Reimbursement of Expenses Associated with Security Breach In the event of a Security Breach that is attributable to the Provider, the Provider shall reimburse and indemnify the LEA for any and all costs and expenses that the LEA incurs in investigating and remediating the Security Breach, without regard to any limitation of liability provision otherwise agreed to between Provider and LEA, including but not limited to costs and expenses associated with: a. Providing notification to the parents of those students whose Student Data was compromised and regulatory agencies or other entities as required by law or contract; b. Providing credit monitoring to those students whose Student Data was exposed in a manner during the Security Breach that a reasonable person would believe may impact the student's credit or financial security; c. Legal fees, audit costs, fines, and any other fees or damages imposed against the LEA as a result of the security breach; and d. Providing any other notifications or fulfilling any other requirements adopted by the Illinois State Board of Education or under other State or federal laws.
Legal Fees Associated with Indemnification With respect to any indemnification provisions in this Agreement providing that a party to this Agreement is required to indemnify another party to this Agreement for attorney’s fees and expenses, such fees and expenses are intended to include attorney’s fees and expenses relating to the enforcement of such indemnity.
Data shared with Subcontractors If DSHS Data provided under this Contract is to be shared with a subcontractor, the Contract with the subcontractor must include all of the data security provisions within this Contract and within any amendments, attachments, or exhibits within this Contract. If the Contractor cannot protect the Data as articulated within this Contract, then the contract with the sub- Contractor must be submitted to the DSHS Contact specified for this contract for review and approval.
Attachment A, Scope of Services The scope of services is amended as follows:
Contractor Certification for Contractor Employees Introduction Texas Education Code Chapter 22 requires entities that contract with school districts to provide services to obtain criminal history record information regarding covered employees. Contractors must certify to the district that they have complied. Covered employees with disqualifying criminal histories are prohibited from serving at a school district. Definitions: Covered employees: Employees of a contractor or subcontractor who have or will have continuing duties related to the service to be performed at the District and have or will have direct contact with students. The District will be the final arbiter of what constitutes direct contact with students. Disqualifying criminal history: Any conviction or other criminal history information designated by the District, or one of the following offenses, if at the time of the offense, the victim was under 18 or enrolled in a public school: (a) a felony offense under Title 5, Texas Penal Code; (b) an offense for which a defendant is required to register as a sex offender under Chapter 62, Texas Code of Criminal Procedure; or (c) an equivalent offense under federal law or the laws of another state. I certify that: NONE (Section A) of the employees of Contractor and any subcontractors are covered employees, as defined above. If this box is checked, I further certify that Contractor has taken precautions or imposed conditions to ensure that the employees of Contractor and any subcontractor will not become covered employees. Contractor will maintain these precautions or conditions throughout the time the contracted services are provided. OR SOME (Section B) or all of the employees of Contractor and any subcontractor are covered employees. If this box is checked, I further certify that: (1) Contractor has obtained all required criminal history record information regarding its covered employees. None of the covered employees has a disqualifying criminal history.
Certification as Small Contractor or Minority Business Enterprise This paragraph was intentionally left blank.
Change in Scope of Work Any change in the scope of the Work, method of performance, nature of materials or price thereof, or any other matter materially affecting the performance or nature of the Work shall not be paid for or accepted unless such change, addition, or deletion is approved in advance and in writing by a valid change order executed by the District. Contractor specifically understands, acknowledges, and agrees that the District shall have the right to request any alterations, deviations, reductions, or additions to the Project or Work, and the cost thereof shall be added to or deducted from the amount of the Contract Price by fair and reasonable valuations. Contractor also agrees to provide the District with all information requested to substantiate the cost of the change order and to inform the District whether the Work will be done by the Contractor or a subcontractor. In addition to any other information requested, Contractor shall submit, prior to approval of the change order, its request for a time extension (if any), as well as all information necessary to substantiate its belief that such change will delay the completion of the Work. If Contractor fails to submit its request for a time extension or the necessary supporting information, it shall be deemed to have waived its right to request such extension.
Vendor Encouraging Members to bypass TIPS agreement Encouraging entities to purchase directly from the Vendor or through another agreement, when the Member has requested using the TIPS cooperative Agreement or price, and thereby bypassing the TIPS Agreement is a violation of the terms and conditions of this Agreement and will result in removal of the Vendor from the TIPS Program.
Reverse ADSL Loops If a CLEC’s ADSL Transmission Unit (including those integrated into DSLAMs) is attached to Sprint’s Network and if an ADSL Copper Loop should start at an outside location, and is looped through a host or remote, and then to the subscriber, the copper plant from the outside location to the Sprint host or remote central office must be a facility dedicated to ADSL transmission only and not part of Sprint’s regular feeder or distribution plant.
Procedures for Providing NP Through Full NXX Code Migration Where a Party has activated an entire NXX for a single Customer, or activated at least eighty percent (80%) of an NXX for a single Customer, with the remaining numbers in that NXX either reserved for future use by that Customer or otherwise unused, if such Customer chooses to receive Telephone Exchange Service from the other Party, the first Party shall cooperate with the second Party to have the entire NXX reassigned in the LERG (and associated industry databases, routing tables, etc.) to an End Office operated by the second Party. Such transfer will be accomplished with appropriate coordination between the Parties and subject to appropriate industry lead times for movements of NXXs from one switch to another. Neither Party shall charge the other in connection with this coordinated transfer.
