COPYRIGHTS AND LICENSES § 7.1 The Architect and the Owner warrant that in transmitting Instruments of Service, or any other information, the transmitting party is the copyright owner of such information or has permission from the copyright owner to transmit such information for its use on the Project.
§ 7.2 The Architect and the Architect’s consultants shall be deemed the authors and owners of their respective Instruments of Service, including the Drawings and Specifications, and shall retain all common law, statutory and other reserved rights, including copyrights. Submission or distribution of Instruments of Service to meet official regulatory requirements or for similar purposes in connection with the Project is not to be construed as publication in derogation of the reserved rights of the Architect and the Architect’s consultants.
§ 7.3 The Architect grants to the Owner a nonexclusive license to use the Architect’s Instruments of Service solely and exclusively for purposes of constructing, using, maintaining, altering and adding to the Project, provided that the Owner substantially performs its obligations under this Agreement, including prompt payment of all sums due pursuant to Article 9 and Article 11. The Architect shall obtain similar nonexclusive licenses from the Architect’s consultants consistent with this Agreement. The license granted under this section permits the Owner to authorize the Contractor, Subcontractors, Sub-subcontractors, and suppliers, as well as the Owner’s consultants and separate contractors, to reproduce applicable portions of the Instruments of Service, subject to any protocols established pursuant to Section 1.3, solely and exclusively for use in performing services or construction for the Project. If the Architect rightfully terminates this Agreement for cause as provided in Section 9.4, the license granted in this Section 7.3 shall terminate.
§ 7.3.1 In the event the Owner uses the Instruments of Service without retaining the authors of the Instruments of Service, the Owner releases the Architect and Architect’s consultant(s) from all claims and causes of action arising from such uses. The Owner, to the extent permitted by law, further agrees to indemnify and hold harmless the Architect and its consultants from all costs and expenses, including the cost of defense, related to claims and causes of action asserted by any third person or entity to the extent such costs and expenses arise from the Owner’s use of the Instruments of Service under this Section 7.3.1. The terms of this Section 7.3.1 shall not apply if the Owner rightfully terminates this Agreement for cause under Section 9.4.
§ 7.4 Except for the licenses granted in this Article 7, no other license or right shall be deemed granted or implied under this Agreement. The Owner shall not assign, delegate, sublicense, pledge or otherwise transfer any license granted herein to another party without the prior written agreement of the Architect. Any unauthorized use of the Instruments of Service shall be at the Owner’s sole risk and without liability to the Architect and the Architect’s consultants.
§ 7.5 Except as otherwise stated in Section 7.3, the provisions of this Article 7 shall survive the termination of this Agreement.
Copyrights, Patents, Trademarks and Licenses, etc The Company and each Subsidiary own or are licensed or otherwise have the right to use all of the material patents, trademarks, service marks, trade names, copyrights, contractual franchises, authorizations and other rights that are reasonably necessary for the operation of their respective businesses, without material conflict with the rights of any other Person. To the best knowledge of the Company, no slogan or other advertising device, product, process, method, substance, part or other material now employed, or now contemplated to be employed, by the Company or any Subsidiary infringes upon any rights held by any other Person. Except as specifically disclosed in Schedule 6.5, no claim or litigation regarding any of the foregoing is pending or, to the knowledge of the Company, threatened, and no patent, invention, device, application, principle or any statute, law, rule, regulation, standard or code is pending or, to the knowledge of the Company, proposed, which, in either case, would reasonably be expected to have a Material Adverse Effect.
Covenants Regarding Patent, Trademark and Copyright Collateral (a) Each Grantor agrees that it will not, and will not permit any of its licensees to, do any act, or omit to do any act, whereby any Patent that is material to the conduct of such Grantor’s business may become abandoned, invalidated or dedicated to the public, and agrees that it shall use commercially reasonable efforts to continue to xxxx any products covered by a material Patent with the relevant patent number as necessary and sufficient to establish and preserve its maximum rights under applicable patent laws.
