APPLICABLE LAW, FORUM, VENUE AND JURISDICTION (a) This Agreement shall be construed in accordance with and governed by the laws of the State of Delaware, without regard to the principles of conflicts of law.
Limited Waiver of Sovereign Immunity Ex Contractu Contractor acknowledges and agrees that Owner is an agency or instrumentality of the State of Georgia, and as such is entitled to the protection of sovereign immunity. As set forth in Article I, Section II, Paragraph IX of the 1983 Georgia Constitution, sovereign immunity is waived “as to any action ex contractu for the breach of any written contract.” Contractor specifically acknowledges the constitutional and contractual requirements that written changes, modifications, and waivers to this Contract must be specifically executed by the Owner as set forth in the Contract Documents. Accordingly, Contractor specifically acknowledges the constitutional prohibitions against claims against Owner based solely upon oral statement, course of conduct, customs of the trade, quasi-contract, quantum meruit, or O.C.G.A § 13-4-4 (mutual departure from contract terms).
Specific Order Processes and Requirements 1. Distributor will order Software from SAP using and filling out completely such forms and minimum order requirements as SAP may prescribe from time to time and must comply with any then-current order process for the specific Software product. Where applicable, Distributor agrees to use the electronic means provided by SAP for placing orders.
Limitation on Out-of-State Litigation - Texas Business and Commerce Code § 272 This is a requirement of the TIPS Contract and is non-negotiable. Texas Business and Commerce Code § 272 prohibits a construction contract, or an agreement collateral to or affecting the construction contract, from containing a provision making the contract or agreement, or any conflict arising under the contract or agreement, subject to another state’s law, litigation in the courts of another state, or arbitration in another state. If included in Texas construction contracts, such provisions are voidable by a party obligated by the contract or agreement to perform the work. By submission of this proposal, Vendor acknowledges this law and if Vendor enters into a construction contract with a Texas TIPS Member under this procurement, Vendor certifies compliance.
Infringement and Defense of Licensee SAP shall defend Licensee against claims brought against Licensee in the Territory by any third party alleging that Licensee's Use of the Software, in accordance with the terms and conditions of this Agreement, constitutes a direct infringement or misappropriation of such third party’s patent claim(s), copyright or trade secret rights, and SAP will pay damages finally awarded against Licensee (or the amount of any settlement SAP enters into) with respect to such claims. This obligation of SAP shall not apply if the alleged infringement or misappropriation results from (i) Use of the Software in conjunction with any other software; (ii) Use of the Software with an apparatus other than a Designated Unit; (iii) failure to promptly use an update provided by SAP if such infringement or misappropriation could have been avoided by use of the update; or (iv) any Use not permitted by this Agreement. This obligation of SAP also shall not apply if Licensee fails to timely notify SAP in writing of any such claim; however Licensee’s failure to provide or delay in providing such notice shall not relieve SAP of its obligations under this Section except to the extent SAP is prejudiced by Licensee’s failure to provide or delay in providing such notice. SAP is permitted to control fully the defense and any settlement of any such claim as long as such settlement shall not include a financial obligation on or admission of liability by Licensee. In the event Licensee declines SAP’s proffered defense, or otherwise fails to give full control of the defense to SAP’s designated counsel, then Licensee waives SAP’s obligations under this Section 8.1. Licensee shall reasonably cooperate in the defense of such claim and may appear, at its own expense, through counsel reasonably acceptable to SAP. SAP expressly reserves the right to cease such defense of any claim(s) in the event the Software is no longer alleged to infringe or misappropriate, or is held not to infringe or misappropriate, the third party’s rights. SAP may settle or mitigate damages from any claim or potential claim by substituting alternative substantially equivalent non-infringing programs and supporting documentation for the Software. Licensee shall not undertake any action in response to any infringement or misappropriation, or alleged infringement or misappropriation of the Software that is prejudicial to SAP’s rights.
Notification of Modifications of Licensed Materials From time to time Publisher may add, change, or modify portions of the Licensed Materials, or migrate the Licensed Materials to other formats. When such changes, modifications, or migrations occur, the Licensor shall give notice of any such changes to Licensee as soon as is practicable, but in no event less than sixty (60) days in advance of modification. Such a notice may also be given directly by the Publisher to the Licensee. If any of the changes, modifications, or migrations renders the Licensed Materials substantially less useful to the Licensee, the Participating Institutions or their Authorized Users, the Licensee may seek to terminate this Agreement for breach pursuant to the termination provisions of this Agreement in Section XI, below.
County of Orange Child Support Enforcement In order to comply with the child support enforcement requirements of the County of Orange, within ten (10) days of notification of selection of award of CONTRACT but prior to official award of CONTRACT, the selected CONTRACTOR agrees to furnish to the CONTRACT MANAGER, the Purchasing Agent, or the agency/department deputy purchasing agent:
Exclusion of applications on preliminary points of law Any recourse to any Court for the determination of a preliminary point of law arising in the course of the arbitration proceedings is excluded.
Program Requirements Provided At No Charge to the Judicial Council A. The Contractor shall provide the following items during the Program at no charge to the Judicial Council:
Objections to New Subprocessors (a) If Customer has a legitimate reason under Data Protection Law to object to the new Subprocessors’ processing of Personal Data, Customer may terminate the Agreement (limited to the Cloud Service for which the new Subprocessor is intended to be used) on written notice to SAP. Such termination shall take effect at the time determined by the Customer which shall be no later than thirty days from the date of SAP’s notice to Customer informing Customer of the new Subprocessor. If Customer does not terminate within this thirty day period, Customer is deemed to have accepted the new Subprocessor.
