Damages for delay by the Operator Sample Clauses

Damages for delay by the Operator. In the event that (i) the Operator does not procure fulfilment or waiver of any or all of the Conditions Precedent set forth in Clause 4.1.3 within the period specified in that Clause, and
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Damages for delay by the Operator. 4.5.1 In the event that (i) the Operator does not procure fulfilment of any or all of the Transition Period Conditions set forth in Article 4.3 within the period specified in respect thereof, and (ii) the delay has not occurred as a result of failure to fulfil the obligations under Article or other breach of this Agreement by the Authority, or due to Force Majeure, the Operator shall pay to the Authority Damages in an amount calculated at the rate of 0.10% (zero point one percent) of the Start Up Period Performance Security for each day’s delay until the fulfilment of such Transition Period Conditions. Provided, however, that the Damages payable hereunder shall be subject to the maximum limit equal to 20% of the aggregate amount of the Start Up Period Performance Security and upon reaching such limit, the Authority may, in its sole discretion may terminate the Agreement due to Operator Event of Default. 4.5.2 In the event of delay solely due to delay by the Authority in procuring fulfilment of the Transition Period Conditions specified in Article 4.3 no Damages shall be due or payable by the Operator under this Article 4.5 until the date on which the Authority shall have procured fulfilment of the Transition Period Conditions specified in Article 4.3.
Sample 1Sample 2Sample 3
Damages for delay by the Operator. 4.2.1 In the event that: (a) the Operator does not procure fulfilment or waiver of any or all of the Conditions Precedent set forth in Article 4.1.3 within the period specified in that Article, and (b) the delay has not occurred as a result of failure to fulfil the obligations by the Authority under Article 4.1.2 or other breach of this Contract by the Authority or due to Force Majeure; the Operator shall pay to the Authority, Damages in an amount calculated at the rate of Rs. 5,000/- (Rupees Five Thousand) for each day of delay until the fulfilment of such Conditions Precedent, subject to a maximum amount equal to 10% (ten percent) of the Contract Performance Security, and upon reaching such maximum, the Authority may, in its sole discretion and subject to the provisions of Article 10.3, terminate the Contract. 4.2.2 In the event of delay by the Authority in procuring fulfilment of the Conditions Precedent specified in Article 4.1.2 having a direct impact on the fulfilment of any the Conditions Precedent to be fulfilled by the Operator under Article 4.1.3, no Damages shall be due or payable by the Operator under this Article 4.2 until the date on which the Authority shall have procured fulfilment of its such Condition Precedent. The payment of Damages pursuant to this Article 4.2 is independent of the Operator’s obligations under any other provision of this Contract.
Sample 1Sample 2
Damages for delay by the Operator. In the event that i. the Operator does not procure fulfillment or waiver of any or all of the Conditions Precedent set forth in Clause 4.1.3 within the period specified in that Clause, and ii. the delay has not occurred as a result of breach of this Agreement by the Authority or due to Force Majeure, the Operator shall pay to the Authority Damages in an amount calculated at the rate of 0.1% (zero point one per cent) of the Performance Security for each day’s delay until the fulfillment of such Conditions Precedent, subject to a maximum amount equal to the Bid Security, and upon reaching such maximum, the Authority may, in its sole discretion and subject to the provisions of Clause 9.2, terminate the Agreement. Provided that in the event of delay by the Authority in procuring fulfillment of the Condition Precedent specified in Clause 4.1.2, no Damages shall be due or payable by the Operator under this Clause 4.3 until the date on which the Authority shall have procured fulfillment of the Conditions Precedent specified in Clause 4.1.2.
Sample 1

Related to Damages for delay by the Operator

  • Damages for delay Subject to the provisions of Clause 12.4, if COD does not occur prior to the 91st day after the Scheduled Completion Date, unless the delay is on account of reasons solely attributable to the Authority or due to Force Majeure, the Concessionaire shall pay Damages to the Authority in a sum calculated at the rate of 0.1% (zero point one per cent) of the amount of Performance Security for delay of each day until COD is achieved.

  • No Damages for Delay The Contractor has no claim for monetary damages for delay or hindrances to the Work from any cause, including without limitation any act or omission of the Owner.

  • Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.

  • Liquidated Damages for Delay In addition to the Contractor bearing the actual cost of correcting any non-compliant work or any other actual damages resulting from Contractor’s breach of this Agreement, the Contractor agrees to pay the Contractor delay damages in the amount of $500.00 per day for every day that the goods and/or services to be provided pursuant to this Agreement have not been timely delivered to the District in compliance with the Scope of Services set forth above, unless the delay has been properly excused by the terms of this Agreement. The parties agree that the District’s actual damages for delay are difficult to estimate and that this $500.00 per day sum is a reasonable pre-estimate of the District’s actual damages for each day of delay and that the is $500.00 per day sum is intended by the parties to be in the nature of liquidated damages, not a penalty. It is not the parties’ intent for this provision to limit either party’s remedies against the other for the breach of this Agreement, except for the District’s money damages for unexcused delays caused by the Contractor.

