Delay LDs Sample Clauses

Delay LDs. Seller shall pay Purchaser liquidated damages at a daily rate of [Amount] dollars ([$XXX]) per day for Project delay (“Delay LDs”) in the event the Project fails to achieve Project Substantial Completion on or before the Guaranteed Substantial Completion Date as such date may be extended in accordance with this Agreement as a result of a Force Majeure Delay or a Purchaser Caused Delay. Delay LDs shall not exceed the Xxxxx XX Cap.
Sample 1Sample 2
AutoNDA by SimpleDocs
Delay LDs. 9.2.1. As part of the consideration for awarding this Contract, Contractor hereby agrees to pay as liquidated damages the amounts (“Delay LDs”) described in this Clause 9.2. 9.2.2. If Contractor fails to achieve the Completion Guarantee Event on or before the Completion Guarantee Event Deadline, Contractor shall pay Delay LDs in the amounts specified in for each full week after the Completion Guarantee Event Deadline until the date of completion of the Completion Guarantee Event. 9.2.3. If the Contract Price changes after the date hereof, the per diem amount of Delay LDs set forth in shall be increased or decreased, as appropriate, pro rata in accordance with the change in the Contract Price; provided that, once paid, Delay LDs shall not be increased or decreased.
Sample 1

Related to Delay LDs

  • Delay Liquidated Damages Delay Liquidated Damages has the meaning set out in GC 7.6.1.

  • Six-Month Delay Notwithstanding anything to the contrary in this Agreement, no compensation or benefits, including without limitation any severance payments or benefits payable under this Section 4, shall be paid to the Executive during the six-month period following the Executive’s Separation from Service if the Company determines that paying such amounts at the time or times indicated in this Agreement would be a prohibited distribution under Section 409A(a)(2)(B)(i) of the Code. If the payment of any such amounts is delayed as a result of the previous sentence, then on the first day of the seventh month following the date of Separation from Service (or such earlier date upon which such amount can be paid under Section 409A without resulting in a prohibited distribution, including as a result of the Executive’s death), the Company shall pay the Executive a lump-sum amount equal to the cumulative amount that would have otherwise been payable to the Executive during such period.

  • Six Month Delay for Specified Employees If any payment, compensation or other benefit provided to the Executive in connection with his employment termination is determined, in whole or in part, to constitute “nonqualified deferred compensation” within the meaning of Section 409A and the Executive is a “specified employee” as defined in Section 409A, no part of such payments shall be paid before the day that is six months plus one day after the Executive’s date of termination or, if earlier, the Executive’s death (the “New Payment Date”). The aggregate of any payments that otherwise would have been paid to the Executive during the period between the date of termination and the New Payment Date shall be paid to the Executive in a lump sum on such New Payment Date. Thereafter, any payments that remain outstanding as of the day immediately following the New Payment Date shall be paid without delay over the time period originally scheduled, in accordance with the terms of this Agreement.

  • Delay Damages If the Commercial Operation Date is not achieved by the date set forth therefor in Section 3.1(a) (as extended pursuant to Section 3.1(c)), Seller shall pay to Buyer damages for each month from and after such date until the Commercial Operation Date at the rate of $1.50 per kwh of Contract Maximum Amount up to a maximum of twelve (12) months of delay, pro rated for partial months (“Delay Damages”). Delay Damages shall be due under this Section 3.2(a) without regard to whether Buyer exercises its right to terminate this Agreement pursuant to Section 9.3; provided, however, that if Buyer exercises its right to terminate this Agreement under Section 9.3, Delay Damages shall be due and owing to the extent that such Delay Damages were due and owing at the date of such termination. If the Facility has not achieved the Commercial Operation by the date set forth therefor in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), for any reason, Seller shall have the right to terminate this Agreement at any time after that deadline date (as so extended) until either the Facility achieves the Commercial Operation Date or Buyer terminates this Agreement under Section 9.3 (regardless of whether or not Seller elected to continue to construct the Project). In the event Seller so terminates this Agreement, Seller shall be liable to Buyer on the date of such termination for (x) the entire amount of Delay Damages that would otherwise accrue (or have accrued) by such date plus (y) the undrawn amount of any Development Period Security provided to Buyer by Seller; provided, however, that if Seller terminates this Agreement on the deadline set forth for the Commercial Operation Date in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), Seller shall not be required to pay any Delay Damages hereunder but shall forfeit the Development Period Security. Subject to the foregoing sentence, neither Party shall have any liability to the other Party with respect to a termination of this Agreement by Seller under this Section 3.2(b). Each Party agrees and acknowledges that (i) the damages that Buyer would incur due to Seller’s delay in achieving the Commercial Operation Date would be difficult or impossible to predict with certainty, and (ii) it is impractical and difficult to assess actual damages in the circumstances stated, and therefore the Delay Damages and other damages as agreed to by the Parties and set forth herein are a fair and reasonable calculation of such damages. Notwithstanding the foregoing, this Article shall not limit the amount of damages payable to Buyer if this Agreement is terminated by Buyer as a result of Seller’s failure to achieve the Commercial Operation Date. Any such termination damages shall be determined in accordance with Article 9. By the tenth (10th) day following the end of the calendar month in which Delay Damages first become due and continuing by the tenth (10th) day of each calendar month during the period in which Delay Damages accrue (and the following months if applicable), Buyer shall deliver to Seller an invoice showing Buyer’s computation of such damages and any amount due Buyer in respect thereof for the preceding calendar month. No later than ten (10) days after receiving such an invoice, Seller shall pay to Buyer, by wire transfer of immediately available funds to an account specified in writing by Buyer or by any other means agreed to by the Parties in writing from time to time, the amount set forth as due in such invoice. If Seller fails to pay such amounts when due, Buyer may draw upon the Development Period Security for payment of such Delay Damages, and Buyer may exercise any other remedies available for Seller’s default hereunder.

