CONTRACT REQUIREMENTS A. Project area boundaries are marked with two blue paint slashes and block boundaries are designated with one blue paint slash. B. All blocks are accessible by foot only. Xxxxxx’x Creek must be crossed on foot from the PGC railroad grade. C. Block 1, All trees 1” DBH and over, except for red and blue paint marked trees are to be cut. All conifers are reserved. Block 1 will be cut during the dormant season; October 15 through March 15. D. Block 2, All American beech, sweet birch, aspen, stripped maple, and ironwood 1” DBH and greater will be cut. All yellow marked trees will be cut. Block 2 will be cut during the dormant season; October 15 through March 15. E. Block 3, All trees 1” DBH and over, except for red and blue paint marked trees are to be cut. All conifers are reserved. Block 3 will be cut during the dormant season; October 15 through March 15. F. All employees must be able to identify species. G. Usable material may not be removed from site. X. Xxxxx material felled with clean cuts must have stumps that are parallel to the ground surface and shall not exceed six (6) inches in height measured on the side next to the highest ground or the diameter of the xxxxx, whichever is smaller, except when in the opinion of the Field Contract Coordinator, said height is impractical. I. Cut trees must be removed from trails, roads, tail drains, streams, and utility rights-of- way. J. All trees shall be felled so tops do not pile on one another but lie singly on the ground. K. Slash shall be lopped to no higher than 4’ and pulled apart as directed by the Regional Forester. L. Operator shall exercise care and caution in all operations to prevent damage to all trees not specified for treatment. M. All tops must be pulled back 25 feet from the State Game Land boundary, (blazed & painted white), all roads, parking lots, herbaceous openings, utility Right of Ways and deer exclosures. Tops, branches, and slash will be removed from all ponds, lakes, and streams. N. Damage to trails, roads, streams, or utility rights-of-way caused by the Operator’s equipment must be repaired by the Operator at their expense. O. Any trash resulting from the Operator’s operations must be removed from the area and properly disposed. P. The Operator shall not block any roads or trails in the area during performance of this contract. The Operator shall not in any way hinder the progress of any Timber Sale Contracts in these areas. Q. All labor, equipment, tools, etc., needed to complete contracted projects are to be provided by the Operator. R. Timber Damages – when in the opinion of Field Contract Coordinator, damage to the residual stand becomes excessive, the Operator shall pay the Commission a fair base current value determined by the Field Contract Coordinator per unit of volume. If this value for damage due to Operator’s carelessness or negligence is less than $10.00 per tree, then a minimum charge of $10.00 per tree will be made whether the tree is commercial, non-commercial, merchantable, or non-merchantable.
Subcontract Requirements As required by Section 6.22(e)(5) of the Administrative Code, Contractor shall insert in every subcontract or other arrangement, which it may make for the performance of Covered Services under this Agreement, a provision that said subcontractor shall pay to all persons performing labor in connection with Covered Services under said subcontract or other arrangement not less than the highest general prevailing rate of wages as fixed and determined by the Board of Supervisors for such labor or services.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Minimum Condition and Warranty Requirements for TIPS Sales All goods quoted or sold through a TIPS Sale shall be new unless clearly stated otherwise in writing. All new goods and services shall include the applicable manufacturers minimum standard warranty unless otherwise agreed to in the Supplemental Agreement.
SERVICE REQUIREMENTS FOR REFERRED CLIENTS A. Agent agrees to respond to any communications from a Referred Client within two (2) hours after receipt if such communication is received between 9:00am to 5:00pm local time. For communications received outside of these hours, Agent agrees to respond by 10:00am the next day. B. Agent agrees to update XXXX.xxx with status updates within 48 hours after initial communication with a Referred Client and upon every significant status change until closing or abandoned. Updates shall be made by Agent via email to xxxxxxxxxxxx@xxxx.xxx. C. Vacations or extended absences shall be reported, with length of pause, to XXXX.xxx via email to D. Agent will not add Referred Client to any email list or calling list without the express permission of Referred Client. E. Agent agrees XXXX.xxx has the right to survey the Referred Client at any time. F. If Agent is contacted by a Referred Client that Agent is unwilling or unable to assist, Agent shall direct such Referred Client back to XXXX.xxx for assistance and notify XXXX.xxx at xxxxxxxxxxxx@xxxx.xxx. G. Agent agrees that XXXX.xxx has no obligation to provide Agent with any number of referrals and that prospective clients are free to select the agent they wish to work with for any particular real estate transaction.
Support Requirements If there is a dispute between the awarded vendor and TIPS Member, TIPS or its representatives may assist, at TIPS sole discretion, in conflict resolution or third party (mandatory mediation), if requested by either party. TIPS, or its representatives, reserves the right to inspect any project and audit the awarded vendors TIPS project files, documentation and correspondence. TIPS Members stand in the place of TIPS as related to this agreement and have the same access to the proposal information and all related documents. TIPS Members have all the same rights under the awarded Agreement as TIPS.
Program Requirements The parties shall comply with the Disadvantaged Business Enterprise Program requirements established in 49 CFR Part 26.
Project Requirements 1. Project must conform to regulations under 24 CFR Part 92, commonly known as the HOME Regulations.