(b) Except as could not reasonably be expected to result in a Material Adverse Effect, each Grantor (either itself or through its licensees or its sublicensees) will, for each Trademark material to the conduct of such Grantor’s business, (i) maintain such Trademark in full force free from any claim of abandonment or invalidity for non-use, (ii) use commercially reasonable efforts to maintain the quality of products and services offered under such Trademark, (iii) display such Trademark with notice of Federal or foreign registration to the extent necessary and sufficient to establish and preserve its maximum rights under applicable law and (iv) not knowingly use or knowingly permit the use of such Trademark in violation of any third party rights.
(c) Each Grantor (either itself or through its licensees or sublicensees) will, for each work covered by a Copyright material to the conduct of such Grantor’s business, continue to publish, reproduce, display, adopt and distribute the work with appropriate copyright notice as necessary and sufficient to establish and preserve its maximum rights under applicable copyright laws.
(d) Each Grantor shall notify the Collateral Agent promptly if it knows or has reason to know that any Patent, Trademark or Copyright material to the conduct of its business may become abandoned, lost or dedicated to the public, or of any adverse determination or development (including the institution of, or any such determination or development in, any proceeding in the United States Patent and Trademark Office, United States Copyright Office or any court or similar office of any country) regarding such Grantor’s ownership of any Patent, Trademark or Copyright, its right to register the same, or its right to keep and maintain the same.
(e) Except as could not reasonably be expected to result in a Material Adverse Effect, no Grantor shall, either itself or through any agent, employee, licensee or designee, file an application for any Patent, Trademark or Copyright (or for the registration of any Trademark or Copyright) with the United States Patent and Xxxxxxxxx Xxxxxx, Xxxxxx Xxxxxx Copyright Office or any office or agency in any political subdivision of the United States or in any other country or any political subdivision thereof, unless it promptly notifies the Collateral Agent, and, upon request of the Collateral Agent, executes and delivers any and all agreements, instruments, documents and papers as the Collateral Agent may request to evidence the Security Interest in such Patent, Trademark or Copyright, and each Grantor hereby appoints the Collateral Agent as its attorney-in-fact to execute and file such writings for the foregoing purposes, all acts of such attorney being hereby ratified and confirmed; such power, being coupled with an interest, is irrevocable.
(f) Except as could not reasonably be expected to result in a Material Adverse Effect, each Grantor will take all necessary steps that are consistent with the practice in any proceeding before the United States Patent and Trademark Office, United States Copyright Office or any office or agency in any political subdivision of the United States or in any other country or any political subdivision thereof, to maintain and pursue each material application relating to the Patents, Trademarks and/or Copyrights (and to obtain the relevant grant or registration) and to maintain each issued Patent and each registration of the Trademarks and Copyrights that is material to the conduct of any Grantor’s business, including timely filings of applications for renewal, affidavits of use, affidavits of incontestability and payment of maintenance fees, and, if consistent with good business judgment, to initiate opposition, interference and cancellation proceedings against third parties.
(g) In the event that any Grantor knows or has reason to believe that any Article 9 Collateral consisting of a Patent, Trademark or Copyright material to the conduct of any Grantor’s business has been or is about to be infringed, misappropriated or diluted by a third person, such Grantor promptly shall notify the Collateral Agent and shall, if consistent with good business judgment, promptly xxx for infringement, misappropriation or dilution and to recover any and all damages for such infringement, misappropriation or dilution, and take such other actions as are appropriate under the circumstances to protect such Article 9
Trademark Licenses (a) The Knicks hereby grant to Licensor for the Term non-exclusive royalty-free licenses by the Knicks and Team of all intellectual property owned or licensed by the Knicks or the Team, including but not limited to images, likenesses, service marks, tradenames and trademarks, for the exclusive purposes of promoting the Arena as the home arena of the Team, operating the Arena and providing the Licensor Services. Licensor’s use of such licenses shall be in accordance with and subject to League Rules and subject to the Knicks prior written approval. Licensor shall not have any right to sublicense, or seek or receive any payments from third parties specifically for the use of, the Knicks’ intellectual property, except in accordance with ARTICLE VII, it being understood that Licensor may exercise the right to promote the Arena as the home arena of the Team in places and in a manner that may also incorporate in an incidental manner promotion of Licensor’s marketing partners and sponsors (including, without limitation, use in connection with the Knicks’ intellectual property any overall Arena marketing partner(s) “lock-up logo” or naming rights, sponsored Licensor web pages and upcoming events promotions, etc.).
