Decisions of the Board The decision of the majority shall be the decision of the Board. Where there is no majority decision, the decision of the Chairperson shall be the decision of the Board. The decision of the Board of Arbitration shall be final and binding and enforceable on all parties, but in no event shall the Board of Arbitration have the power to change this Agreement or to alter, modify or amend any of its provisions. However, the Board shall have the power to dispose of any discharge or a discipline grievance by any arrangement which in its opinion it deems just and equitable.
Provisions of the Agreement a reference to any Clause or Schedule is, except where it is expressly stated to the contrary, a reference to such clause of, or schedule to, this Agreement. A reference in a Schedule to any paragraph is, except where it is expressly stated to the contrary, a reference to a paragraph in that Schedule;
Obligations of the Academy Trust 4.B The Academy Trust must keep the Land clean and tidy and make good any damage or deterioration to the Land. The Academy Trust must not do anything to lessen the value or marketability of the Land without the Secretary of State’s consent.
Extensions of Time 34.1 If at any time during performance of the Contract, the Supplier or its subcontractors should encounter conditions impeding timely delivery of the Goods or completion of Related Services pursuant to GCC Clause 13, the Supplier shall promptly notify the Procuring Entity in writing of the delay, its likely duration, and its cause. As soon as practicable after receipt of the Supplier's notice, the Procuring Entity shall evaluate the situation and may at its discretion extend the Supplier's time for performance, in which case the extension shall be ratified by the parties by amendment of the Contract.
DELAYS AND EXTENSIONS OF TIME 8.3.1 If the Contractor is delayed at any time in the progress of the Work by any act or failure to act by the State or the Architect, or by any employee of either, or by any separate contractor employed by the State, or by changes ordered in the Work, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, or any causes beyond the Contractor's control, or by delay authorized by the State pending alternative dispute resolution proceedings, or by any other cause which may justify the delay, then the Contract Time shall be extended by Change Order for such reasonable time as recommended by the Architect and approved by the State.
Judicial Council 's Obligation Subject to Availability of Funds A. The Judicial Council's obligation under this Agreement is subject to the availability of authorized funds. The Judicial Council may terminate the Agreement or any part of the Contract Work, without prejudice to any right or remedy of the Judicial Council, for lack of appropriation of funds. If expected or actual funding is withdrawn, reduced, or limited in any way prior to the expiration date set forth in this Agreement, or in any Amendment hereto, the Judicial Council may, upon written Notice to the Contractor, terminate this Agreement in whole or in part. Such termination shall be in addition to the Judicial Council's rights to terminate for cause or other than for cause, as set forth herein.
Representations of the Parties Each party hereto hereby further represents and warrants to the other that: (i) it is registered as an investment adviser under the Advisers Act and is registered or licensed as an investment adviser under the laws of all jurisdictions in which its activities require it to be so registered or licensed; and (ii) it will use its reasonable best efforts to maintain each such registration or license in effect at all times during the term of this Agreement; and (iii) it will promptly notify the other if it ceases to be so registered, if its registration is suspended for any reason, or if it is notified by any regulatory organization or court of competent jurisdiction that it should show cause why its registration should not be suspended or terminated; and (iv) it is duly authorized to enter into this Agreement and to perform its obligations hereunder. The Sub-Adviser further represents that it has adopted a written Code of Ethics in compliance with Rule 17j-1(b) of the ICA. The Sub-Adviser shall be subject to such Code of Ethics and shall not be subject to any other Code of Ethics, including the Investment Manager's Code of Ethics, unless specifically adopted by the Sub-Adviser. The Investment Manager further represents and warrants to the Sub-Adviser that (i) the appointment of the Sub-Adviser by the Investment Manager has been duly authorized and (ii) it has acted and will continue to act in connection with the transactions contemplated hereby, and the transactions contemplated hereby are, in conformity with the ICA, the Company's governing documents and other applicable law.
Obligations of the Department a. The Department shall notify Business Associate of a) any limitation in any applicable Notice of Privacy Practices that would affect the use or disclosure of PHI by the Business Associate and b) any changes, revocations, restrictions or permissions by an individual to the use and disclosure of his/her PHI to which the Department has agreed, to the extent such restrictions or limitations may affect the performance of Business Associate’s services on behalf of the Department.
Conditions to Obligations of the Company The Company’s obligation to sell and issue the Shares and the Warrants at the Closing is subject to the fulfillment to the satisfaction of the Company on or prior to the Closing Date of the following conditions, any of which may be waived by the Company:
Obligations of the Authority 6.1.1 The Authority shall, at its own cost and expense undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder.
