Service Delivery Requirements The following sections describe in detail the work activity required by this program. All CONTRACTORS will be expected to fulfill the work activity requirements in these areas.
A. Staff Requirements & Policies CONTRACTOR shall provide the necessary management and administrative personnel whose expertise will ensure efficient operation of SNEMT services. OoA recognizes that a high quality operation begins with key personnel. Therefore, a minimum level of required staffing is described for the positions and functions described below.
1. Program Manager/Director The program manager/director will be in charge of all management and day- to-day operations of the CONTRACTOR’s SNEMT program. The position will maintain consistent and sufficient contact and communication with the OoA and be responsible for all CONTRACT obligations.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Equipment Requirements No Equipment is provided to Customer as part of this Service.
DATA ESCROW REQUIREMENTS Registry Operator will engage an independent entity to act as data escrow agent (“Escrow Agent”) for the provision of data escrow services related to the Registry Agreement. The following Technical Specifications set forth in Part A, and Legal Requirements set forth in Part B, will be included in any data escrow agreement between Registry Operator and the Escrow Agent, under which ICANN must be named a third-‐party beneficiary. In addition to the following requirements, the data escrow agreement may contain other provisions that are not contradictory or intended to subvert the required terms provided below.
CONTRACT REQUIREMENTS A. Project area boundaries are marked with two blue paint slashes and block boundaries are designated with one blue paint slash.
B. All blocks are accessible by foot only. Xxxxxx’x Creek must be crossed on foot from the PGC railroad grade.
C. Block 1, All trees 1” DBH and over, except for red and blue paint marked trees are to be cut. All conifers are reserved. Block 1 will be cut during the dormant season; October 15 through March 15.
D. Block 2, All American beech, sweet birch, aspen, stripped maple, and ironwood 1” DBH and greater will be cut. All yellow marked trees will be cut. Block 2 will be cut during the dormant season; October 15 through March 15.
E. Block 3, All trees 1” DBH and over, except for red and blue paint marked trees are to be cut. All conifers are reserved. Block 3 will be cut during the dormant season; October 15 through March 15.
F. All employees must be able to identify species.
G. Usable material may not be removed from site.
X. Xxxxx material felled with clean cuts must have stumps that are parallel to the ground surface and shall not exceed six (6) inches in height measured on the side next to the highest ground or the diameter of the xxxxx, whichever is smaller, except when in the opinion of the Field Contract Coordinator, said height is impractical.
I. Cut trees must be removed from trails, roads, tail drains, streams, and utility rights-of- way.
J. All trees shall be felled so tops do not pile on one another but lie singly on the ground.
K. Slash shall be lopped to no higher than 4’ and pulled apart as directed by the Regional Forester.
L. Operator shall exercise care and caution in all operations to prevent damage to all trees not specified for treatment.
M. All tops must be pulled back 25 feet from the State Game Land boundary, (blazed & painted white), all roads, parking lots, herbaceous openings, utility Right of Ways and deer exclosures. Tops, branches, and slash will be removed from all ponds, lakes, and streams.
N. Damage to trails, roads, streams, or utility rights-of-way caused by the Operator’s equipment must be repaired by the Operator at their expense.
O. Any trash resulting from the Operator’s operations must be removed from the area and properly disposed.
P. The Operator shall not block any roads or trails in the area during performance of this contract. The Operator shall not in any way hinder the progress of any Timber Sale Contracts in these areas.
Q. All labor, equipment, tools, etc., needed to complete contracted projects are to be provided by the Operator.
R. Timber Damages – when in the opinion of Field Contract Coordinator, damage to the residual stand becomes excessive, the Operator shall pay the Commission a fair base current value determined by the Field Contract Coordinator per unit of volume. If this value for damage due to Operator’s carelessness or negligence is less than $10.00 per tree, then a minimum charge of $10.00 per tree will be made whether the tree is commercial, non-commercial, merchantable, or non-merchantable.
Support Requirements If there is a dispute between the awarded vendor and TIPS Member, TIPS or its representatives may assist, at TIPS sole discretion, in conflict resolution or third party (mandatory mediation), if requested by either party. TIPS, or its representatives, reserves the right to inspect any project and audit the awarded vendors TIPS project files, documentation and correspondence. TIPS Members stand in the place of TIPS as related to this agreement and have the same access to the proposal information and all related documents. TIPS Members have all the same rights under the awarded Agreement as TIPS.
Federal Medicaid System Security Requirements Compliance Party shall provide a security plan, risk assessment, and security controls review document within three months of the start date of this Agreement (and update it annually thereafter) in order to support audit compliance with 45 CFR 95.621 subpart F, ADP System Security Requirements and Review Process.
Project Requirements 1. Project must conform to regulations under 24 CFR Part 92, commonly known as the HOME Regulations.
Export Requirements The Program, Documentation and all related technical information or materials are subject to export controls and U.S. Government export regulations. You will comply strictly with all legal requirements established under these controls and will not, in connection with its limited evaluation rights hereunder, export, re-export, divert, transfer or disclose, directly or indirectly the Program, Documentation and any related technical information or materials without the prior approval of the U.S.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
