Delay in Delivery of Leased Premises Sample Clauses

Delay in Delivery of Leased Premises. If due to reasons attributable to the Landlord or to Unavoidable Delay due to reasons attributable to the Tenant (including any even of Unavoidable Delay attributable to the Tenant), the Leased Premises are not substantially completed as provided in Section 4.2 of the Lease by the Delivery Date and as a result possession of the Leased Premises is given to the Tenant later than the Delivery Date, the Commencement Date of the Lease and termination date, and all other dates and delays stipulated herein will be moved forward by the same number of days as the delay in giving possession. The Tenant shall not be entitled to any damages or indemnity whatsoever resulting from such delay and agrees to accept any such extension as full and final settlement of any and all claims which the Tenant may otherwise have by reason of any delay in delivering possession of the Lease Premises. Any delay in delivering possession of the Leased Premises due to reasons attributable to the Tenant (including any event of Unavoidable Delay attributable to the Tenant), shall not entail extension of the Commencement Date or termination date of the Lease nor entitle the Tenant to any compensation whatsoever.
Sample 1
AutoNDA by SimpleDocs

Related to Delay in Delivery of Leased Premises

  • Acceptance of Leased Premises On or before the Possession Date, Tenant and Landlord shall each execute the letter agreement in the form attached hereto as Exhibit E (the “Letter Agreement”). By its execution of the Letter Agreement or occupancy of the Leased Premises, Tenant shall be deemed to represent and certify that it has examined the Leased Premises and that it thereby accepts the Leased Premises in its condition at the time, except for the list of defects and/or omissions identified in writing prior to the Possession Date (the “Punch-List”) and latent defects, but subject, in all cases, to Landlord’s repair, maintenance and replacement obligations set forth in this Lease and to the warranty related to the Tenant Improvements, as provided in the Work Letter Agreement. After the notice provided in Section 3.03 and prior to the Possession Date, the parties shall meet in the Leased Premises to establish the Punch-List. Landlord shall review the Punch-List items with Tenant and correct all undisputed Punch- List items within a reasonable time, not to exceed thirty (30) days after receipt of the Punch- List; provided that, if any Punch-List items cannot be corrected within such thirty (30) day period despite reasonable diligence by Landlord, then, so long as Landlord commences correction of such Punch-List items within such thirty (30) day period and diligently pursues such correction to completion, no default by Landlord shall be deemed to have occurred. Punch-List items for completion taking longer than six (6) months to complete (and not otherwise the result of Force Majeure, Tenant Delay, or the COVID-19 Condition) shall trigger a day for day prorated Minimum Monthly Rent abatement. The Tenant Improvements shall be subject to a two (2) year warranty, from the Possession Date, with regard to materials, design and workmanship, as provided in more detail in the Work Letter Agreement. Tenant shall reasonably cooperate with Landlord in providing required information as needed for Landlord to pursue vendor warranties on a timely basis, as requested in writing by Landlord. Landlord will pursue any valid warranty claims against its contractor beyond the two (2) year warranty provided that any expenses incurred and/or any recovery obtained shall be treated as either additional Operating Costs or an offset to Operating Costs under Section 5.03(a).

  • Condition of Leased Premises Tenant hereby acknowledges that Xxxxxx has examined the leased premises prior to the signing of this Lease, or knowingly waived said examination. Tenant acknowledges that Tenant has not relied on any representations made by Landlord or Landlord’s agents regarding the condition of the leased premises and that Tenant takes premises in its AS-IS condition with no express or implied warranties or representations beyond those contained herein or required by applicable Georgia law. Xxxxxx agrees not to damage the premises through any act or omission, and to be responsible for any damages sustained through the acts or omissions of Tenant, Xxxxxx’s family or Xxxxxx’s invitees, licensees, and/or guests. If such damages are incurred, Tenant is required to pay for any resulting repairs at the same time and in addition to the next month’s rent payment, with consequences for non-payment identical to those for non- payment of rent described herein. At the expiration or termination of the Lease, Tenant shall return the leased premises in as good condition as when taken by Tenant at the commencement of the lease, with only normal wear-and-tear excepted. Any modification of this lease shall not be binding upon Landlord unless in writing and signed by Landlord or Landlord’s authorized agent. No oral representation shall be effective to modify this Lease. If, as per the terms of this paragraph, any provision of this lease is newly added, modified, or stricken out, the remainder of this Lease shall remain in full force and effect.

