Delays Caused by Tenant. There shall be no abatement of rent, and the ninety (90) day period specified in Section 2.4 shall be deemed extended, to the extent of any delays caused by acts or omissions of Tenant, Tenant’s agents, employees and contractors, or for Tenant delays as defined in any work letter agreement attached to this Lease, if any (hereinafter “Tenant Delays”). Tenant shall pay to Landlord an amount equal to one thirtieth (1/30th) of the Base Monthly Rent due for the first full calendar month of the Lease term for each day of Tenant Delay. For purposes of the foregoing calculation, the Base Monthly Rent payable for the first full calendar month of the term of this Lease shall not be reduced by any abated rent, conditionally waived rent, free rent or similar rental concessions, if any. Landlord and Tenant agree that the foregoing payment constitutes a fair and reasonable estimate of the damages Landlord will incur as the result of a Tenant Delay. Within thirty (30) days after Landlord tenders possession of the Premises to Tenant, Landlord shall notify Tenant of Landlord’s reasonable estimate of the date Landlord could have delivered possession of the Premises to Tenant but for the Tenant Delays. After delivery of said notice, Tenant shall immediately pay to Landlord the amount described above for the period of Tenant Delay.
Delays Caused by Tenant. Notwithstanding anything to the contrary above, if City's inability to deliver possession of the Premises on the Commencement Date results from the acts or omissions of Tenant or any of Tenant's Agents, then the Base Rent and Additional Charges payable by Tenant under this Lease shall commence on the date when City would have delivered possession of the Premises but for such acts or omissions.
Delays Caused by Tenant. There shall be no abatement of Rent, and the sixty (60) day period following the Commencement Date before which Tenant's right to cancel this Lease accrues under paragraph 3.2, shall be deemed extended to the extent of any delays caused by wrongful or negligent acts or omissions of Tenant, Tenant's agents, employees and contractors.
Delays Caused by Tenant. Notwithstanding anything to the contrary above, if County’s inability to deliver possession of the Premises on the Estimated Commencement Date results from Tenant’s or its Agents’ acts or omissions, then Base Rent and Additional Charges payable by Tenant hereunder shall commence on the date when Landlord would have delivered possession of the Premises but for such acts or omissions.
Delays Caused by Tenant. If the Effective Date is delayed due in any respect to Tenant's failure to meet the schedule set forth in paragraph 3 of this Exhibit B, or due to construction delays related to any changes required by Tenant, or due to any other failures by Tenant to perform its obligations under this Exhibit B or otherwise under the Lease or the Amendment, then any such delays shall be deemed Tenant caused delays for purposes of determining the Effective Date pursuant to paragraph 2 of the Amendment.
Delays Caused by Tenant. Notwithstanding anything to the contrary in Section 4.1, if Landlord’s failure to deliver possession of the Premises to Tenant on the Commencement Date results from Tenant’s (or its agents’ or employees’) acts or omissions, the Monthly Rent and Additional Rent payable by Tenant shall commence on the date when Landlord would have delivered possession of the Premises but for such acts or omissions.
Delays Caused by Tenant. There shall be no abatement of Rent, and the sixty (60) day period following the Commencement Date before which Tenant's right to cancel this Lease accrues under paragraph 3.2, shall be deemed extended to the extent of any delays caused by acts or omissions of Tenant, Tenant's agents, employees and contractors.
Delays Caused by Tenant. If Tender of Possession is delayed as a result of delays caused by acts or omissions of Tenant, Tenant’s agents, employees and contractors, the date that Tender of Possession would have occurred but for such delays shall be deemed for all purposes to be the date of Tender of Possession, and there shall be no abatement of rent thereafter.
Delays Caused by Tenant. If the Substantial Completion Date shall be delayed by reason of a Tenant Delay, the Premises shall be deemed Substantially Complete for purposes of determining the Commencement Date as of the day that the Premises would have been Substantially Complete but for such Tenant Delay as determined by Landlord in its reasonable discretion. Tenant shall pay to Landlord a sum equal to any additional cost to Landlord in completing Landlord's Work resulting from any Tenant Delay if, as a result thereof, the aggregate cost to complete Landlord's Work is increased. Any such sum shall be in addition to any sums payable pursuant to any other section of this Lease and shall be paid to Landlord within ten (10) days after Landlord submits an invoice to Tenant. Any costs payable pursuant to this Section 1.3b shall be collectable in the same manner as Rent and, if Tenant defaults in the payment thereof, Landlord shall have the same rights as in the Event of Default by Tenant in the payment of Rent in addition to any other remedies and Landlord shall have no obligation to continue the performance of Landlord's Work until Tenant shall have cured such Default.
Delays Caused by Tenant. If the commencement of the term is delayed due in any material respect to Tenant's failure to meet the schedule set forth in paragraph 4 above, or to construction delays because of any changes required by Tenant, or due to any other failures to Tenant to perform its obligations under this lease, then the basic rent and common area charges and any other payments specified in the lease as commencing upon the commencement date of this lease shall nonetheless commence in full as of the date by which Landlord's work would have been, in Landlord's reasonable judgment, completed but for such delays or failure to perform by Tenant.
