Delay in Remedying Defects Sample Clauses

Delay in Remedying Defects. ‌ If any such Defect or damage is not remedied by Seller within a reasonable time or requires prompt remediation as a result of an emergency situation existing at the Site, Buyer may proceed to do the Work at Seller’s risk and expense provided that it does so in a reasonable manner and notifies Seller of Buyer’s intention so to do. All Costs incurred by Buyer shall be deducted from the Purchase Price or be paid by Seller to Buyer.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Delay in Remedying Defects. If any such error defect damage or failure be not remedied by the Contractor within 14 (fourteen) days from receipt of the notification thereof by the Purchaser or Engineer under Clause 36.2, the Purchaser may proceed to do the work at the Contractor's expense provided that it notifies the Contractor of its intention so to do. The cost reasonably incurred by the Purchaser shall, without prejudice to any other method of recovery be deducted from the Contract Price or be paid by the Contractor to the Purchaser forthwith on demand. Provided, however, that if the Contractor demonstrates to the satisfaction of the Purchaser that the Contractor has made best endeavours (such as placement of orders for replacement materials and equipments in good time) to remedy the defects within the stipulated time and any delay is for causes not entirely controllable by the Contractor (such as replacement material and equipments are not generally available due to general shortage in the market for such materials and equipment), then the Purchaser shall grant a reasonable extension of time to remedy defects to the Contractor
Sample 1Sample 2
Delay in Remedying Defects. If any such Defect or damage is not remedied by Developer within a reasonable time or requires prompt remediation as a result of an emergency situation existing at the Site, then PacifiCorp may proceed to do the Work or have others perform such Work at Developer’s risk and expense provided that it does so in a reasonable manner and notifies Developer of PacifiCorp’s intention so to do. Developer reserves the right to investigate and determine the eligibility for such Work to classify as part of a warranty claim. All costs incurred by or on behalf of PacifiCorp in connection with such Work shall be deducted from the Contract Price or be paid by Developer to PacifiCorp within thirty (30) days.
Sample 1Sample 2
Delay in Remedying Defects. If any defect is not remedied by Contractor within a reasonable time or requires prompt remediation as a result of an emergency situation existing at the Project or Site, Company may proceed to do the Work at Contractor’s risk and expense provided that it does so in a reasonable manner and notifies Contractor of Company’s intention so to do. All Costs (excluding, in the case of Costs comprised of Company’s internal Costs, any xxxx-up for allocated overhead (including general and administrative expenses) in excess of five percent (5%)) incurred by Company shall be deducted from the Contract Price or be paid by Contractor to Company.
Sample 1Sample 2
Delay in Remedying Defects. If any such Defect or damage is not remedied by Contractor within a reasonable time or requires prompt remediation as a result of an emergency situation existing at the Site, Company may proceed to do the Work at Contractor’s risk and expense provided that it does so in a reasonable manner and notifies Contractor of Company’s intention so to do. All Costs incurred by Company shall be deducted from the Contract Price or be paid by Contractor to Company.
Sample 1

Related to Delay in Remedying Defects

  • Cost of remedying Defects Any repair or rectification undertaken in accordance with the provisions of Clause 17.2, including any additional testing, shall be carried out by the Contractor at its own risk and cost, to the extent that such rectification or repair is attributable to: (a) the design of the Project; (b) Plant, Materials or workmanship not being in accordance with this Agreement and the Specifications and Standards; (c) improper maintenance during construction of the Project Highway by the Contractor; and/ or (d) failure by the Contractor to comply with any other obligation under this Agreement.

  • REMEDY OF DEFECTS (a) The BUILDER shall remedy, at its expense, any defects, against which the VESSEL is guaranteed under this Article, by making all necessary repairs or replacements at the SHIPYARD or elsewhere as provided for in (b) hereinbelow. In such case, the VESSEL shall be taken at the BUYER's cost and responsibility to the place selected, ready in all respects for such repairs or replacements and in any event, the BUILDER shall not be responsible for towage, dockage, wharfage, port charges and anything else incurred for the BUYER's getting and keeping the VESSEL ready for such repairing or replacing. (b) However, if it is impractical (which shall include, but not be limited to, an emergency) to bring the VESSEL to the SHIPYARD, the BUYER may cause the necessary repairs or replacements to be made elsewhere which is deemed by the BUYER with the consent of the BUILDER which shall not be unreasonably withheld, to be suitable for the purpose, provided that, in such event, the BUILDER may forward or supply replacement parts or materials under the terms described in (c) hereinbelow, unless forwarding or supplying thereof under the terms described in (c) hereinbelow would impair or delay the operation or working schedule of the VESSEL. In the event that the BUYER proposes to cause the necessary repairs or replacements to be made to the VESSEL at any shipyard or works other than the SHIPYARD, the BUYER shall first (but in all events as soon as reasonably possible) give the BUILDER notice by email or facsimile of the time and place such repairs will be made, and if the VESSEL is not thereby delayed, or her operation or working schedule is not thereby impaired, the BUILDER shall have the right to verify by its own representative(s) the nature and extent of the defects complained of. The BUILDER shall, in such case, promptly advise the BUYER by email or facsimile, after such examination has been completed, of its acceptance or rejection of the defects as ones that are covered by the guarantee herein provided. Upon the BUILDER's acceptance of the defects as justifying remedy under this Article, or upon award of the arbitration so determining, the BUILDER shall compensate the BUYER an amount equal to the reasonable cost of making the same repairs or replacements at the SHIPYARD. (c) In the event that it is necessary for the BUILDER to forward a replacement for a defective part under this guarantee, replacement parts shall be shipped to the BUYER under the C.I.F terms to the BUYER's nominated port. The BUILDER reserves the option to retrieve, at the BUILDER's cost, any of the replaced equipment/parts in case defects are remedied in accordance with the provisions in this Article. (d) Any dispute under this Article shall be referred to arbitration in accordance with the provisions of Article XIII hereof.

