Product Recall (a) If a recall is required by applicable Law, or if Buyer or Supplier reasonably determines that a recall is advisable because the goods may create a potential safety hazard, are not in compliance with any applicable code, standard or legal requirement, or contain a defect or non-conformance with the requirements of this Order occurring or likely to occur in multiple goods, which such defects or non-conformances are substantially similar or have substantially similar causes or effects (collectively a “Serial Defect”), the parties shall promptly communicate such facts to each other. At Buyer’s request, Supplier shall promptly develop a corrective action plan satisfactory to Buyer, which shall include all actions required to recall and/or repair the goods and any actions required by applicable Law (“Corrective Action Plan”) for Buyer’s review and approval. At Buyer’s election, Xxxxx may develop the Corrective Action Plan. In no event shall Buyer and Supplier’s failure to agree on the Corrective Action Plan delay the timely notification of a potential safety hazard, non-compliance or Serial Defect to users of the goods, cause either party to be non-compliant with applicable Law or prevent Buyer from taking reasonable actions to prevent injury or damage to persons, equipment or other property. Supplier and Buyer shall cooperate with and assist each other in any corrective actions and/or filings, if applicable.
(b) To the extent a recall is required by applicable Law, or due to a potential safety hazard, non-compliance or Serial Defect, which is caused by Supplier, Supplier shall indemnify and hold Buyer harmless from all reasonable costs and expenses incurred in connection with any recall, repair, replacement or refund program, including all costs related to: (i) investigating and/or inspecting the affected goods; (ii) notifying Buyer’s customers; (iii) repairing, or where repair of the goods is impracticable or impossible, repurchasing or replacing the recalled goods; (iv) packing and shipping the recalled goods; and (v) media notification. Each party shall consult the other before making any statements to the public or a governmental agency relating to such recall, potential safety hazard, non- compliance or Serial Defect, except where such consultation would prevent timely notification required by Law.
Product Recalls (a) If either Party reasonably decides or is required by any government authority or court of competent jurisdiction, to initiate a product recall, withdrawal or field correction with respect to, or if there is any governmental seizure of, the Product, the Party initiating or required to initiate such action will notify the other Party promptly of the details regarding such action, including providing copies of all relevant documentation concerning such action. The Parties will assist each other in investigating any such situation and all regulatory contacts that are made and all activities concerning seizure, recall, withdrawal or field correction will be jointly coordinated by HSL and LMI.
(b) If any such recall, withdrawal, field correction or seizure occurs due solely to (i) failure of any Product produced by HSL hereunder to conform to Specifications (including, without limitation, being adulterated or misbranded) or any warranty or other requirement set forth in this Agreement, (ii) the failure of HSL to comply in all material respects with any applicable law, rule, regulation, guideline, standard, court order or decree or (iii) the negligent or intentional wrongful act or omission of HSL in connection with the production of Product hereunder, then HSL shall bear the **** of any such seizure, recall, withdrawal or field correction and shall reimburse LMI for its ****, including any purchase price payments made to HSL and related taxes to the extent related to such recalled Product. To the extent any such recall, withdrawal, field correction or seizure occurs for any reason other than that set forth in the immediately preceding sentence, then LMI shall bear the **** of any such seizure, recall, withdrawal or field correction. If both HSL and LMI contribute to the cause of a seizure, recall, withdrawal or field correction, the cost and expense thereof will be shared in proportion to each Party’s contribution to the problem. For the purposes of this Agreement, the expenses of any recall, withdrawal, field correction or seizure shall include, without limitation, the out-of-pocket expenses of notification and destruction or return of the recalled Product and all other out-of-pocket costs incurred in connection with such recall but shall not include a Party’s lost profits. HSL’s reimbursement for the costs of LMI Materials related to such recall, withdrawal or field correction is limited by Section 5.6(c).
Clinical Data and Regulatory Compliance The preclinical tests and clinical trials, and other studies (collectively, “studies”) that are described in, or the results of which are referred to in, the Registration Statement or the Prospectus were and, if still pending, are being conducted in all material respects in accordance with the protocols, procedures and controls designed and approved for such studies and with standard medical and scientific research procedures; each description of the results of such studies is accurate and complete in all material respects and fairly presents the data derived from such studies, and the Company and its subsidiaries have no knowledge of any other studies the results of which are inconsistent with, or otherwise call into question, the results described or referred to in the Registration Statement or the Prospectus; the Company and its subsidiaries have made all such filings and obtained all such approvals as may be required by the Food and Drug Administration of the U.S. Department of Health and Human Services or any committee thereof or from any other U.S. or foreign government or drug or medical device regulatory agency, or health care facility Institutional Review Board (collectively, the “Regulatory Agencies”); neither the Company nor any of its subsidiaries has received any notice of, or correspondence from, any Regulatory Agency requiring the termination, suspension or modification of any clinical trials that are described or referred to in the Registration Statement or the Prospectus; and the Company and its subsidiaries have each operated and currently are in compliance in all material respects with all applicable rules, regulations and policies of the Regulatory Agencies.