(b) The Knicks shall be permitted to reference the Arena as their home venue on all material promoting the Team and ticket sales (and the Ticket Agent). In connection therewith, Licensor and its Affiliates hereby grant to the Knicks a non-exclusive royalty-free license to use the trademarks “MADISON SQUARE GARDEN,” “MSG,” “THE WORLD’S MOST FAMOUS ARENA” and related logos solely for such promotional purposes. The Knicks’ use of such licenses shall be subject to the Licensor’s prior written approval, not to be unreasonably withheld, conditioned or delayed. The Knicks shall not have any right to sublicense, or seek or receive any payments from third parties specifically for the use of, Licensor’s intellectual property.
Patents, Trademarks, Copyrights and Licenses All patents, patent applications, trademarks, trademark applications, service marks, service xxxx applications, copyrights, copyright applications, design rights, tradenames, assumed names, trade secrets and licenses owned or utilized by any Borrower are set forth on Schedule 5.9, are valid and have been duly registered or filed with all appropriate Governmental Bodies and constitute all of the intellectual property rights which are necessary for the operation of its business; there is no objection to or pending challenge to the validity of any such patent, trademark, copyright, design rights, tradename, trade secret or license and no Borrower is aware of any grounds for any challenge, except as set forth in Schedule 5.9 hereto. Each patent, patent application, patent license, trademark, trademark application, trademark license, service xxxx, service xxxx application, service xxxx license, design rights, copyright, copyright application and copyright license owned or held by any Borrower and all trade secrets used by any Borrower consist of original material or property developed by such Borrower or was lawfully acquired by such Borrower from the proper and lawful owner thereof. Each of such items has been maintained so as to preserve the value thereof from the date of creation or acquisition thereof. With respect to all software used by any Borrower, such Borrower is in possession of all source and object codes related to each piece of software or is the beneficiary of a source code escrow agreement, each such source code escrow agreement being listed on Schedule 5.9 hereto.
Assignment of Rights to Intellectual Property The Executive shall promptly and fully disclose all Intellectual Property to the Company. The Executive hereby assigns and agrees to assign to the Company (or as otherwise directed by the Company) the Executive’s full right, title and interest in and to all Intellectual Property. The Executive agrees to execute any and all applications for domestic and foreign patents, copyrights or other proprietary rights and to do such other acts (including without limitation the execution and delivery of instruments of further assurance or confirmation) requested by the Company to assign the Intellectual Property to the Company and to permit the Company to enforce any patents, copyrights or other proprietary rights to the Intellectual Property. The Executive will not charge the Company for time spent in complying with these obligations. All copyrightable works that the Executive creates shall be considered “work made for hire”.
Trademark License System Agency grants to Grantee, for the term of the Grant Agreement, a limited non- exclusive, royalty-free, non-assignable, non-transferable license to reproduce System Agency’s trademarks on published materials in the United States related to the performance of the Grant Agreement, provided that such license is expressly conditional upon, and subject to, the following:
i. Grantee is in compliance with all provisions of the Grant Agreement;
ii. Grantee’s use of the trademarks is strictly in accordance with the quality standards and in conformance with the reproduction requirements set forth in this Grant Agreement or as otherwise communicated by System Agency;
iii. Grantee takes no action to damage the goodwill associated with the trademarks, and refrains from any attempt to contest, attack, dispute, challenge, cancel and/or oppose System Agency’s right, title and interest in the trademarks or their validity;
iv. Grantee makes no attempt to sublicense any rights under this trademark license; and
v. Grantee complies with any marking requests System Agency may make in relation to the trademarks, including without limitation to use the phrase “Registered Trademark”, the registered trademark symbol “®” for registered trademarks, and the symbol “™” for unregistered trademarks.
