Payment Claims Subject to clause 11.3, the Contractor must give the PDS Contractor claims for payment on account of the Contract Price and all other amounts then payable by the Commonwealth to the Contractor under the Contract: at the times specified in the Contract Particulars until Completion or termination of the Contract (whichever is earlier); unless terminated earlier: after Completion, within 28 days (or such longer period agreed in writing by the PDS Contractor) after the issue of a Completion certificate under clause 13.1; and after the Defects Liability Period, within the time required by clause 11.9; in the format set out in the Schedule of Collateral Documents or in any other format which the PDS Contractor reasonably requires; which are based on the Table of Variation Rates and Prices or the Schedule of Rates to the extent these are relevant; which show separately the amounts (if any) claimed on account of the: Contract Price; and all other amounts then payable by the Commonwealth to the Contractor under the Contract; and which set out or attach sufficient details, calculations, supporting documentation and other information in respect of all amounts claimed by the Contractor: to enable the PDS Contractor to fully and accurately determine (without needing to refer to any other documentation or information) the amounts then payable by the Commonwealth to the Contractor under the Contract; and including any such documentation or information which the PDS Contractor may by written notice from time to time require the Contractor to set out or attach, whether in relation to a specific payment claim or all payment claims generally.
Initial Claim Post-Service Claims must be submitted to AvMed within 90 days from the date of service or within one year unless the Member was legally incapacitated; otherwise the Claim will be considered to have been waived.
Excluded Claims Notwithstanding the foregoing, the following are not included in the Released Claims (the “Excluded Claims”): (i) any rights or claims for indemnification you may have pursuant to any written indemnification agreement with the Company to which you are a party, the charter, bylaws, or operating agreements of the Company, or under applicable law; (ii) any rights which are not waivable as a matter of law; and (iii) any claims for breach of this Agreement. In addition, nothing in this Agreement prevents you from filing, cooperating with, or participating in any proceeding before the Equal Employment Opportunity Commission, the Department of Labor, or any other government agency, except that you acknowledge and agree that you are hereby waiving your right to any monetary benefits in connection with any such claim, charge or proceeding. You hereby represent and warrant that, other than the Excluded Claims, you are not aware of any claims you have or might have against any of the Released Parties that are not included in the Released Claims.
Third Party Claim A Claim where there is (a) a claim, demand, suit or action by a person who is not a Party, (b) a settlement with, judgment by, or liability to, a person who is not a Party, or (c) a fine or penalty imposed by a person who is not a Party.
Infringement Claims You may submit an infringement claim notice to us at our Contact Formavailable here if you have a good faith belief that Your Content has been copied and made accessible through the Services (including as a part of the Service Content or Third Party Content) in violation of your Inte lectual Property Rights. A copyright infringement claims notice must include at (i) the identification of such a legedly infringing materials, including information su ficient for us to locate it within our Services, ( i) a demand that such a legedly infringing materials be removed or access disabled, ( i) a statement that you have a good faith belief that use of the material in the manner complained of is not authorized by the copyright owner, its agent, or the law; (iv) a statement that the information in the notification is accurate, and under penalty of perjury, that you are authorized to act on behalf of the owner of an exclusive right that is a legedly infringed; (v) contact information for you, such as address, phone number, and, if available, an email address; and (vi) must be signed by you or the person authorized to act on behalf of the owner of the a legedly infringed work (the “Notice Requirements”). Pursuant to 17 U.S.C. 512(c)(3), if the above Notice Requirements are not met, we may disregard the notice. Pursuant 17 U.S.C. 512(f), be advised that knowingly making a material misrepresentation that online material or activity is infringing or that material or activity was removed or disabled by mistake or misidentification, may subject you to heavy civil penalties. These penalties include monetary damages, including costs and attorneys' fees, incurred by the a leged infringer, by any copyright owner or copyright owner's authorized licensee, or by a service provider who is injured by your misrepresentation. If we make a decision to remove Your Content in response to a complaint, we may notify you and provide you with contact information for the complaining party. You may also object to such determination by writing to our designated agent, which must contain the fo lowing information pursuant to 17 U.S.C. 512(g)(3), (i) your physical or electronic signature; ( i) identification of the material that has been removed or to which access has been disabled and the location at which the material appeared before it was removed or access to it was disabled; ( i) a statement under penalty of perjury that the you have a good faith belief that the material was removed or disabled as a result of mistake or misidentification of the material to be removed or disabled; and (iv) your name, address, phone number, and a statement that you consent to the jurisdiction of Federal District Court for the judicial district in which the address is located, or if you are located outside of the United States, for any judicial district in which the service provider may be found, and that you wil accept service of process from the person who provided notification under subsection 17 U.S.C. 512(c)(1)(C) or an agent of such person.
Notice and contest of claims In the event that either Party receives a claim or demand from a third party in respect of which it is entitled to the benefit of an indemnity under this Article 38 (the "Indemnified Party") it shall notify the other Party (the "Indemnifying Party") within 15 (fifteen) days of receipt of the claim or demand and shall not settle or pay the claim without the prior approval of the Indemnifying Party, which approval shall not be unreasonably withheld or delayed. In the event that the Indemnifying Party wishes to contest or dispute the claim or demand, it may conduct the proceedings in the name of the Indemnified Party, subject to the Indemnified Party being secured against any costs involved, to its reasonable satisfaction.