Random Drug Testing All employees covered by this Agreement shall be subject to random drug testing in accordance with Appendix D.
SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work.
4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work.
4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged.
4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents.
4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents.
4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof.
4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals.
4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
Product Specifications (a) Supplier shall manufacture all Products according to the Specifications in effect as of the date of this Agreement, with such changes or additions to the Specifications of the Products related thereto as shall be requested by Buyer in accordance with this Section or as otherwise agreed in writing by the Parties. All other Products shall be manufactured with such Specifications as the Parties shall agree in writing.
(b) Buyer may request changed or additional Specifications for any Product by delivering written notice thereof to Supplier not less than one hundred twenty (120) days in advance of the first Firm Order for such Product to be supplied with such changed or additional Specifications. Notwithstanding the foregoing, if additional advance time would reasonably be required in order to implement the manufacturing processes for production of a Product with any changed or additional Specifications, and to commence manufacture and delivery thereof, Supplier shall so notify Buyer, and Supplier shall not be required to commence delivery of such Product until the passage of such additional time.
(c) Supplier shall be required to accommodate any change of, or additions to, the Specifications for any Product, if and only if (i) in Supplier’s good faith judgment, such changed or additional Specifications would not require Supplier to violate good manufacturing practice, (ii) the representation and warranty of Buyer deemed made pursuant to Subsection (e) below is true and correct, and (iii) Buyer agrees to reimburse Supplier for the incremental costs and expenses incurred by Supplier in accommodating the changed or additional Specifications, including the costs of acquiring any new machinery and tooling. For the avoidance of doubt, such costs and expenses shall be payable by Buyer separately from the cost of Products at such time or times as Supplier shall request.
(d) Supplier shall notify Buyer in writing within thirty (30) days of its receipt of any request for changed or additional Specifications (i) whether Supplier will honor such changed or additional Specifications, (ii) if Supplier declines to honor such changed or additional Specifications, the basis therefor and (iii) if applicable, the estimated costs and expenses that Buyer will be required to reimburse Supplier in respect of the requested changes or additions, as provided in Subsection (c) above. Buyer shall notify Supplier in writing within fifteen (15) days after receiving notice of any required reimbursement whether Buyer agrees to assume such reimbursement obligation.
(e) By its request for any changed or additional Specifications for any Product, Buyer shall be deemed to represent and warrant to Supplier that the manufacture and sale of the Product incorporating Buyer’s changed or additional Specifications, as a result of such incorporation, will not and could not reasonably be expected to (i) violate or conflict with any contract, agreement, arrangement or understanding to which Buyer and/or any of its Affiliates is a party, including this Agreement and any other contract, agreement, arrangement or understanding with Supplier and/or its Affiliates, (ii) infringe on any trademark, service xxxx, copyright, patent, trade secret or other intellectual property rights of any Person, or (iii) violate any Applicable Law. Buyer shall indemnify and hold Supplier and its Affiliates harmless (including with respect to reasonable attorneys’ fees and disbursements) from any breach of this representation and warranty.
Alcohol and Drug Testing Employee agrees to comply with and submit to any Company program or policy for testing for alcohol abuse or use of drugs and, in the absence of such a program or policy, to submit to such testing as may be required by Company and administered in accordance with applicable law and regulations.
DRUG/ALCOHOL TESTING Section 33.1 Drug testing may be conducted on employees during their duty hours upon reasonable suspicion or randomly by computer selection. Alcohol testing will be conducted only upon reasonable suspicion. Reasonable suspicion that an employee used or is using a controlled substance or alcohol in an unlawful or abusive manner may be based upon, but not limited to:
A. Observable phenomena, such as direct observation of drug or alcohol use or possession and/or the physical symptoms of being under the influence of a drug or alcohol;
B. A pattern or abnormal conduct or erratic behavior, including abnormal leave patterns;
C. Arrest or conviction for a drug or alcohol-related offense, or the identification of an employee as the focus of a criminal investigation into illegal drug or alcohol possession, use, or trafficking;
D. Information provided either by reliable and credible sources or independently corroborated;
E. Evidence that an employee has tampered with a previous drug test;
F. Facts or circumstances developed in the course of an authorized investigation of an accident or unsafe working practices.
