Developer’s Investigations Sample Clauses

Developer’s Investigations. For a period up to and including the Contingency Date, EDA shall allow Developer and Developer’s agents access to the Property without charge and at all times for the purpose of Developer’s investigation and testing of the Property, including surveying and testing of soil and groundwater (“Developer’s Investigations”); provided, however, Developer shall not perform any invasive testing unless (a) EDA gives its prior approval of Developer’s consultant that will perform the testing, which approval shall not be unreasonably withheld, conditioned or delayed, and (b) Developer gives EDA reasonable prior notice of such testing. EDA shall have the right to accompany Developer during any of Developer’s Investigations of the Property. Developer shall provide to EDA copies of all third- party, non-confidential written test results and reports conducted as part of Developer’s Investigations. Developer agrees to pay all of the costs and expenses associated with Developer’s Investigations, to cause to be released any lien on the Property arising as a result of Developer’s Investigations and to repair and restore, at Developer’s expense, any damage to the Property caused by Developer’s Investigations. Developer shall indemnify and hold EDA harmless from all costs and liabilities, including, but not limited to, reasonable attorneys’ fees, arising from Developer’s Investigations. The indemnification obligations provided herein shall survive the termination or cancellation of this Agreement.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Developer’s Investigations. For a period of up to sixty (60) calendar days following the Effective Date, HEDRA shall allow Developer and Developer’s agents access to the Property without charge and at all times for the purpose of Developer’s investigation and testing of the Property, including surveying and testing of soil and groundwater (“Developer’s Investigations”); provided, however, Developer shall not perform any invasive testing unless (a) HEDRA gives its prior written approval of Developer’s consultant that will perform the testing, which approval shall not be unreasonably withheld, conditioned or delayed, and (b) Developer gives HEDRA reasonable prior notice of such testing. HEDRA shall have the right to accompany Developer during any of Developer’s Investigations of the Property. Developer shall provide to HEDRA copies of all third-party, non-confidential written test results and reports conducted as part of Developer’s Investigations. Developer agrees to pay all of the costs and expenses associated with Developer’s Investigations, to cause to be released any lien on the Property arising as a result of Developer’s Investigations and to repair and restore, at Developer’s expense, any damage to the Property caused by Developer’s Investigations which, however, shall not include any duty by Developer to remediate any pre-existing environmental conditions discovered or disturbed at the Property. Developer shall indemnify and hold HEDRA and the Property harmless from all costs and liabilities, including, but not limited to, reasonable attorneys’ fees, arising from Developer’s Investigations. The indemnification obligations provided herein shall survive the termination or cancellation of this Agreement.
Sample 1
Developer’s Investigations. For a period of ninety (90) days after the New Effective Date (the "Due Diligence Period"), the UG shall allow Developer access to the UG Property for purposes of inspecting the UG Property, including the right to testing of same (the "Investigations"); provided, however, that: (i) Developer must schedule such Investigations with the UG; (ii) Developer shall provide the UG with a copy of any third party written reports resulting from the Investigations within thirty (30) days of completion of the Investigations; (iii) Developer and the UG (subject always to the Kansas Open Records Act,
Sample 1
Developer’s Investigations. For a period up to and including the Contingency Date, EDA shall allow Developer and Developer’s agents access to the Property without charge and at all times for the purpose of Developer’s investigation and testing of the Property, including surveying and testing of soil and groundwater (“Developer’s Investigations”). EDA shall have the right to accompany Developer during any of Developer’s Investigations of the Property. Developer shall provide to EDA copies of all third-party, non-confidential written test results and reports conducted as part of Developer’s Investigations. Xxxxxxxxx agrees to pay all of the costs and expenses associated with Developer’s Investigations, to cause to be released any lien on the Property arising as a result of Developer’s Investigations. Developer shall indemnify and hold EDA harmless from all costs and liabilities, including, but not limited to, reasonable attorneys’ fees, arising from Developer’s Investigations. The indemnification obligations provided herein shall survive the termination or cancellation of this Agreement.
Sample 1
Developer’s Investigations. Prior to Closing, the UG shall allow Developer access to the WCLB Property and shall use commercially reasonable efforts to secure access for Developer to the KDOT Property, and to include such access rights in the renewed Option Agreement, for purposes of inspecting the WCLB Property and the KDOT Property, including the right to non-invasive testing of same (the "Investigations"); provided, however, that:
Sample 1

Related to Developer’s Investigations

  • COMPLAINTS AND INVESTIGATIONS 1. This article applies to complaints or allegations made externally and not from normal supervisory activities.

