PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract. Delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor, unless otherwise agreed to by the Authorized User and the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of a Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
SERVICE DELIVERABLES You will receive service on the Covered Product as described below: Carry-In: Unless otherwise provided in this Agreement, the Covered Product must be shipped or delivered and retrieved by You at Our authorized service center during normal business hours. In-Home/On-Site: Service will be performed in Your home or on-site as indicated on the Declarations Page of this Agreement, or on Your sales receipt or invoice provided You have fulfilled the following requirements: (1) provide Our authorized technician with accessibility to the Covered Product; (2) provide a non-threatening and safe environment for Our authorized technician; and (3) an adult over the age of 18 must be present for the period of time Our authorized technician is scheduled to provide service and while Our authorized technician is on Your property servicing the Covered Product. In-Home Service will be provided by Our authorized service provider during regular business hours, local time, Monday through Friday, except holidays. Our authorized service center may opt to remove the Covered Product to perform service in-shop. The Covered Product will be returned upon completion. Additional time and mileage charges for in-home repairs outside of twenty-five (25) contiguous land miles or the normal service radius of Our authorized service center are not covered by this Agreement, and are Your responsibility.
Supply of Products
3.1 The Supplier warrants that the Products shall:
(a) correspond with their description and any applicable Product Specification;
(b) conform in all respects with the Order and any relevant sample;
(c) be of satisfactory quality and fit for any purpose held out by the Supplier or made known to the Supplier by Ornua, expressly or by implication, and in this respect Ornua relies on the Supplier's skill and judgement;
(d) be manufactured by properly trained and qualified personnel using all reasonable skill, care and diligence and in a good and workmanlike manner;
(e) where they are manufactured products, be free from defects in design, materials and workmanship and remain so for the period set out in the Product Specification or, if none is specified, for at least 12 months after delivery;
(f) comply with all applicable statutory and regulatory requirements relating to the manufacture, labelling, packaging, storage, handling and delivery of the Products;
(g) comply with all relevant standards including any UK Standards, European Standards or International Standards applicable in the UK and the country or State where the Products are to be used; and
(h) in the case of Products containing food stuffs, when delivered to Ornua, comply with all applicable food and hygiene legislation and regulations and best industry practice.
3.2 The Supplier shall ensure that at all times it has and maintains all licences, permissions, authorisations, consents and permits needed to carry out its obligations under the Contract in respect of the supply of Products. Breach of this Condition shall be deemed a material breach of the Contract.
3.3 Ornua may inspect and test the Products at any time before delivery. The Supplier shall remain fully responsible for the Products despite any such inspection or testing and any such inspection or testing shall not reduce or otherwise affect the Supplier's obligations under the Contract.
3.4 If following such inspection or testing Ornua considers that the Products do not comply or are unlikely to comply with the Supplier's undertakings at clause 3.1, Ornua shall inform the Supplier and the Supplier shall immediately take such remedial action as is necessary to ensure compliance.
3.5 Ornua may conduct further inspections and tests after the Supplier has carried out its remedial actions.
PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract or Contract Award Notice. Unless otherwise specified in the Bid Documents, delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
Supply of Product 4.1 DAEWOONG shall manufacture and supply Product to AEON in a primary packaged and labeled form. Product packaging shall display the logo of DAEWOONG (to the extent required by applicable law) and AEON and the outer label shall be marked using English language in accordance with applicable laws and Product’s Regulatory Approvals.
4.2 AEON’s estimate sales forecast of the Product during the Term of Agreement in the Territory in the Field is set forth in Annex D. Within ninety (90) days after the Effective Date, AEON shall provide DAEWOONG with a non-binding twelve (12) month rolling forecast of its requirements of Product, which the Parties agree is not a commitment to buy any stated quantity. Thereafter, on at least a quarterly basis, AEON shall provide DAEWOONG with an updated twelve (12) month rolling forecast, together with a binding six (6) month forecast to the extent AEON has requested Safety Stock as described in Article 4.10 below. Each such forecast shah be referred to herein as a “Forecast.”
