Expansion Premises (a) In consideration of the rents, terms, provisions and covenants of this Amendment and the Lease, Landlord hereby leases unto Tenant and Tenant hereby rents and accepts from Landlord the Expansion Premises. The Expansion Premises is more particularly described on Exhibit A attached hereto. The Expansion Premises is contiguous to the Replacement Premises.
(b) Tenant covenants, as a material part of the consideration for the Lease, as amended hereby, to keep and perform each and all of said terms, covenants and conditions for which Tenant is liable and that this Amendment is made upon the condition of such performance. On and after the Second Renewal Term Commencement Date, all of the terms and provisions of the Lease, as amended hereby, shall apply to both the Replacement Premises and the Expansion Premises. From and after the Second Renewal Term Commencement Date, each and every reference in the Lease and in this Amendment to “Premises” shall be and mean the Replacement Premises and the Expansion Premises, collectively. The Replacement Premises and Expansion Premises consist of a total of approximately 12,103 rentable square feet. The Expansion Premises shall be known as Suite 246.
(c) At Landlord’s request, Tenant shall execute a Commencement Date Memorandum in the form attached hereto as Exhibit B acknowledging, among other things, the (i) Second Renewal Term Commencement Date, (ii) scheduled termination date of the Lease and (iii) Tenant’s acceptance of the Expansion Premises. Tenant’s failure to execute the Commencement Date Memorandum shall not affect Tenant’s liability hereunder.
Early Occupancy If Tenant occupies the Property prior to the Commencement Date, Tenant's occupancy of the Property shall be subject to all of the provisions of this Lease. Early occupancy of the Property shall not advance the expiration date of this Lease. Tenant shall pay Base Rent and all other charges specified in this Lease for the early occupancy period.
Tenant Covenants (a) From and after the date hereof, Tenant will not pay any rent under the Lease more than thirty (30) days in advance of its due date.
(b) From and after the date hereof, so long as there shall be any assignment of Landlord's interest in the Lease to Lender, or any successor thereto, Tenant will not: consent to the modification of the Lease nor to the termination thereof without the prior written consent of the Lender or any successor holder of the Loan or the Mortgage which consent shall not be unreasonably withheld or delayed (either of them being called "Mortgagee"), nor seek to terminate the Lease by reason of any act or omission of Landlord until Tenant shall have given written notice of such act or omission to such Mortgagee's last address furnished Tenant) and until a reasonable period of time shall have elapsed following the giving of such notice, during which period the Mortgagee shall have the right, but not the obligation, to remedy such act or omission.
(c) Upon written notice of the default by Landlord under any of the loan documents held by Mortgagee and assignment of the Landlord's interest under the Lease by Landlord to Mortgagee, Tenant, if Mortgagee so requests, will recognize such Mortgagee as the Landlord under the Lease and will thereafter pay rent and other sums to Mortgagee (or to the party designated by the Mortgagee in writing) in accordance with the terms of the Lease, and, in such event, such Mortgagee will not be liable for any act or omission of any prior lessor, liable for return of the security deposit unless same was actually delivered to Mortgagee, bound by any amendment to or assignment of the Lease made without its consent, bound by any rent paid more than thirty (30) days in advance, or be subject to any set-off or defense Tenant might have had against any prior lessor.
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
(i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord;
(ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed;
(iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord;
(iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed;
(v) Construction of any Change Requests;
(vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible);
(vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein;
(viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord;
(ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or
(x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Landlord’s Work The Landlord will provide and carry out, in accordance with the provisions of the Lease, including, without limitation, this Schedule, at the Tenant’s expense, all equipment and work other than Tenant’s Work required to be provided in order to render the Premises complete and suitable to open for business (the “Landlord’s Work”) including, but not limited to the following: • Connecting all utilities including, power to building and distribution panels to the Premises, including the requirement to provide via separate metering. • Connecting water, including without limitation hot water, to greenhouse area and distribution water tank(s). • Installation of a storage cooler. • All concrete work around the greenhouse and drive-way to the compost hut and floor for compost piles as designed. • Installation of necessary or required ventilation fans. • Installation or replacement of lighting, including without limitation any required high upper grow lights. • Installation of hand wash stations in the Premises. • Gas heaters and controls. • Any repairs or refurbishing of outer panels, germination room walls. The Tenant’s consent (not to be unreasonably withheld, conditioned or delayed), shall be required prior to the commencement of the Landlord’s Work. The Landlord shall provide, in such detail as the Tenant may reasonably request, all material documentation relating to the Landlord’s Work, including without limitation, any proposed plans and drawings, proposed agreements with any contractors or subcontractors and estimated costs to complete the Landlord’s Work. Subject to receiving the Tenant’s consent as contemplated herein, the Landlord shall commence the Landlord’s Work in accordance with the terms of this Lease. Upon completion of the Landlord’s Work, the Landlord shall provide the Tenant receipted invoices verifying the actual cost of completing the Landlord’s Work in the Premises. It is acknowledged and agreed that in consideration for the Tenant being responsible for all the costs associated with the Landlord’s Work as contemplated herein, the cost of the Landlord’s Work shall be included in total amount subject recoverable by the Tenant and to the Free Rent Period (as hereinafter defined) subject to the terms and conditions of this Schedule “D” and the Lease, generally.
