SimpleDocs
Construction; Absence of Presumption. For the purposes of this Agreement, (i) words (including capitalized terms defined herein) in the singular shall be held to include the plural and vice versa, and words (including capitalized terms defined herein) of one gender shall be held to include the other gender as the context requires; (ii) the terms “hereof,” “herein” and “herewith” and words of similar import shall, unless otherwise stated, be construed to refer to this Agreement as a whole and not to any particular provision of this Agreement; (iii) Article and Section references are to the Articles and Sections to this Agreement, unless otherwise specified; (iv) the word “including” and words of similar import when used in this Agreement shall mean “including, without limitation”; (v) all references to any period of days shall be deemed to be to the relevant number of calendar days unless otherwise specified; and (vi) all references herein to “$” or dollars shall refer to United States dollars.
Sample 1

Related to Construction; Absence of Presumption

  • Interpretation; Absence of Presumption (a) It is understood and agreed that the specification of any dollar amount in the representations and warranties contained in this Agreement or the inclusion of any specific item in the Sellers Disclosure Letter is not intended to imply that such amounts or higher or lower amounts, or such items so included or other items, are or are not material, and no Party shall use the fact of the setting of any amount or the fact of the inclusion of any item in the Sellers Disclosure Letter in any dispute or controversy between the Parties as to whether any obligation, item or matter not described in this Agreement or included in the Sellers Disclosure Letter is or is not material for purposes of this Agreement. (b) For the purposes of this Agreement, (i) words in the singular shall be held to include the plural and vice versa, and words of one gender shall be held to include the other gender as the context requires; (ii) references to the terms Article, Section, paragraph, Exhibit and Schedule are references to the Articles, Sections, paragraphs, Exhibits and Schedules to this Agreement unless otherwise specified; (iii) the terms “hereof,” “herein,” “hereby,” “hereto,” and derivative or similar words refer to this entire Agreement, including the Schedules and Exhibits hereto; (iv) references to “$” or cash shall mean U.S. dollars; (v) the word “including” and words of similar import when used in this Agreement shall mean “including without limitation,” unless otherwise specified; (vi) the word “or” shall not be exclusive; (vii) references to “written” or “in writing” include in electronic form; (viii) provisions shall apply, when appropriate, to successive events and transactions; (ix) Sellers and Purchasers have each participated in the negotiation and drafting of this Agreement and if an ambiguity or question of interpretation should arise, this Agreement shall be construed as if drafted jointly by the Parties hereto and no presumption or burden of proof shall arise favoring or burdening any Party by virtue of the authorship of any of the provisions in this Agreement; (x) a reference to any Person includes such Person’s successors and permitted assigns; (xi) any reference to “days” shall mean calendar days unless Business Days are expressly specified; and (xii) when calculating the period of time before which, within which or following which any act is to be done or step taken pursuant to this Agreement, the date that is the reference date in calculating such period shall be excluded and if the last day of such period is not a Business Day, the period shall end at the close of business on the next succeeding Business Day. (c) If the Closing shall occur, notwithstanding anything in this Agreement to the contrary, any payment obligation of Purchasers hereunder shall be a joint and several obligation of Purchasers and the Transferred Entities.

  • Absence of Presumption This Agreement shall be construed without regard to any presumption or rule requiring construction or interpretation against the party drafting or causing any instrument to be drafted.

  • Construction With Other Parts Of The Tariff This ISA shall not be construed as an application for service under Part II or Part III of the Tariff.

  • Advice of Counsel, No Strict Construction Each of the parties represents to each other party hereto that it has discussed this Agreement with its counsel. The parties hereto have participated jointly in the negotiation and drafting of this Agreement. In the event an ambiguity or question of intent or interpretation arises, this Agreement shall be construed as if drafted jointly by the parties hereto and no presumption or burden of proof shall arise favoring or disfavoring any party by virtue of the authorship of any provisions of this Agreement.

  • Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Funding by Lenders; Presumption by Agent Unless Agent shall have received notice from a Lender prior to the proposed date of any Committed Borrowing of Eurodollar Rate Loans (or, in the case of any Committed Borrowing of Base Rate Loans, prior to 12:00 noon on the date of such Committed Borrowing) that such Lender will not make available to Agent such Lender’s share of such Committed Borrowing, Agent may assume that such Lender has made such share available on such date in accordance with Section 2.02 (or, in the case of a Committed Borrowing of Base Rate Loans, that such Lender has made such share available in accordance with and at the time required by Section 2.02) and may, in reliance upon such assumption, make available to Borrower a corresponding amount. In such event, if a Lender has not in fact made its share of the applicable Committed Borrowing available to Agent, then the applicable Lender and Borrower severally agree to pay to Agent forthwith on demand such corresponding amount in immediately available funds with interest thereon, for each day from and including the date such amount is made available to Borrower to but excluding the date of payment to Agent, at (A) in the case of a payment to be made by such Lender, the greater of the Federal Funds Rate and a rate determined by Agent in accordance with banking industry rules on interbank compensation, plus any administrative, processing or similar fees customarily charged by Agent in connection with the foregoing and (B) in the case of a payment to be made by Borrower, the interest rate applicable to Base Rate Loans. If Borrower and such Lender shall pay such interest to Agent for the same or an overlapping period, Agent shall promptly remit to Borrower the amount of such interest paid by Borrower for such period. If such Lender pays its share of the applicable Committed Borrowing to Agent, then the amount so paid shall constitute such Lender’s Committed Loan included in such Committed Borrowing. Any payment by Borrower shall be without prejudice to any claim Borrower may have against a Lender that shall have failed to make such payment to Agent.

  • Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.

  • MAINTENANCE OF CONDITIONS Conditions of employment in effect at the execution of this Agreement shall, except as improved herein, be maintained during the term of this Agreement.

  • Absence of Unlawful Influence The Company has not offered, or caused the Underwriters to offer, the Offered Securities to any person or entity with the intention of unlawfully influencing: (a) a customer or supplier of the Company or any affiliate of the Company to alter the customer’s or supplier’s level or type of business with the Company or such affiliate or (b) a journalist or publication to write or publish favorable information about the Company or any such affiliate.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!