4.3 AEON may from time to time submit Purchase Orders to DAEWOONG for Product in accordance with the forecasting requirements in Article 4.2. Orders will be shipped on CIF Los Angeles port.
4.4 Once a Purchase Order for Product and Product Samples has been received by DAEWOONG, it shall be considered as irrevocable.
4.5 AEON agrees herein to place an Order for Product not later than [***] from receipt of Regulatory Approval.
4.6 Individual Purchase Orders of Product shall be placed at least [***] in advance of the required delivery date.
4.7 For the purpose of Commercialization, AEON will store and maintain the full quantity of Product in a clean, secured area in accordance with the reasonable directions and specifications provided by DAEWOONG in writing in connection thereof in the Territory. AEON will advise DAEWOONG on the applicable requirements specifically deriving from the laws and regulations in the Territory.
4.8 AEON agrees that DAEWOONG and its collaborators and agents, in DAEWOONG’s sole discretion, which collaborators and Agents will be subject to appropriate obligations of confidentiality, will have the right upon reasonable prior notice, to observe and to inspect and to audit AEON’s facility to ascertain compliance by AEON with the terms of this Agreement, including without limitation (a) the holding facilities for Product, and (b) AEON’s compliance with applicable law, including cGMP (if applicable). Following any such audit, DAEWOONG will discuss its observations and conclusions with AEON and corrective actions, if any, will be agreed upon by the Parties, and executed by AEON using Commercially Reasonable Efforts.
4.9 In addition to any other rights and remedies available to AEON, AEON shall have the right to recover lost profits in the event that DAEWOONG fails to deliver at least [***] in any [***] (a “Supply Default Event”). For purposes of this provision, lost profits would be equal to [***] of AEON operating profit (sales less direct expenses and the puce paid by AEON for such Products) on Products that have not been shipped against firm Purchase Orders during the period leading up to the Supply Default Event and bona fide Purchase Orders submitted by AEON that are consistent with the Forecast during the Supply Default Period (as defined below). Such payment shall be made with respect to all Product not shipped in the period giving rise to the Supply Default and for the period until DAEWOONG is again timely shipping Product to meet AEON’s needs (the “Supply Default Period”). The first such payment shall be made within [***] of the Supply Default Event, and every [***] thereafter. AEON agrees to permit full disclosure to DAEWOONG of AEON’s accounting records, solely related to the calculation of lost profits, for the [***] ending on the first day of the month in which the Supply Event Default occurred. In the event that DAEWOONG is unable to supply both AEON’s requirements of Product and its own and third parties’ requirements for Product, DAEWOONG shall allocate Product that DAEWOONG has in inventory and that DAEWOONG is able to Product, so that AEON receives its requirements of Product in priority to DAEWOONG and third parties.
4.10 At the request of AEON, DAEWOONG shall at its own cost and expense during the Term, maintain an amount of inventory of Product equal to AEON’s requirements for Product for [***] based on AEON’s most recent forecast (“Safety Stock”). The Safety Stock shall be (i) maintained for the sole benefit of AEON and its Affiliates, (ii) shall be stored at a secure facility in compliance with GMP, and (iii) shall not be used for the benefit of any other customer of DAEWOONG. DAEWOONG shall rotate the Safety Stock on a “First Expiry-First Out” basis for routine fulfillment of firm orders, subject to Article 7.