  • Delay Rights Notwithstanding anything to the contrary contained herein, the Partnership may, upon written notice to any Selling Holder whose Registrable Securities are included in a Registration Statement, suspend such Selling Holder’s use of any prospectus which is a part of such Registration Statement (in which event the Selling Holder shall suspend sales of the Registrable Securities pursuant to such Registration Statement) if (i) the Partnership is pursuing an acquisition, merger, reorganization, disposition or other similar transaction and the Partnership determines in good faith that the Partnership’s ability to pursue or consummate such a transaction would be materially and adversely affected by any required disclosure of such transaction in such Registration Statement or (ii) the Partnership has experienced some other material non-public event, the disclosure of which at such time, in the good faith judgment of the Partnership, would materially and adversely affect the Partnership; provided, however, that in no event shall the Selling Holders be suspended from selling Registrable Securities pursuant to such Registration Statement for a period that exceeds an aggregate of sixty (60) days in any 180-day period or ninety (90) days in any 365-day period. Upon disclosure of such information or the termination of the condition described above, the Partnership shall provide prompt notice to the Selling Holders whose Registrable Securities are included in such Registration Statement, and shall promptly terminate any suspension of sales it has put into effect and shall take such other actions necessary or appropriate to permit registered sales of Registrable Securities as contemplated in this Agreement.

  • Payment Delay Notwithstanding any other terms of this Agreement, no payments will be made to CONTRACTOR until COUNTY is satisfied that work of such value has been rendered pursuant to this Agreement. However, COUNTY will not unreasonably withhold payment and, if a dispute exists, the withheld payment shall be proportional only to the item in dispute.

  • Effect of Failure or Delay in Requesting Compensation Failure or delay on the part of any Lender or the Issuing Bank to demand compensation pursuant to this Section 5.01 shall not constitute a waiver of such Lender’s or the Issuing Bank’s right to demand such compensation; provided that the Borrower shall not be required to compensate a Lender or the Issuing Bank pursuant to this Section 5.01 for any increased costs or reductions incurred more than 180 days prior to the date that such Lender or the Issuing Bank, as the case may be, notifies the Borrower of the Change in Law giving rise to such increased costs or reductions and of such Lender’s or the Issuing Bank’s intention to claim compensation therefor; provided further that, if the Change in Law giving rise to such increased costs or reductions is retroactive, then the 180-day period referred to above shall be extended to include the period of retroactive effect thereof.

  • Delay No failure or delay on the part of any party in exercising any right, power, or remedy hereunder shall operate as a waiver thereof, nor shall any single or partial exercise of any such right, power, or remedy preclude any other or further exercise thereof or the exercise of any other right, power, or remedy. The remedies provided for herein are cumulative and are not exclusive of any remedies that may be available to a party at law or in equity or otherwise.

  • Six-Month Delay in Certain Circumstances Notwithstanding anything in this Agreement to the contrary, if any amount or benefit that would constitute Non-Exempt Deferred Compensation would otherwise be payable or distributable under this Agreement by reason of the Executive’s separation from service during a period in which he is a “specified employee” (as defined in Code Section 409A and the final regulations thereunder), then, subject to any permissible acceleration of payment by the Company under Treas. Reg. Section 1.409A‑3(j)(4)(ii) (domestic relations order), (j)(4)(iii) (conflicts of interest), or (j)(4)(vi) (payment of employment taxes), (i) the amount of such Non-Exempt Deferred Compensation that would otherwise be payable during the six-month period immediately following the Executive’s separation from service will be accumulated through and paid or provided on the first day of the seventh month following the Executive’s separation from service (or, if the Executive dies during such period, within thirty (30) days after the Executive’s death) (in either case, the “Required Delay Period”); and (ii) the normal payment or distribution schedule for any remaining payments or distributions will resume at the end of the Required Delay Period.

  • Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!