Direct Claims Any Action by an Indemnified Party on account of a Loss which does not result from a Third Party Claim (a “Direct Claim”) shall be asserted by the Indemnified Party giving the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than 30 days after the Indemnified Party becomes aware of such Direct Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Direct Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have 30 days after its receipt of such notice to respond in writing to such Direct Claim. The Indemnified Party shall allow the Indemnifying Party and its professional advisors to investigate the matter or circumstance alleged to give rise to the Direct Claim, and whether and to what extent any amount is payable in respect of the Direct Claim and the Indemnified Party shall assist the Indemnifying Party’s investigation by giving such information and assistance (including access to the Company’s premises and personnel and the right to examine and copy any accounts, documents or records) as the Indemnifying Party or any of its professional advisors may reasonably request. If the Indemnifying Party does not so respond within such 30 day period, the Indemnifying Party shall be deemed to have rejected such claim, in which case the Indemnified Party shall be free to pursue such remedies as may be available to the Indemnified Party on the terms and subject to the provisions of this Agreement.
Claims Payment The Reinsurer will be liable to the Company for its share of the benefits owed under the express contractual terms of the Reinsured Policies and as specified under the terms of this Agreement. The Reinsurer will not participate in any ex gratia payments made by the Company (i.e., payments the Company is not required to make under the Reinsured Policy terms.) The payment of death benefits by the Reinsurer will be in one lump sum regardless of the mode of settlement under the Reinsured Policy. Benefit payments from the Reinsurer will be due within 30 days of the claim satisfying the requirements established under this Agreement. The Reinsurer’s share of any interest payable under the terms of a Reinsured Policy or applicable law which is based on the death benefits paid by the Company, will be payable provided that the Reinsurer will not be liable for interest accruing on or after the date of the Company’s payment of benefits. The Reinsurer will make payment to the Company for each such claim. For Waiver of Premium claims, the Company will continue to pay premiums for reinsurance, except premiums for disability reinsurance. The Reinsurer will pay its proportionate share of the gross premium waived by the Company on the Reinsured Policy, including its share of the premiums for benefits that remain in effect during disability. For claims on Accelerated Benefit riders reinsured under this Agreement, the benefit amount payable by the Reinsurer will be calculated by multiplying the total accelerated death benefit rider payout by the ratio of the reinsured Net Amount at Risk, as defined in Exhibit C-1, to the face amount of the Reinsured Policy.
Claim A demand or assertion by the Owner or the Contractor seeking an adjustment of the Contract Sum or Contract Time, or both, or other relief with respect to the terms of the Contract. The term "Claim" also includes other disputes and matters in question between the Owner and the Contractor arising out of or relating to the Contract. The responsibility to substantiate a Claim shall rest with the party making the Claim. A demand for money or services by a third party, including a Trade Contractor, Supplier, or subcontractor to the Contractor, is ipso facto not a Claim against the Owner.
Indemnification Claims (a) In the event that any of the Parties are entitled, or seek to assert rights, to indemnification under this Article VI, the Party or Parties seeking indemnification (the “Indemnified Parties”) shall give written notification to the other Party or Parties (the “Indemnifying Parties”) of the commencement of any suit or proceeding relating to a third party claim for which indemnification pursuant to this Article VI may be sought. Such notification shall be given within 20 Business Days after receipt by the Indemnified Parties of notice of such suit or proceeding, and shall describe in reasonable detail (to the extent known by the Indemnified Parties) the facts constituting the basis for such suit or proceeding and the amount of the claimed damages; provided, however, that no delay on the part of the Indemnified Parties in notifying the Indemnifying Parties shall relieve the Indemnifying Parties of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Parties may, upon written notice thereof to the Indemnified Parties seeking indemnification, assume control of the defense of such suit or proceeding with counsel reasonably satisfactory to the Indemnified Party seeking indemnification; provided that the Indemnifying Parties may not assume control of the defense of a suit or proceeding involving criminal liability or in which equitable relief is sought against the Indemnified Party seeking indemnification. If the Indemnifying Parties do not so assume control of such defense, the Indemnified Parties seeking indemnification shall control such defense. The Party not controlling such defense (the “Non-Controlling Party”) may participate therein at its own expense; provided that if the Indemnifying Parties assumes control of such defense and the Indemnified Parties seeking indemnification reasonably concludes that the Indemnifying Parties and the Indemnified Parties seeking indemnification have conflicting interests or different defenses available with respect to such suit or proceeding, the reasonable fees and expenses of counsel to the Indemnified Parties shall be considered “Damages” for purposes of this Agreement. The Party or Parties controlling such defense (the “Controlling Party”) shall keep the Non-Controlling Party advised of the status of such suit or proceeding and the defense thereof and shall consider in good faith recommendations made by the Non-Controlling Party with respect thereto. The Non-Controlling Party shall furnish the Controlling Party with such information as it may have with respect to such suit or proceeding (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party as reasonably needed in the defense of such suit or proceeding at the sole cost and expense of the Indemnifying Parties under Section 6.1 or 6.2, which cost and expense shall be considered “Damages” for purposes of this Agreement. The Indemnifying Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnified Parties, which shall not be unreasonably withheld or delayed; provided that the consent of the Indemnified Parties shall not be required if the Indemnifying Parties agrees in writing to pay any amounts payable pursuant to such settlement or judgment and such settlement or judgment includes a complete release of the Indemnified Parties from further liability and has no other materially adverse effect on the Indemnified Parties. The Indemnified Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnifying Parties, which shall not be unreasonably withheld or delayed.
