Correction of Latent Existing Defects Sample Clauses

Correction of Latent Existing Defects. Austin Engineering shall promptly notify Hanover of any Latent Existing Defect in writing and obtain Hanover’s prior written approval as to scope and cost of the work before proceeding with any corrective work for which Austin Engineering intends to seek compensation. Except for emergencies or situations in which prior notice is not commercially reasonable, if Austin Engineering corrects a Latent Existing Defect without prior notice to Hanover and without a written directive from Hanover to undertake such work, then Austin Engineering shall be deemed to have waived any claim against Hanover for such work. For corrective work performed on a Latent Existing Defect by Austin Engineering with Hanover’s prior written approval, which is: (i) completed to the satisfaction of City of Leander and Hanover; and (ii) accepted under the Contract Documents, Hanover shall pay Austin Engineering an amount equal to its reasonable and necessary direct costs for field labor, associated fringe benefits, taxes and insurances, materials and equipment, together with a xxxx-up on those direct costs not to exceed 150% as full compensation for all associated elements of direct and indirect cost (including for field superintendent and field and home office overhead) and profit, regardless of the extent or aggregate number of all corrective work items and any resulting impact or delay to Austin Engineering’s other operations.
Sample 1
AutoNDA by SimpleDocs

Related to Correction of Latent Existing Defects

  • Correction of Defects 35.1 The Engineer shall give notice to the Contractor of any Defects before the end of the Defects Liability Period, which begins at Completion and is defined in the Contract Data. The Defects Liability Period shall be extended for as long as Defects remain to be corrected. 35.2 Every time notice of a Defect is given, the Contractor shall correct the notified Defect within the length of time specified by the Engineer’s notice.

  • Latent Defects Notwithstanding anything to the contrary set forth herein, no acceptance, or deemed acceptance, by City pursuant to this Section shall be applicable with respect to any Latent Defects. An acceptance, or deemed acceptance, by City pursuant to this Section shall not mean that City has accepted, or the other party has been relieved of, responsibility for: (i) compliance with the Laws; (ii) the proper application of construction means or methods; or (iii) correcting any portion of the Project if it later is determined that any portion of the Project is inconsistent with the Final Documents and Drawings.

  • Inspection and Rejection of Nonconforming Goods The Buyer has the right to inspect the Goods on or after the Delivery Date. Buyer, at its sole option, may inspect all or a sample of the Goods, and may reject all or any portion of the Goods if it determines the Goods are nonconforming or defective. If Buyer rejects any portion of the Goods, Buyer has the right, effective upon written notice to Seller, to: (a) rescind the Order in its entirety; (b) accept the Goods at a reasonably reduced price; or (c) reject the Goods and require replacement of the rejected Goods. If Buyer requires replacement of the Goods, Seller shall, at its expense, promptly replace the nonconforming Goods and pay for all related expenses, including, but not limited to, transportation charges for the return of the defective goods and the delivery of replacement Goods. If Seller fails to timely deliver replacement Goods, Buyer may replace them with goods from a third party and charge Seller the cost thereof and terminate this Order for cause pursuant to Section 19. Any inspection or other action by Buyer under this Section shall not reduce or otherwise affect Seller's obligations under the Order, and Buyer shall have the right to conduct further inspections after Seller has carried out its remedial actions.

  • Cost of remedying Defects Any repair or rectification undertaken in accordance with the provisions of Clause 17.2, including any additional testing, shall be carried out by the Contractor at its own risk and cost, to the extent that such rectification or repair is attributable to: (a) the design of the Project; (b) Plant, Materials or workmanship not being in accordance with this Agreement and the Specifications and Standards; (c) improper maintenance during construction of the Project Highway by the Contractor; and/ or (d) failure by the Contractor to comply with any other obligation under this Agreement.

  • Manufacturer’s Warranty The Goods include the manufacturer’s standard limited parts warranty to replace defective parts covered under such warranty exclusive of labor. Labor is warranted by the Elevator Contractor for 90 days following installation. The manufacturer’s parts warranty may require that the Goods be maintained throughout the warranty period by an authorized manufacturer’s representative under a separate maintenance contract. Any warranty is conditioned on written notice to the Elevator Contractor within warranty period and contingent upon receipt of final payment to Elevator Contractor.

  • Correction of Errors Contractor shall perform, at its own cost and expense and without reimbursement from the District, any work necessary to correct errors or omissions which are caused by the Contractor’s failure to comply with the standard of care required herein.