LESSOR'S ACCESS; SHOWING PREMISES; REPAIRS Lessor and Lessor's agents shall have the right to enter the Premises at any time, in the case of an emergency, and otherwise at reasonable times for the purpose of showing the same to prospective purchasers, lenders, or lessees, and making such alterations, repairs, improvements or additions to the Premises or to the Building, as Lessor may reasonably deem necessary. Lessor may at any time place on or about the Premises or Building any ordinary "For Sale" signs and Lessor may at any time during the last one hundred eighty (180) days of the term hereof place on or about the Premises any ordinary "For Lease" signs. All such activities of Lessor shall be without abatement of rent or liability to Lessee.
Disbursement of Tenant Improvement Allowance During the construction of the Tenant Improvements, Landlord shall make monthly disbursements of the Tenant Improvement Allowance for Tenant Improvement Allowance Items for the benefit of Tenant and shall authorize the release of monies for the benefit of Tenant as follows.
Landlord’s Default Subject to Landlord's right to dispute its obligation in accordance with Section 5.1.5(b), if Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement, and any such default shall continue for a period of ten (10) days after Notice thereof with respect to monetary defaults, and thirty (30) days after Notice thereof with respect to non-monetary defaults, from Tenant to Landlord and, subject to Section 19.3, any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct such non-monetary defaults, Tenant may declare the occurrence of a "Landlord Default" under this Agreement by giving Notice of such declaration to Landlord and to such Facility Mortgagee. Thereafter, Tenant may (but shall have no obligation to) cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys' fees, paralegals' fees and court costs) incurred by Tenant in curing the same. If any such costs and expenses have not been reimbursed to Tenant as of the fifth (5th) day after the Landlord receives Tenant's Notice therefor, Landlord shall pay to Tenant, a late charge computed at the Overdue Rate on the amount of such reimbursement from the expiration of the applicable cure period to the date of payment thereof. Except as otherwise expressly provided herein to the contrary, Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder or under the Other Leases and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof; provided, however, that in the event of any such adverse determination, Landlord shall pay to Tenant interest on any disputed funds at the Disbursement Rate, from the date demand for such funds was made by Tenant until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. During the term of the Operating Agreement, Landlord shall indemnify and hold Tenant harmless against all claims, costs and expenses (including reasonable attorneys' fees and paralegals' fees) arising from a Landlord Default under the terms and conditions of this Agreement which shall cause an Event of Default under Section 16.01 of the Operating Agreement or a breach by Landlord of its obligations under the Owner Agreement or the Pooling Agreement. The provisions of this Section 14.2 shall survive the termination, expiration or cancellation of this Agreement for a period of five (5) years.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Tenant’s Lease Default Notwithstanding any provision to the contrary contained in the Lease, if an event of default by Tenant as described in Section 12.01 of the Lease or any default by Tenant under this Work Letter (which, for purposes hereof, shall include, without limitation, the delivery by Tenant to Landlord of any oral or written, including electronic, notice instructing Landlord to cease the design and/or construction of the Tenant Improvements and/or that Tenant does not intend to occupy the Premises, and/or any other anticipatory breach of the Lease) has occurred at any time on or before the Substantial Completion of the Premises, then (i) in addition to all other rights and remedies granted to Landlord pursuant to the Lease, at law and/or in equity, Landlord shall have the right to withhold payment of all or any portion of the Tenant Improvement Allowance and/or Landlord may cause Contractor to cease the construction of the Premises (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such work stoppage as a Tenant Delay as set forth in Section 5.01 above), and (ii) all other obligations of Landlord under the terms of this Work Letter shall be forgiven until such time as such default is cured pursuant to the terms of the Lease (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such inaction by Landlord as a Tenant Delay). In addition, if the Lease is terminated prior to the Lease Commencement Date, for any reason due to an event of default by Tenant as described in Section 12.01 of the Lease or under this Work Letter (including, without limitation, any anticipatory breach described above in this Section 6.05), then (A) Tenant shall be liable to Landlord for all damages available to Landlord pursuant to the Lease and otherwise available to Landlord at law and/or in equity by reason of a default by Tenant under the Lease or this Work Letter, and (B) Tenant shall pay to Landlord, as Additional Rent under the Lease, within five (5) Business Days after Tenant’s receipt of a statement therefor, any and all costs incurred by Landlord (including any portion of the Tenant Improvement Allowance disbursed by Landlord) and not reimbursed or otherwise paid by Tenant through the date of such termination in connection with the Tenant Improvements to the extent planned, installed and/or constructed as of such date of termination, including, but not limited to, any costs related to the removal of all or any portion of the Tenant Improvements and restoration costs related thereto.