  • Effect of Failure or Delay in Requesting Compensation Failure or delay on the part of any Lender or the Issuing Bank to demand compensation pursuant to this Section 5.01 shall not constitute a waiver of such Lender’s or the Issuing Bank’s right to demand such compensation; provided that the Borrower shall not be required to compensate a Lender or the Issuing Bank pursuant to this Section 5.01 for any increased costs or reductions incurred more than 180 days prior to the date that such Lender or the Issuing Bank, as the case may be, notifies the Borrower of the Change in Law giving rise to such increased costs or reductions and of such Lender’s or the Issuing Bank’s intention to claim compensation therefor; provided further that, if the Change in Law giving rise to such increased costs or reductions is retroactive, then the 180-day period referred to above shall be extended to include the period of retroactive effect thereof.

  • Liability for defects 5.1 The Customer is required to inspect the delivered Products without undue delay after delivery and to report any defects. 5.2 The delivered Products are deemed to have been approved if XXXX, with regard to obvious defects, obvious shortages or other defects which were or would have been identifiable in the course of an immediate, careful inspection, has not received notifi- cation of the defect within 7 days of delivery of the product, or otherwise – in the case of unclear or hidden defects – within 7 days of the discovery of the defect or the time at which the defect was identifiable to the Customer in the course of normal use of the Product without closer inspection. 5.3 In the event of a justified complaint, the Customer will be entitled to two attempts to rectify defects or make a replacement delivery at XXXX'x discretion free of charge within a reasonable period of time. Shortages will be delivered subsequently. If two attempts to rectify defects or make a replacement delivery within a reasonable period of time are unsuccessful, the Customer will be entitled to the statutory rights, subject to the provisions of clause 7. Subsequent performance will include neither removal of the defective item nor reassembly if XXXX was not originally required to carry out assembly. The expenses required for the purpose of inspection and subsequent performance, in particular transport, travel, labour and material costs (not: removal and assembly costs), insofar as these are not increased because the subject matter of the contract is located at a place other than our Customer's place of performance, will be borne by XXXX if there is actually a defect. Otherwise, XXXX may demand compensation from the Customer for the costs incurred by the unjustified request for rectification of the defect (in particular inspection and transport costs), unless the lack of defectiveness was not identifiable for the Customer. XXXX can refuse to rectify defects or make a replacement delivery if the Customer does not fulfil its payment obligations towards XXXX to an extent that corresponds to the defect-free part of the service provided. 5.4 No warranty will be assumed, in particular, in the following cases: Unsuitable or in- correct use by the Customer or by third parties instructed by the Customer, in particular through the use of insufficiently qualified personnel, faulty assembly or commission- ing, natural wear and tear (wearing parts), faulty or negligent handling, improper maintenance, unsuitable operating materials, defective construction work, unsuitable construction land, chemical, electrochemical or electrical influences, provided XXXX is not responsible for these circumstances. 5.5 XXXX is also not required to provide a warranty insofar as defects of Products are based on defective materials supplied by the Customer or insofar as defects of Products are based on the fact that the Customer has prescribed the execution of the order ac- cording to construction plans of third parties. 5.6 A delivery of used Products agreed with the Customer in the individual case is made to the exclusion of any warranty, unless XXXX has caused the defect intentionally or through gross negligence or has fraudulently concealed the defect. 5.7 The warranty period will be one year from delivery or, where acceptance was stipu- lated, from acceptance. Replaced parts will become our property and must be sent to us at our request. If shipping, assembly or commissioning is delayed through no fault of our own, our liability will expire no later than twelve months after the transfer of risk. 5.8 The right of recovery in accordance with sections 445a, 445b German Civil Code (BGB) is excluded, unless XXXX has caused the defect intentionally or by gross neg- ligence or has fraudulently concealed the defect.