  • USE OF LEASED PREMISES The Lessor is leasing the Premises to the Lessee and the Lessee is hereby agreeing to lease the Premises for the following use and purpose: Any change in use or purpose the Premises other than as described above shall be upon prior written consent of Lessor only.

  • Condition of Leased Property Tenant acknowledges receipt and delivery of possession of the Leased Property and Tenant accepts the Leased Property in its “as is” condition, subject to the rights of parties in possession, the existing state of title, including all covenants, conditions, restrictions, reservations, mineral leases, easements and other matters of record or that are visible or apparent on the Leased Property, all applicable Legal Requirements, the lien of any financing instruments, mortgages and deeds of trust existing prior to the Commencement Date or permitted by the terms of this Agreement, and such other matters which would be disclosed by an inspection of the Leased Property and the record title thereto or by an accurate survey thereof. TENANT REPRESENTS THAT IT HAS INSPECTED THE LEASED PROPERTY AND ALL OF THE FOREGOING AND HAS FOUND THE CONDITION THEREOF SATISFACTORY AND IS NOT RELYING ON ANY REPRESENTATION OR WARRANTY OF LANDLORD OR LANDLORD’S AGENTS OR EMPLOYEES WITH RESPECT THERETO AND TENANT WAIVES ANY CLAIM OR ACTION AGAINST LANDLORD IN RESPECT OF THE CONDITION OF THE LEASED PROPERTY. LANDLORD MAKES NO WARRANTY OR REPRESENTATION, EXPRESS OR IMPLIED, IN RESPECT OF THE LEASED PROPERTY OR ANY PART THEREOF, EITHER AS TO ITS FITNESS FOR USE, DESIGN OR CONDITION FOR ANY PARTICULAR USE OR PURPOSE OR OTHERWISE, AS TO THE QUALITY OF THE MATERIAL OR WORKMANSHIP THEREIN, LATENT OR PATENT, IT BEING AGREED THAT ALL SUCH RISKS ARE TO BE BORNE BY TENANT. To the maximum extent permitted by law, however, Landlord hereby assigns to Tenant all of Landlord’s rights to proceed against any predecessor in interest or insurer for breaches of warranties or representations or for latent defects in the Leased Property. Landlord shall fully cooperate with Tenant in the prosecution of any such claims, in Landlord’s or Tenant’s name, all at Tenant’s sole cost and expense. Tenant shall indemnify, defend, and hold harmless Landlord from and against any loss, cost, damage or liability (including reasonable attorneys’ fees) incurred by Landlord in connection with such cooperation.

  • Repair of Damage to Premises by Landlord Tenant shall promptly notify Landlord of any damage to the Premises resulting from fire or any other casualty. If the Premises or any Common Areas serving or providing access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or other matters beyond Landlord's reasonable control, and subject to all other terms of this Article 1 1, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the Base Building and the Common Areas prior to the casualty, except for modifications required by zoning and building codes and other laws or by the holder of a mortgage on the Building or Project or any other modifications to the Common Areas deemed desirable by Landlord, which are consistent with the character of the Project, provided that access to the Premises and any common restrooms serving the Premises shall not be materially impaired. Landlord shall repair any injury or damage to the improvements which exist in the Premises as of the Lease Commencement Date (the "Original Improvements") and shall return such Original Improvements to their original condition. Prior to the commencement of construction, Tenant shall submit to Landlord, for Landlord's review and approval, all plans, specifications and working drawings relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant's business resulting in any way from such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or Common Areas necessary to Tenant's occupancy, and the Premises are not occupied by Tenant as a result thereof, then during the time and to the extent the Premises are unfit for occupancy, the Rent shall be abated in proportion to the ratio that the amount of rentable square feet of the Premises which is unfit for occupancy for the purposes permitted under this Lease bears to the total rentable square feet of the Premises, provided that if the Premises are so damaged that it is not reasonably practicable for Tenant to continue its business operations from any portion of the Premises, then the Rent shall be fully abated during such time.

