Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.
Construction Management Fee The Construction Management Fee for the Project shall be either a ☒Lump Sum or ☐Not-To-Exceed Fee of Thirty-Six Thousand, Eight Hundred Forty-Six Dollars and Twenty-Six Cents ($36,846.26). NOTE: Allowances will be on a Not-To-Exceed basis. All unused funds will be returned to the School District at the time of construction closeout. Fee will be paid only on cost of work for these items. Exhibit C- Project Assignment Page 2 of 4
Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms.
b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage.
c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications.
d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders.
e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims.
f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc.
g. Assist in community outreach meetings and media relations
h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).
Construction Manager The individual, partnership, corporation, joint venture, or any combination thereof, or its authorized representative, named as such by the District. If no Construction Manager is used on the Project that is the subject of this Contract, then all references to Construction Manager herein shall be read to refer to District.
Management by Manager i) The Member hereby elects Charter Communications, Inc., a Delaware corporation (formerly known as CCH I, LLC) (“CCI”), or its successor-in-interest, as the Company’s manager (the “Manager”). CCI shall be the Manager until a simple majority of the Votes elects otherwise. No additional person may be elected as Manager without the approval of a simple majority of the Votes (for purposes of this Agreement, to the extent the context requires, the term “person” refers to both individuals and entities). Except as otherwise required by applicable law and as provided below with respect to the Manager’s board of directors (the “Board”), the powers of the Company shall at all times be exercised by or under the authority of, and the business, property and affairs of the Company shall be managed by, or under the direction of, the Manager. The Manager is a “manager” of the Company within the meaning of the Act. Any person appointed as Manager shall accept its appointment by execution of a consent to this Agreement.
ii) The Manager shall be authorized to elect, remove or replace directors and officers of the Company, who shall have such authority with respect to the management of the business and affairs of the Company as set forth herein or as otherwise specified by the Manager in the resolution or resolutions pursuant to which such directors or officers were elected.
iii) Except as otherwise required by this Agreement or applicable law, the Manager shall be authorized to execute or endorse any check, draft, evidence of indebtedness, instrument, obligation, note, mortgage, contract, agreement, certificate or other document on behalf of the Company without the consent of any Member or other person.
iv) No annual or regular meetings of the Manager or the Members are required. The Manager may, by written consent, take any action which it is otherwise required or permitted to take at a meeting.
v) The Manager’s duty of care in the discharge of its duties to the Company and the Members is limited to discharging its duties pursuant to this Agreement in good faith, with the care a director of a Delaware corporation would exercise under similar circumstances, in the manner it reasonably believes to be in the best interests of the Company and its Members.
vi) Except as required by the Act, no Manager shall be liable for the debts, liabilities and obligations of the Company, including without limitation any debts, liabilities and obligations under a judgment, decree or order of a court, solely by reason of being a manager of the Company.
Management by Managers (a) Except as otherwise expressly provided in this Agreement or to the extent delegated by the written consent of the Sole Member, (i) the business and affairs of the Company solely shall be vested in and controlled by the Managers, which shall have the exclusive power and authority, on behalf of the Company, to take any action and to do anything and everything they deem necessary or appropriate to carry on the business of the Company, (ii) the Managers shall have full, exclusive and complete discretion in the management and control of the Company, (iii) all decisions relating to the business and affairs of the Company shall be made by, and all action proposed to be taken by or on behalf of the Company, shall be taken by, the Managers and (iv) the Managers shall have full power and authority to execute all documents and take all other actions on behalf of the Company and thereby bind the Company and the Sole Member with respect thereto, including, without limitation, all decisions required or permitted to be made by the Sole Member under this Agreement and all decisions required or permitted to be made by the Company as a member, partner or other beneficial owner of any other Person. Notwithstanding the foregoing or anything in this Agreement to the contrary, the Sole Member may take any action that the LLC Law or this Agreement requires or permits the Managers to take.
(b) The implementation of any decisions properly made by the Managers, including the execution and delivery of all documents, may be through any Person selected by the Managers (including any Manager or Officer). All approvals and consents required or permitted herein may be prospective or retroactive.
(c) The Managers are, to the extent of their rights and powers set forth in this Agreement, agents of the Company for the purpose of the Company’s business, and all actions of the Managers taken in accordance with such rights and powers shall bind the Company.
(d) The Managers shall consist of not less than one (1) nor more than eight (8)
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Utilization Management Contractor shall maintain a utilization management program that complies with applicable laws, rules and regulations, including Health and Safety Code § 1367.01 and other requirements established by the applicable State Regulators responsible for oversight of Contractor.
Construction Services 4,500 thousand SDR for Japan Post in Group A 15,000 thousand SDR for all other entities in Group A 4,500 thousand SDR for entities in Group B Architectural, engineering and other technical services covered by this Agreement: 450 thousand SDR
Management by Members Management of the Company shall be vested in its members. The members shall have the exclusive right, power and authority to manage and operate the business and affairs of the Company and to authorize any act or transaction on behalf of the Company. The members may from time to time appoint and delegate authority to act on behalf of the Company to such officers as the members deem appropriate. Any deed, agreement or other instrument, whether or not for apparently carrying on in the usual way the business or affairs of the Company, shall be binding on the Company and may be relied upon by any person or entity which is supplied with such executed deed, agreement or other instrument, if the same is executed on behalf of the Company by a member.
