Defective work, default and breach of Contract Sample Clauses

Defective work, default and breach of Contract. 27.1.1. The Principal‟s Representative or the Project Manager may reject any work or materials not in accordance with this Contract. 27.1.2. If, before the issue of a Certificate of Practical Completion, the Principal‟s Representative or the Project Manager notifies the Contractor: a. that any work performed or material used is defective or does not conform to the Contractor Documents; and b. that the Contractor has failed to remedy any defect in the Works, the Contractor shall be bound to forthwith remedy any such default. 27.1.3. If the Contractor fails to remedy any default as described in clause 27.1.2, the Principal may employ or pay other persons to remedy the default and complete the Works as it considers necessary without prejudice to any other rights or remedies the Principal may have against the Contractor. 27.1.4. If the Principal does employ or pay such other persons to remedy the default and complete the Works, the Contractor's engagement under this Contract is terminated and the Principal may cause the Contractor and its equipment and other goods to be removed from the Site. 27.1.5. All costs and charges incurred as a result of, or incidental to, such new appointment and the Works to be carried out thereunder may be deducted from moneys otherwise due to the Contractor. 27.1.6. Where such costs and charges exceed the amount due to the Contractor, the balance shall become a debt due to the Principal from the Contractor. 27.1.7. If, during the term of this Contract, the Contractor becomes subject to a form of external administration under Chapter 5 of the Corporations Xxx 0000 (Cth): a. the Principal may immediately terminate this Contract and engage another contractor to complete the Works; b. the Principal shall be under no liability to make any further payment to the Contractor and may prove in any liquidation for any loss and damage consequent upon the engagement of another contractor; and c. ownership of the Contractor's materials on the Site shall vest in the Principal who may deal with them as it sees fit. 27.1.8. In the event of the termination of this Contract by the Principal pursuant to this clause, the Contractor shall have no further rights or claims against the Principal under or by virtue of this Contract.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs

Related to Defective work, default and breach of Contract

  • Customer Default The occurrence at any time of any of the following events shall constitute a “Customer Default”:

  • Material Breach of Contract In the event Contractor fails to deliver the product and services as contracted for herein, to the satisfaction of the City of Sparks or otherwise fails to perform any provisions of this Contract, the City, after providing five (5) days written notice and Contractor’s failure to cure such breach within the time specified in the notice, may without waiving any other remedy, make good the deficiencies and deduct the actual cost of providing alternative products and/or services from payment due the Contractor. Non-performance after the first notice of non-performance shall be considered a material breach of contract.

  • Default Breach Remedies See Addendum 13.1

  • BREACH OF CONTRACT TERMS The State reserves its right to all administrative, contractual, or legal remedies, including but not limited to suspension or termination of this contract, in instances where the Contractor or any of its subcontractors violate or breach any contract term. If the Contractor or any of its subcontractors violate or breach any contract term, they shall be subject to such sanctions and penalties as may be appropriate. The duties and obligations imposed by the contract documents and the rights and remedies available thereunder shall be in addition to and not a limitation of any duties, obligations, rights and remedies otherwise imposed or available by law.

  • Default by Contractor To the maximum extent permitted by applicable law, failure to comply with any of the terms and/or conditions of this Contract, including these General Conditions, shall constitute default by Contractor and grounds for termination of this Contract. Contractor shall be liable for any and all damages suffered by District due to the failure by Contractor or Contractor’s subcontractor(s) to comply with this Contract.

  • Default; Breach A “Default” is defined as a failure by the Lessee to comply with or perform any of the terms, covenants, conditions or Rules and Regulations under this Lease. A “Breach” is defined as the occurrence of one or more of the following Defaults, and the failure of Lessee to cure such Default within any applicable grace period:

  • Breach of Contract The failure of the Contractor to comply with any of the provisions, covenants or conditions of this Contract shall be a material breach of this Contract. In such event the County may, and in addition to any other remedies available at law, in equity, or otherwise specified in this Contract: a) Terminate the Contract immediately, pursuant to Section K herein; b) Afford the Contractor written notice of the breach and ten (10) calendar days or such shorter time that may be specified in this Contract within which to cure the breach; c) Discontinue payment to the Contactor for and during the period in which the Contractor is in breach; and d) Offset against any monies billed by the Contractor but yet unpaid by the County those monies disallowed pursuant to the above.

  • NO BREACH OF CONTRACT The Executive hereby represents to the Company that: (i) the execution and delivery of this Agreement by the Executive and the performance by the Executive of the Executive’s duties hereunder shall not constitute a breach of, or otherwise contravene, the terms of any other agreement or policy to which the Executive is a party or otherwise bound, except for agreements entered into by and between the Executive and any member of the Group pursuant to applicable law, if any; (ii) that the Executive has no information (including, without limitation, confidential information and trade secrets) relating to any other person or entity which would prevent, or be violated by, the Executive entering into this Agreement or carrying out his duties hereunder; (iii) that the Executive is not bound by any confidentiality, trade secret or similar agreement (other than this) with any other person or entity except for other member(s) of the Group, as the case may be.

  • Contractor Default Failure of the Contractor, which has neither been remedied nor waived, to perform or otherwise to comply with the terms of the Construction Contract.

  • Breach of Contract Claims [Option (Include if University prefers an abbreviated Breach of Contract Claims provision): To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.] 19.1 To the extent that Chapter 2260, Texas Government Code, as it may be amended from time to time (Chapter 2260), is applicable to this Agreement and is not preempted by other Applicable Laws, the dispute resolution process provided for in Chapter 2260 will be used, as further described herein, by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor: 12.19.1.1 Contractor’s claims for breach of this Agreement that the parties cannot resolve pursuant to other provisions of this Agreement or in the ordinary course of business will be submitted to the negotiation process provided in subchapter B of Chapter 2260. To initiate the process, Contractor will submit written notice, as required by subchapter B of Chapter 2260, to University in accordance with the notice provisions in this Agreement. Contractor's notice will specifically state that the provisions of subchapter B of Chapter 2260 are being invoked, the date and nature of the event giving rise to the claim, the specific contract provision that University allegedly breached, the amount of damages Contractor seeks, and the method used to calculate the damages. Compliance by Contractor with subchapter B of Chapter 2260 is a required prerequisite to Contractor's filing of a contested case proceeding under subchapter C of Chapter 2260. The chief business officer of University, or another officer of University as may be designated from time to time by University by written notice to Contractor in accordance with the notice provisions in this Agreement, will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. 12.19.1.2 If the parties are unable to resolve their disputes under Section 12.19.1.1, the contested case process provided in subchapter C of Chapter 2260 is Contractor’s sole and exclusive process for seeking a remedy for any and all of Contractor's claims for breach of this Agreement by University. 12.19.1.3 Compliance with the contested case process provided in subchapter C of Chapter 2260 is a required prerequisite to seeking consent to xxx from the Legislature under Chapter 107,

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!