  • REMEDY OF DEFECTS (a) The BUILDER shall remedy, at its expense, any defects, against which the VESSEL is guaranteed under this Article, by making all necessary repairs or replacements at the SHIPYARD or elsewhere as provided for in (b) hereinbelow. In such case, the VESSEL shall be taken at the BUYER's cost and responsibility to the place selected, ready in all respects for such repairs or replacements and in any event, the BUILDER shall not be responsible for towage, dockage, wharfage, port charges and anything else incurred for the BUYER's getting and keeping the VESSEL ready for such repairing or replacing. (b) However, if it is impractical (which shall include, but not be limited to, an emergency) to bring the VESSEL to the SHIPYARD, the BUYER may cause the necessary repairs or replacements to be made elsewhere which is deemed by the BUYER with the consent of the BUILDER which shall not be unreasonably withheld, to be suitable for the purpose, provided that, in such event, the BUILDER may forward or supply replacement parts or materials under the terms described in (c) hereinbelow, unless forwarding or supplying thereof under the terms described in (c) hereinbelow would impair or delay the operation or working schedule of the VESSEL. In the event that the BUYER proposes to cause the necessary repairs or replacements to be made to the VESSEL at any shipyard or works other than the SHIPYARD, the BUYER shall first (but in all events as soon as reasonably possible) give the BUILDER notice by email or facsimile of the time and place such repairs will be made, and if the VESSEL is not thereby delayed, or her operation or working schedule is not thereby impaired, the BUILDER shall have the right to verify by its own representative(s) the nature and extent of the defects complained of. The BUILDER shall, in such case, promptly advise the BUYER by email or facsimile, after such examination has been completed, of its acceptance or rejection of the defects as ones that are covered by the guarantee herein provided. Upon the BUILDER's acceptance of the defects as justifying remedy under this Article, or upon award of the arbitration so determining, the BUILDER shall compensate the BUYER an amount equal to the reasonable cost of making the same repairs or replacements at the SHIPYARD. (c) In the event that it is necessary for the BUILDER to forward a replacement for a defective part under this guarantee, replacement parts shall be shipped to the BUYER under the C.I.F terms to the BUYER's nominated port. The BUILDER reserves the option to retrieve, at the BUILDER's cost, any of the replaced equipment/parts in case defects are remedied in accordance with the provisions in this Article. (d) Any dispute under this Article shall be referred to arbitration in accordance with the provisions of Article XIII hereof.

  • Hardware Warranty Company warrants that for a period of one (1) year from delivery of Hardware, Hardware will be free from defects in material and workmanship in normal use, but does not cover any of the following: (i) improper installation, maintenance, adjustment, repair or modification by Customer or a third party; (ii) misuse, neglect, or any other cause other than ordinary use, including without limitation, accidents or acts of God; (iii) improper environment, excessive or inadequate heating or air conditioning, electrical power failures, surges, water damage or other irregularities; (iv) third party software or software drivers; or (v) damage during shipment.

  • Title Warranty Assignor warrants that: a. Except as specifically set forth in the Purchase and Sale Agreement described in Article 10. below or under the contracts and agreements listed in Exhibit 1 to this Assignment, and further except as a consequence of the formation of a unit, neither Assignor nor any parent, subsidiary or affiliate of Assignor during their respective periods of ownership has (A) executed any deed, conveyance, assignment or other instrument as an assignor, grantor, sublessor or in another capacity or (B) has breached any obligation under any Lease that would (i) result in Assignee's being entitled to receive less than the net revenue interest for any Lease, well or unit set forth in Exhibit 1 of all oil and gas in, under, and that may be produced, saved and marketed from or attributable to such Lease, well or unit, or (ii) obligate Assignee to bear the costs and expenses relating to the maintenance, development and operation of such Lease, well or unit in an amount greater than the working interest for such Lease, well or unit set forth in Exhibit 1, unless the net revenue interest attributable to said working interest is increased by a proportionate or greater amount; and b. Except as specifically set forth in the Purchase and Sale Agreement described in Article 10. below or under the contracts and agreements listed in Exhibit 1 to this Assignment, the Assets are free of all liens, security interests and encumbrances; (the limited warranty set forth in subparagraphs (a) and (b) above shall hereinafter be referred to as the Special Limited Warranty ). Assignor shall convey the Assets with no warranty whatsoever other than the Special Limited Warranty, but with full substitution and subrogation to Assignee in and to all covenants, agreements, representations and warranties made by others heretofore given or made in connection with the Assets or any part thereof.

  • EXCLUSIONS FROM WARRANTY This warranty does not cover problems caused by your acts (or failures to act), the acts of others, or events beyond Microsoft’s reasonable control.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!