Contract Deliverables The Contractor shall provide information technology staff augmentation services, including comprehensive management of staff, as set forth in this Contract. The term “staff” refers to the temporary staff provided by the Contractor to render information technology services identified by Customers, but that staff shall not be deemed an employee of the State or deemed to be entitled to any benefits associated with such employment. Contracts resulting from this solicitation should not be structured as fixed-price agreements or used for any services requiring authorization for payment of milestone tasks. Contractor shall only provide information technology staff augmentation services for those Job Titles awarded to the Contractor and shall be paid on an hourly basis. The Department’s intent is for Contractor’s information technology staff to provide services closely related to those described in the Job Family Descriptions document. Detailed scopes of work, specific requirements of the work to be performed, and any requirements of staff shall be provided by the Customer in a Request for Quote. The Contractor shall possess the professional and technical staff necessary to allocate, outsource, and manage qualified information technology staff to perform the services requested by the Customer. The Contractor shall provide Customers with staff who must have sufficient skill and experience to perform the services assigned to them. All of the information technology staff augmentation services to be furnished by the Contractor under the Contract shall meet the professional standards and quality that prevails among information technology professionals in the same discipline and of similar knowledge and skill engaged in related work throughout Florida under the same or similar circumstances. The Contractor shall provide, at its own expense, training necessary for keeping Contractor’s staff abreast of industry advances and for maintaining proficiency in equipment and systems that are available on the commercial market. The Contractor shall be responsible for the administration and maintenance of all employment and payroll records, payroll processing, remittance of payroll and taxes, and all administrative tasks required by state and federal law associated with payment of staff. The Contractor shall, at its own expense, be responsible for adhering to the Contract background screening requirements, testing, evaluations, advertising, recruitment, and disciplinary actions of Contractor’s information technology staff. The Contractor shall maintain during the term of the Contract all licenses, permits, qualifications, insurance and approvals of whatever nature that are legally required to perform the information technology staff augmentation services.
Limited Product Warranty Repair or Replacement within 12 years
Purchase Order Pricing/Product Deviation If a deviation of pricing/product on a Purchase Order or contract modification occurs between the Vendor and the TIPS Member, TIPS must be notified within five (5) business days of receipt of change order. TIPS reserves the right to terminate this agreement for cause or no cause for convenience with a thirty (30) days prior written notice. Termination for convenience is conditionally required under Federal Regulations 2 CFR part 200 if the customer is using federal funds for the procurement. All purchase orders presented to the Vendor, but not fulfilled by the Vendor, by a TIPS Member prior to the actual termination of this agreement shall be honored at the option of the TIPS Member. The awarded Vendor may terminate the agreement with ninety (90) days prior written notice to TIPS 0000 XX Xxx Xxxxx, Xxxxxxxxx, Xxxxx 00000. The vendor will be paid for goods and services delivered prior to the termination provided that the goods and services were delivered in accordance with the terms and conditions of the terminated agreement. This termination clause does not affect the sales agreements executed by the Vendor and the TIPS Member customer pursuant to this agreement. TIPS Members may negotiate a termination for convenience clause that meets the needs of the transaction based on applicable factors, such as funding sources or other needs. Usually, purchase orders or their equal are issued by participating TIPS Member to the awarded vendor and should indicate on the order that the purchase is per the applicable TIPS Agreement Number. Orders are typically emailed to TIPS at xxxxxx@xxxx-xxx.xxx. • Awarded Vendor delivers goods/services directly to the participating member. • Awarded Vendor invoices the participating TIPS Member directly. • Awarded Vendor receives payment directly from the participating member. • Fees are due to TIPS upon payment by the Member to the Vendor. Vendor agrees to pay the participation fee to TIPS for all Agreement sales upon receipt of payment including partial payment, from the Member Entity or as otherwise agreed by TIPS in writing and signed by an authorized signatory of TIPS.
Project Deliverables The Contractor shall provide each of the following deliverables in writing to the City for review and approval to achieve the project objectives.
C.1. <Title> Deliverable 1
SHIPPING/RECEIPT OF PRODUCT a. Packaging Tangible Product shall be securely and properly packed for shipment, storage and stocking in appropriate, clearly labeled shipping containers and according to accepted commercial practice, without any extra charges for packing materials, cases or other types of containers. The container shall become and remain the property of the Authorized User unless otherwise specified in the Contract documents.