Section 33.2 Drug/alcohol testing shall be conducted solely for administrative purposes and the results obtained shall not be used in criminal proceedings. Under no circumstances may the results of drug/alcohol screening or testing be released to a third party for use in a criminal prosecution against the affected employee. The following procedure shall not preclude the Employer from other administrative action but such actions shall not be based solely upon the initial reagent testing results alone.
Section 33.3 All drug screening tests shall be conducted by laboratories meeting the standards of the Substance Abuse and Mental Health Service Administration. No test shall be considered positive until it has been confirmed by a Gas Chromatography/Mass Spectrometry. The procedures utilized by the Employer and testing laboratory shall include an evidentiary chain of custody control and split sample testing. All procedures shall be outlined in writing and this outline shall be followed in all situations arising under this article.
Section 33.4 Alcohol testing shall be done in accordance with the law of the State of Ohio to detect drivers operating a motor vehicle under the influence. A positive result shall entitle the Employer to proceed with sanctions as set forth in this Article.
Section 33.5 The results of the testing shall be delivered to a specified employee of the Employer with command responsibility and the employee tested. An employee whose confirmatory test result is positive shall have the right to request a certified copy of the testing results in which the vendor shall affirm that the test results were obtained using the approved protocol methods. The employee shall provide a signed release for disclosure of the testing results to the Employer. A representative for the bargaining unit shall have a right of access to the results upon request to the Employer, with the employee’s written consent. Refusal to submit to the testing provided for under this Agreement may be grounds for discipline.
A. If a drug screening test is positive, a confirmatory test shall be conducted utilizing the fluid from the primary sample.
B. In the event that any confirmation drug test results are positive, the employee is entitled to have the split sample tested by another DHHS-certified lab in the manner prescribed above at the employee’s expense. The employee must request the split sample test within seventy-two (72) hours of being notified of a positive result. The results of this test, whether positive or negative, shall be determinative.
Section 33.7 A list of three (3) testing laboratories shall be maintained by the Employer. These laboratories shall conduct any testing directed by the Employer. The Employer shall obtain the approval of the bargaining unit representative as to any laboratories put on this list, which approval shall not be unreasonably withheld.
Section 33.8 If after the testing required above has produced a positive result the Employer may require the employee to participate in any rehabilitation or detoxification program that is covered by the employee’s health insurance. Discipline allowed by the positive findings provided for above shall be deferred pending rehabilitation of the employee within a reasonable period. An employee who participates in a rehabilitation or detoxification program shall be allowed to use sick time and vacation leave for the period of the rehabilitation or detoxification program. If no such leave credits are available, the employee shall be placed on medical leave of absence without pay for the period of the rehabilitation or detoxification program. Upon completion of such program and upon receiving results from a retest demonstrating that the employee is no longer abusing a controlled substance/alcohol, the employee shall be returned to his/her former position. Such employee may be subject to periodic retesting upon his/her return to his/her position for a period of one (1) year from the date of his/her return to work. Any employee in a rehabilitation or detoxification program in accordance with this Article will not lose any seniority or benefits, should it be necessary for the employee to be placed on medical leave of absence without pay, for a period not to exceed ninety (90) days.
Section 33.9 If the employee refuses to undergo rehabilitation or detoxification, or if he/she tests positive during a retesting within one (1) year after his/her return to work from such a program, the employee shall be subject to disciplinary action, including removal from his/her position and termination of his/her employment.
Section 33.10 Costs of all drug screening tests and confirmatory tests shall be borne by the Employer except that any test initiated at the request of the employee shall be at the employee’s expense.
Section 33.11 The Employer may conduct four (4) tests of an employee during the one (1) year period after the employee has completed a rehabilitation or detoxification program as provided above.
Section 33.12 The provisions of this Article shall not require the Employer to offer a rehabilitation/detoxification program to any employee more than once.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Drug Testing (A) The state and the PBA agree to drug testing of employees in accordance with section 112.0455, F.S., the Drug-Free Workplace Act.
(B) All classes covered by this Agreement are designated special risk classes for drug testing purposes. Special risk means employees who are required as a condition of employment to be certified under Chapter 633 or Chapter 943, F.S.
(C) An employee shall have the right to grieve any disciplinary action taken under section 112.0455, the Drug-Free Workplace Act, subject to the limitations on the grievability of disciplinary actions in Article 10. If an employee is not disciplined but is denied a demotion, reassignment, or promotion as a result of a positive confirmed drug test, the employee shall have the right to grieve such action in accordance with Article 6.