COPYRIGHT, PATENTS AND OTHER PROPRIETARY RIGHTS 16.1 Except as is otherwise expressly provided in writing in the Contract, UNDP shall be entitled to all intellectual property and other proprietary rights including, but not limited to, patents, copyrights, and trademarks, with regard to products, processes, inventions, ideas, know-how, or documents and other materials which the Contractor has developed for UNDP under the Contract and which bear a direct relation to or are produced or prepared or collected in consequence of, or during the course of, the performance of the Contract. The Contractor acknowledges and agrees that such products, documents and other materials constitute works made for hire for UNDP.
16.2 To the extent that any such intellectual property or other proprietary rights consist of any intellectual property or other proprietary rights of the Contractor: (i) that pre-existed the performance by the Contractor of its obligations under the Contract, or (ii) that the Contractor may develop or acquire, or may have developed or acquired, independently of the performance of its obligations under the Contract, UNDP does not and shall not claim any ownership interest thereto, and the Contractor grants to UNDP a perpetual license to use such intellectual property or other proprietary right solely for the purposes of and in accordance with the requirements of the Contract.
16.3 At the request of UNDP, the Contractor shall take all necessary steps, execute all necessary documents and generally assist in securing such proprietary rights and transferring or licensing them to UNDP in compliance with the requirements of the applicable law and of the Contract.
16.4 Subject to the foregoing provisions, all maps, drawings, photographs, mosaics, plans, reports, estimates, recommendations, documents, and all other data compiled by or received by the Contractor under the Contract shall be the property of UNDP, shall be made available for use or inspection by UNDP at reasonable times and in reasonable places, shall be treated as confidential, and shall be delivered only to UNDP authorized officials on completion of work under the Contract.
Copyrights, Patents and Trademarks (i) Borrower hereby represents and warrants that, as of the date of this Agreement, Borrower does not have any maskworks, computer software, or other copyrights, that are registered (or are the subject of any application for registration) with the United States Copyright Office. Borrower hereby covenants and agrees that Borrower will NOT register with the United States Copyright Office (or apply for such registration of) any of Borrower’s maskworks, computer software, or other copyrights, unless Borrower has provided Lender not less than 30 days prior written notice of the commencement of such registration/application and Borrower has executed and delivered to Lender such security agreement(s) and other documentation (in form and substance reasonably satisfactory to Lender) which Lender in its good faith business judgment may require for filing with the United States Copyright Office with respect to such registration or application.
(ii) Borrower will identify to Lender in writing any and all patents and trademarks of Borrower that are registered (or the subject of any application for registration) with the United States Patent and Trademark Office and, upon Lender’s request therefor, promptly execute and deliver to Lender such security agreement(s) and other documentation (in form and substance reasonably satisfactory to Lender) which Lender in its good faith business judgment may require for filing with the United States Patent and Trademark Office with respect to such registration or application.
(iii) Borrower will: (x) protect, defend and maintain the validity and enforceability of Borrower’s copyrights, patents, and trademarks; (y) promptly advise Lender in writing of material infringements of Borrower’s copyrights, patents, or trademarks of which Borrower is or becomes aware; and (z) not allow any material item of Borrower’s copyrights, patents, or trademarks to be abandoned, forfeited or dedicated to the public without Lender’s written consent.
Trademark Usage Customer agrees that QuoVadis may use Customer’s name and trademark to perform its obligations under this Agreement and to indicate that Customer is receiving QuoVadis’s Service, provided that such use would not foreseeably diminish or damage Customer’s rights in any of its trademarks, create a misrepresentation of the parties’ relationship, or diminish or damage a party’s reputation. Neither party may register or claim any right in the other party’s trademarks. Customer grants QuoVadis a right to use any trademark of Customer included in the Certificate to the extent necessary to operate such Certificate.