  • Prevention or Delay of Performance by the Company or the Depositary Neither the Depositary nor the Company nor any of their respective directors, employees, agents or affiliates shall incur any liability to any Owner or Holder: (i) if by reason of (A) any provision of any present or future law or regulation or other act of the government of the United States, any State of the United States or any other state or jurisdiction, or of any governmental or regulatory authority or stock exchange; (B) (in the case of the Depositary only) any provision, present or future, of the articles of association or similar document of the Company, or any provision of any securities issued or distributed by the Company, or any offering or distribution thereof; or (C) any event or circumstance, whether natural or caused by a person or persons, that is beyond the ability of the Depositary or the Company, as the case may be, to prevent or counteract by reasonable care or effort (including, but not limited to, earthquakes, floods, severe storms, fires, explosions, war, terrorism, civil unrest, labor disputes, criminal acts or outbreaks of infectious disease; interruptions or malfunctions of utility services, Internet or other communications lines or systems; unauthorized access to or attacks on computer systems or websites; or other failures or malfunctions of computer hardware or software or other systems or equipment), the Depositary or the Company is, directly or indirectly, prevented from, forbidden to or delayed in, or could be subject to any civil or criminal penalty on account of doing or performing and therefore does not do or perform, any act or thing that, by the terms of this Deposit Agreement or the Deposited Securities, it is provided shall be done or performed; (ii) for any exercise of, or failure to exercise, any discretion provided for in this Deposit Agreement (including any determination by the Depositary to take, or not take, any action that this Deposit Agreement provides the Depositary may take); (iii) for the inability of any Owner or Holder to benefit from any distribution, offering, right or other benefit that is made available to holders of Deposited Securities but is not, under the terms of this Deposit Agreement, made available to Owners or Holders; or (iv) for any special, consequential or punitive damages for any breach of the terms of this Deposit Agreement. Where, by the terms of a distribution to which Section 4.1, 4.2 or 4.3 applies, or an offering to which Section 4.4 applies, or for any other reason, that distribution or offering may not be made available to Owners, and the Depositary may not dispose of that distribution or offering on behalf of Owners and make the net proceeds available to Owners, then the Depositary shall not make that distribution or offering available to Owners, and shall allow any rights, if applicable, to lapse.

  • Partial Terminations by the Purchasers In the event so instructed by the Purchasers in writing after the Closing Date and at the Purchasers’ sole expense, each Seller shall execute documents prepared by the Purchasers and reasonably acceptable to such Seller resigning or appointing a successor Appointed Trustee under any Serviced Appointment for which such Seller acts as Appointed Trustee (other than with respect to any Serviced Appointment that is an Excluded Appointment), and shall reasonably cooperate, at the Purchasers’ sole expense, as instructed by the Purchasers, in finding a qualified successor Appointed Trustee, including executing any documents prepared by the Purchasers in connection with the application to a court of competent jurisdiction to appoint a successor Appointed Trustee.

  • TERMINATION BY THE CONTRACTOR If the Work is stopped for a period of thirty days under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing any of the Work under a contract with the Contractor, or if the Work should be stopped for a period of thirty days by the Contractor because the Architect has not issued a Certificate for Payment as provided in Paragraph 9.7 of these General Conditions or because the State has not made payment thereon as provided in Paragraph 9.7, then the Contractor may, upon seven additional days written notice to the State and the Architect, terminate the Contract and recover from the State payment for all Work executed and for any proven loss sustained upon any materials, equipment, tools, construction equipment and machinery, including reasonable profit and damages.

  • Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

  • Indemnification by the Manager The Trust shall not be responsible for, and the Manager shall indemnify and hold the Trust or any Fund harmless from and against, any and all losses, damages, costs, charges, counsel fees, payments, expenses and liability arising out of or attributable to the willful misfeasance, bad faith, negligent acts or reckless disregard of obligations or duties on the part of the Manager or any of its officers, directors, employees or agents.

  • Prevention or Delay in Performance by the Depositary or the Company Neither the Depositary nor the Company nor any of their respective directors, employees, agents or affiliates shall incur any liability to any Owner or Holder (i) if by reason of any provision of any present or future law or regulation of the United States or any other country, or of any governmental or regulatory authority or stock exchange, or by reason of any provision, present or future, of the articles of association or similar document of the Company, or by reason of any provision of any securities issued or distributed by the Company, or any offering or distribution thereof, or by reason of any act of God or war or terrorism or other circumstances beyond its control, the Depositary or the Company shall be prevented, delayed or forbidden from, or be subject to any civil or criminal penalty on account of, doing or performing any act or thing which by the terms of this Deposit Agreement or the Deposited Securities it is provided shall be done or performed, (ii) by reason of any non-performance or delay, caused as aforesaid, in the performance of any act or thing which by the terms of this Deposit Agreement it is provided shall or may be done or performed, (iii) by reason of any exercise of, or failure to exercise, any discretion provided for in this Deposit Agreement, (iv) for the inability of any Owner or holder to benefit from any distribution, offering, right or other benefit which is made available to holders of Deposited Securities but is not, under the terms of this Deposit Agreement, made available to Owners or holders, or (v) for any special, consequential or punitive damages for any breach of the terms of this Deposit Agreement. Where, by the terms of a distribution pursuant to Section 4.01, 4.02 or 4.03, or an offering or distribution pursuant to Section 4.04, or for any other reason, such distribution or offering may not be made available to Owners, and the Depositary may not dispose of such distribution or offering on behalf of such Owners and make the net proceeds available to such Owners, then the Depositary shall not make such distribution or offering, and shall allow any rights, if applicable, to lapse.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!