Contract Value Terms and Pricing. Provide information as described above in the Overview section, number 3.
Contract Value Terms and Pricing Sample Clauses
Related to Contract Value Terms and Pricing
Price Schedule, Payment Terms and Billing, and Price Adjustments (a) Price Schedule: Price Schedule under this Contract is set forth in Exhibit B.
Payment Terms and Billing (1) Payment shall be made only after the Client Agency receives and accepts the Goods or Services and after it receives a properly completed invoice. Unless otherwise specified in the Contract, payment for all accepted Goods or Services shall be due within forty-five (45) days after acceptance of the Goods or Services, or thirty (30) days if the Contractor is a certified small contractor or minority business enterprise as defined in Conn. Gen.
GSA Benchmarked Pricing Additionally, where the NYS Net Price is based upon an approved GSA Supply Schedule:
Contract Modifications It is understood that changes are inherent in operations of the type covered by this contract. The number of changes, the scope of those changes, and the impact they have on the progress of the original operations cannot be defined at this time. The PURCHASER is notified that changes are anticipated and that there will be no compensation made to the PURCHASER directly related to the number of changes made. Each change will be evaluated for extension of contract time and increase or decrease in compensation based on its own merit. STATE reserves the right to make, at any time during the contract, such modifications as are necessary or desirable; provided such modifications shall not change the character of the operations to be done nor increase the cost, unless such operations or cost increase is approved in writing by PURCHASER. Any modifications so made shall not invalidate this contract nor release PURCHASER of obligations under the performance bond. PURCHASER agrees to do the modified operations as if it had been a part of the original contract. If any change under this section causes an increase or decrease in the PURCHASER's cost of, or the time required for the performance of any part of the operations, the PURCHASER must submit a written statement setting forth the nature and specific extent of the claim. Such claim shall include all time and cost impacts against the contract and be submitted as soon as possible, but no later than 30 days after receipt of any written notice of modification of the contract. If the PURCHASER discovers site conditions which differ materially from what was represented in the contract or from conditions that would normally be expected to exist and be inherent to the activities defined in the contract, the PURCHASER shall notify the STATE's Authorized Representative immediately and before the area has been disturbed. The STATE's Authorized Representative will investigate the area and make a determination as to whether or not the conditions differ materially from either the conditions stated in the contract or those which could reasonably be expected in execution of this particular contract. If it is determined that a differing site condition exists, any compensation or credit will be determined based on an analysis by STATE's Authorized Representative. If the PURCHASER does not concur with the decision of the STATE's Authorized Representative and/or believes that it is entitled to additional compensation, the PURCHASER may proceed to file a claim. All claims shall be submitted in writing and shall include a detailed, factual statement of the basis of the claim, pertinent dates, contract provisions which support or allow the claim, reference to or copies of any documents which support the claim, the exact dollar value of the claim, and specific time extension requested for the claim. If the claim involves operations to be completed by subcontractors, the PURCHASER will analyze and evaluate the merits of the subcontractor's claim. PURCHASER shall forward the subcontractor's claim and PURCHASER's evaluation of such claim to STATE's Authorized Representative. The STATE's Authorized Representative will not consider direct claims from subcontractors, suppliers, manufacturers, or others not a party to this contract. The decision of the STATE shall be final and binding unless the PURCHASER requests mediation.
Unit Pricing If required by the Bid Specifications, the Bidder should insert the price per unit specified and the price extensions in decimals, not to exceed four places for each item unless otherwise specified, in the Bid. In the event of a discrepancy between the unit price and the extension, the unit price shall govern unless, in the sole judgment of the Commissioner, such unit pricing is obviously erroneous.
CONTRACT MODIFICATION The following is adopted as the new CTC for the Contract effective December 29, 2022:
PREVAILING WAGE RATES - PUBLIC WORKS AND BUILDING SERVICES CONTRACTS If any portion of work being Bid is subject to the prevailing wage rate provisions of the Labor Law, the following shall apply:
Sentencing Guidelines Calculations Defendant understands that in imposing sentence the Court will be guided by the United States Sentencing Guidelines. Defendant understands that the Sentencing Guidelines are advisory, not mandatory, but that the Court must consider the Guidelines in determining a reasonable sentence.
Prices and Services Billing 8.1 SCHEDULE OF PRICES AND TERMS Competitive Supplier agrees to provide Firm Full-Requirements Power Supply and other related services as expressly set forth herein in accordance with the prices and terms included in EXHIBIT A to this ESA, which exhibit is hereby incorporated by reference into this ESA.
Description of Goods or Services and Additional Terms and Conditions The Contractor shall perform as set forth in Exhibit A. For purposes of this Contract, to perform and the performance in Exhibit A is referred to as “Perform” and the “Performance.”
