Construction Period Guaranty Sample Clauses

Construction Period Guaranty. On or prior to January 1, 2018, Contractor will to deliver to Owner and maintain in full force and effect either (i) the Construction Period Guaranty executed by Guarantor for the benefit of Owner or (ii) a payment bond in an amount equal to [**] ($[**]) in form and substance reasonably satisfactory to Owner and issued by a surety reasonably acceptable to Owner assuring the payments otherwise guaranteed by the Construction Period Guaranty (the “Project Surety Bond”). The Construction Period Guaranty or the Project Surety Bond, as the case may be, shall remain in effect until the earlier to occur of (x) payment in full, or termination, of all of the payment obligations (including contingent obligations) guaranteed thereby and (z) the delivery to Owner of the Post-Construction Guaranty (“Construction Period Guaranty Expiration”).
Sample 1Sample 2
AutoNDA by SimpleDocs
Construction Period Guaranty. Until such time as the Initial Improvements have been constructed to the point of Substantial Completion of such Initial Improvements, the obligations of Tenant under this Lease shall be guaranteed by Xxxxx X. Xxxxx and Xxxxx Xxxxxx pursuant to the term of the Lease Guaranty attached hereto as Schedule 10.5.
Sample 1

Related to Construction Period Guaranty

  • Construction Contract If federal funds are included as part of the financing of the non-OPWC portion of the Project, federal law may prevail, including, but not limited to, application of Xxxxx Xxxxx prevailing wage rates, the Xxxxxxxx “Anti-Kickback” Act, the Contract Work Hours and Safety Standards Act, and any federal environmental regulations. Recipient is solely responsible for ensuring compliance with federal requirements applicable to its Local Subdivision Contribution. Notwithstanding the above, the following provisions apply to construction contracts under this Agreement:

  • Construction Period During the construction period, Redeveloper agrees to keep the construction area, including completed operations insured against loss or damage by fire, and such other risks, casualties, and hazards as are customarily covered by builders’ risk or extended coverage policies in an amount not less than the replacement value but allowing for reasonable coinsurance clauses and deductibles. In the event of any insured damage or destruction, Redeveloper agrees to use its good faith efforts to commence restoration of the Private Improvements to its prior condition within nine (9) months from the date of the damage or destruction, and shall diligently pursue the same to completion.

  • Project Completion Date It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.

  • Contract Amendment A. Contract Exhibit A, Scope of Work, is hereby deleted and replaced in its entirety with the attached Exhibit A, Scope of Work, which is incorporated into the Contract by reference herein. B. Contract Exhibit B, Additional Special Contract Conditions, is hereby deleted in its entirety and replaced with the attached Exhibit B, Additional Special Contract Conditions, which is incorporated into the ACS by reference herein. C. Contract Exhibit I, PUR 1355: Foreign Country of Concern Attestation, is hereby incorporated in its entirety to the ACS by reference herein.

  • Term of Agreement; Amendment; Assignment A. This Agreement shall become effective with respect to each Fund listed on Exhibit A hereof as of the date hereof and, with respect to each Fund not in existence on that date, on the date an amendment to Exhibit A to this Agreement relating to that Fund is executed. Unless sooner terminated as provided herein, this Agreement shall continue in effect for two years from the date hereof. Thereafter, if not terminated, this Agreement shall continue in effect automatically as to each Fund for successive one-year periods, provided such continuance is specifically approved at least annually by: (i) the Trust’s Board, or (ii) the vote of a “majority of the outstanding voting securities” of a Fund, and provided that in either event, the continuance is also approved by a majority of the Trust’s Board who are not “interested persons” of any party to this Agreement, by a vote cast in person at a meeting called for the purpose of voting on such approval. B. Notwithstanding the foregoing, this Agreement may be terminated, without the payment of any penalty, with respect to a particular Fund: (i) through a failure to renew this Agreement at the end of a term, (ii) upon mutual consent of the parties, or (iii) upon not less than 60 days’ written notice, by either the Trust upon the vote of a majority of the members of its Board who are not “interested persons” of the Trust and have no direct or indirect financial interest in the operation of this Agreement, or by vote of a “majority of the outstanding voting securities” of a Fund, or by the Distributor. The terms of this Agreement shall not be waived, altered, modified, amended or supplemented in any manner whatsoever except by a written instrument signed by the Distributor and the Trust. If required under the 1940 Act, any such amendment must be approved by the Trust’s Board, including a majority of the Trust’s Board who are not “interested persons” of any party to this Agreement, by a vote cast in person at a meeting for the purpose of voting on such amendment. In the event that such amendment affects the Advisor, the written instrument shall also be signed by the Advisor. This Agreement will automatically terminate in the event of its “assignment.” C. As used in this Section, the terms “majority of the outstanding voting securities,” “interested person,” and “assignment” shall have the same meaning as such terms have in the 1940 Act. D. Sections 7 and 8 shall survive termination of this Agreement.

  • Assignment Amendments Waiver and Contract Complete 032620-FDX

  • Construction Contracts Item A: Enter the total dollar amount of all contacts awarded on the project/ program. Item B: Enter the total dollar amount of contracts connected with this project/program that were awarded to Section 3 businesses.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Term of Guaranty This Guaranty shall continue in effect until all the Guaranteed Obligations and all of the obligations of Guarantor to Lender under this Guaranty are fully and finally paid, performed and discharged and are not subject to any bankruptcy preference period or any other disgorgement.

  • Substantial Completion Date Substantial Completion of the Work as defined in Article 6.1.2 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by July 31, 2022.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!