  • Defaults Remedies If Tenant fails to pay the Rent, or any installment thereof, within five (5) days after the same becomes due and payable, or if Tenant violates or fails or neglects to keep and perform any of the covenants, conditions, and agreements herein contained on the part of Tenant to be kept and performed within thirty (30) days after receipt of written notice of such failure or neglect, or if the Premises becomes vacant or deserted, then, and in each and every such event, at the option of Landlord, Tenant's right of possession will thereupon cease and terminate, and to the extent permitted by law Landlord will be entitled to the possession of the Premises and to re-enter the same without demand of Rent or demand of possession and may forthwith proceed to recover possession of the Premises by process of law, ANY NOTICE TO QUIT OR OF INTENTION TO RE-ENTER THE SAME BEING HEREBY EXPRESSLY WAIVED BY TENANT. In the event of such re-entry by process of law or otherwise, Tenant nevertheless agrees to remain answerable for any and all damage, deficiency or loss of Rent which Landlord may sustain by such re-entry, including reasonable attorneys' fees and court costs; and in such case, Landlord reserves full power, which is hereby acceded to by Tenant, to relet the Premises for the benefit of Tenant, in liquidation and discharge, in whole or in part, as the case may be, of the liability of Tenant under the terms and provision of this Lease. In addition to the foregoing remedies, Landlord will also have the following remedies to the extent permitted by law and all other remedies afforded to it at law or in equity, all of which shall be cumulative: to terminate this Lease; to declare due and payable all Rent for the unexpired Term as and when the same becomes due and payable or to defer any suit until after the Term without thereby prejudicing its rights; to accelerate the Rent for the remainder of the Term and declare it all immediately due and payable [with a present value discount two (2) whole percentage points below the prime rate published in The Wall Street Journal on the date Landlord elects said remedy]; and to bring an action for specific performance, injunction, or other equitable relief to prevent any threatened or impending default or to end any existing default. In addition, Landlord may perform any obligation which Tenant has failed to perform after the expiration of any applicable notice and/or cure period (except in an emergency, when no notice or cure period will be necessary or afforded), all at the cost of Tenant as Additional Rent payable upon demand. Tenant shall also pay all expenses (including, without limitation, reasonable attorneys' fees) incurred by Landlord following a default, whether or not suit is instituted; the same shall be Additional Rent payable upon demand. In determining the Rent due for the balance of the Term, all Additional Rent shall be determined by projecting into the future the Additional Rent payable on the date of default increasing by a compounding five percent (5%) per Lease Year. No waiver of any breach of any covenant, condition, or agreement herein contained shall operate as a waiver of the covenant, condition or agreement itself, or of any subsequent breach thereof. No provision of this Lease shall be deemed to have been waived by Landlord unless such waiver shall be in writing signed by Landlord. No payment by Tenant or receipt by Landlord of a lesser amount than the Rent herein stipulated shall be deemed to be other than on account of the earliest stipulated Rent, nor shall any endorsement or statement on any check or any letter accompanying any check or payment as Rent be deemed an accord and satisfaction, and Landlord may accept such check or payment without prejudice to Landlord's right to recover the balance of such Rent or pursue any other remedy provided in this Lease. Landlord shall have a lien for the payment of the Rent upon all of the goods, wares, chattels, fixtures, furniture and other personal property of Tenant which may be in or upon the Premises, Tenant hereby specifically waiving any and all exemptions allowed by law; such lien may be enforced on the nonpayment of any installment of Rent by the taking and selling of such property in the same manner as in the case of chattel mortgages on default thereunder; said sale is to made upon ten (10) days notice served upon Tenant by posting upon the Premises or such lien may be enforced in any other lawful manner at the option of Landlord.

  • Our Liability for Failure to Complete Transactions If we do not properly complete a transaction from your Card on time or in the correct amount according to our Agreement with you, we will be liable for your losses or damages. However, there are some exceptions. We will not be liable, for instance:

  • Latent Defects Notwithstanding anything to the contrary set forth herein, no acceptance, or deemed acceptance, by City pursuant to this Section shall be applicable with respect to any Latent Defects. An acceptance, or deemed acceptance, by City pursuant to this Section shall not mean that City has accepted, or the other party has been relieved of, responsibility for: (i) compliance with the Laws; (ii) the proper application of construction means or methods; or (iii) correcting any portion of the Project if it later is determined that any portion of the Project is inconsistent with the Final Documents and Drawings.

  • Failure to Cure If DSHS learns of a pattern or practice of the Business Associate that constitutes a violation of the Business Associate’s obligations under the terms of this Contract and reasonable steps by DSHS do not end the violation, DSHS shall terminate this Contract, if feasible. In addition, If Business Associate learns of a pattern or practice of its Subcontractors that constitutes a violation of the Business Associate’s obligations under the terms of their contract and reasonable steps by the Business Associate do not end the violation, Business Associate shall terminate the Subcontract, if feasible.

  • Correction of Defects 35.1 The Engineer shall give notice to the Contractor of any Defects before the end of the Defects Liability Period, which begins at Completion and is defined in the Contract Data. The Defects Liability Period shall be extended for as long as Defects remain to be corrected. 35.2 Every time notice of a Defect is given, the Contractor shall correct the notified Defect within the length of time specified by the Engineer’s notice.

  • Termination for Default; Remedies 8.2.1 Each of the following shall constitute an immediate event of default (“Event of Default”) under this Agreement: (a) Contractor fails or refuses to perform or observe any term, covenant or condition contained in any of the following Sections of this Agreement:

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!