  • Use of Leased Property Xxxxxx agrees to use the Leased Property only as residence. Xxxxxx agrees to obey all federal, state and local laws and regulations when using the Leased Property. Xxxxxx agrees not to store any flammable or dangerous things in or around the Leased Property. Xxxxxx agrees not to do anything in or around the Leased Property, which could harm anyone or damage any property. Xxxxxx agrees that Tenant will not allow more than one person per bedroom to live in the Leased Property without the written permission of Landlord. The fact that Tenant may have conflict with a roommate will not act as grounds to terminate this Lease. In the event that Xxxxxx is arrested for or charged with any crime (other than a traffic related offense not involving illegal or controlled substances) during the term of the Lease, and/or Landlord is presented with evidence of activities of Tenant which shall constitute a nuisance or a threat to Landlord, other tenants, the Leased Property or the development, Landlord shall have the right to evict Tenant from the Leased Property.

  • Landlord’s Option to Repair Notwithstanding the terms of Section 11.1 of this Lease, Landlord may elect not to rebuild and/or restore the Premises, Building and/or Project, in which event this Lease shall terminate, by notifying Tenant in writing of such termination within sixty (60) days after the date of discovery of the damage, such notice will include a termination date giving Tenant sixty (60) days to vacate the Premises, but this Lease may be so terminated Landlord may so elect only if the Building or Project shall be damaged by fire or other casualty or cause, whether or not the Premises are affected, and one or more of the following conditions is present: (i) in Landlord’s reasonable judgment, repairs cannot reasonably be completed within one hundred eighty (180) days after the date of discovery of the damage (when such repairs are made without the payment of overtime or other premiums); (ii) the holder of any mortgage on the Building or Project or ground lessor with respect to the Building or Project shall require that the insurance proceeds or any portion thereof be used to retire the mortgage debt, or shall terminate the ground lease, as the case may be; (iii) the damage is not fully covered by Landlord’s insurance policies or that portion of the proceeds from Landlord’s insurance policies allocable to the Building or the Project, as the case may be; (iv) Landlord decides to rebuild the Building or Common Areas so that they will be substantially different structurally or architecturally; (v) the damage occurs during the last twelve (12) months of the Lease Term; or (vi) any owner of any other portion of the Project, other than Landlord, does not intend to repair the damage to such portion of the Project; provided, however, that if such fire or other casualty shall have damaged the Premises or a portion thereof or Common Areas necessary to Tenant’s occupancy and as a result of such damage the Premises are unfit for occupancy, and provided that Landlord does not elect to terminate this Lease pursuant to Landlord’s termination right as provided above, and either (a) the repairs cannot, in the reasonable opinion of Landlord’s contractor, be completed within two hundred seventy (270) days after being commenced, or (b) the damage occurs during the last twelve months of the Lease Term and will reasonably require in excess of ninety (90) days to repair, Tenant may elect, no earlier than sixty (60) days after the date of the damage and not later than ninety (90) days after the date of such damage, to terminate this Lease by written notice to Landlord effective as of the date specified in the notice, which date shall not be less than thirty (30) days nor more than sixty (60) days after the date such notice is given by Tenant.

  • DESCRIPTION OF LEASED PREMISES The Lessor agrees to lease to the Lessee the following described square feet (SF) of Additional Description: Hereinafter known as the “Premises”.

  • Subleased Premises Sublandlord hereby subleases to Subtenant and Subtenant hereby subleases from Sublandlord for the term, at the rental, and upon all of the conditions set forth herein, the Subleased Premises.

  • Surrender of Leased Premises 26.1 Tenant shall, at least ninety (90) days before the last day of the term hereof, give to Landlord a written notice of intention to surrender the leased premises on that date, but nothing contained herein shall be construed as an extension of the term hereof or as consent of Landlord to any holding over by Tenant. At the end of the term or any renewal thereof or other sooner termination of this Lease, Tenant will peaceably deliver up to the Landlords possession of the leased premises, together with all improvements or additions upon or belonging to the same, by whosoever made, in substantially the same condition as received, or first installed, ordinary wear and tear and damage by fire, earthquake, act of God or the elements alone excepted. Tenant may, upon the termination of this Lease, remove, at Tenants sole cost, all trade fixtures installed by Tenant, title to which shall be in Tenant until such termination, repairing any damage to the leased caused by such removal. Any of Tenants personal property and trade fixtures not removed by Tenant at the end of the term or other sooner termination of this Lease shall be deemed abandoned by the Tenant if Landlord so elects, and Landlord shall remove, store and disposing of Tenants abandoned personal property and trade fixtures. Tenant shall indemnify Landlord against any loss or liability resulting from delay by Tenant in so surrendering the leased premises, including without limitation, any claims made by any succeeding Tenant founded on such delay.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!