  • Background Investigations OSC policy requires that background investigations be conducted on Contractor Staff who will have access to OSC’s IT systems, access to OSC confidential information/data, or routine access to any OSC facility. For purposes of this policy, “routine access” is defined as access to an OSC facility for five consecutive business days or 10 business days over the annual term of the engagement. Accordingly, with the signing of this Agreement, the Contractor certifies that it has or will conduct a background investigation on Staff to whom the policy applies within the 12 months prior to the Staff commencing Services under this Agreement. The Contractor agrees to undertake a background investigation of any new/replacement Staff during the term of the Agreement. At a minimum, background investigations shall include a review/evaluation of the following: • identity verification, including Social Security Number search; • employment eligibility, including verification of U.S. citizenship or legal immigration status where appropriate; • criminal history/court records (Federal, State and local for the past five years); • work experience/history for the past five years; • pertinent skills, qualifications, and education/professional credentials; and • references. The Contractor must obtain the consent of its Staff to allow OSC, upon request: (i) to review the background investigation records, including all supporting documentation, and (ii) to conduct its own background investigation. Only Staff who have passed the background investigation, and provided such consent shall be assigned to provide Services to OSC under this Agreement. During the term of the Agreement, and in accordance with Appendix A (Section 10, Records), the Contractor must maintain records related to the background investigations performed.

  • Complaints Investigation ‌ An employee who complains of harassment under the provisions of the Human Rights Code of British Columbia may refer the complaint to either one or other of the following processes:

  • Cooperation with Investigations You agree to cooperate with us in the investigation of unusual transactions, poor quality transmissions, and resolution of customer claims, including by providing, upon request and without further cost, any originals or copies of items deposited through the Service in your possession and your records relating to such items and transmissions.

  • Geotechnical Investigation Perform in accordance with the City Design Manual and other City requirements as designated in writing by the Director.

  • Accident Investigations When an accident occurs involving the equipment or personnel of a Supporting Agency, the Protecting Agency shall immediately notify the jurisdictional and supporting agencies. As soon as practical, the Protecting Agency shall initiate an investigation of the accident. The investigation shall be conducted by a team of representatives from the affected agencies, as appropriate. As appropriate, the Parties agree that the Protecting Agency will provide notification of the accident to the National Transportation Safety Board, or the Occupational Safety and Health Administration and other appropriate Agencies.

  • Grievance Investigations Where an employee has asked or is obliged to be represented by the Institute in relation to the presentation of a grievance and an employee acting on behalf of the Institute wishes to discuss the grievance with that employee, the employee and the representative of the employee will, where operational requirements permit, be given reasonable leave with pay for this purpose when the discussion takes place in the headquarters area of such employee and leave without pay when it takes place outside the headquarters area of such employee.

  • AUDITS AND INVESTIGATIONS 27.1 Each invoice paid by UNDP shall be subject to a post-payment audit by auditors, whether internal or external, of UNDP or by other authorized and qualified agents of UNDP at any time during the term of the Contract and for a period of three (3) years following the expiration or prior termination of the Contract.

  • Criminal Background Investigations For investigative Vendor Staff, Citizens will accept a copy of a current Class C Private Investigator license as proof that a criminal background check has been conducted for that investigator. For all other Vendor Staff, Vendor must provide Citizens with a copy of a criminal background check performed on such Vendor Staff dated within thirty (30) days of submission of the Vendor Staff to Citizens for qualification and credentialing review. Vendor shall use Exhibit D, Applicant Background Review Guide to as a guideline to determine eligibility of Vendor Staff to perform Services. The criminal background check must be updated every two (2) years thereafter. All background checks will be at Vendor’s expense and, unless otherwise approved in writing by Citizens’ Contract Manager, shall include but not be limited to: (a) state and federal felony convictions or pending adjudications; (b) state and federal misdemeanor convictions or pending adjudications; (c) any crimes in violation of the Violent Crime Control and Law Enforcement Act of 1995 or pending adjudications; and, (d) a seven (7) year minimum timeframe, extending as close as practicable to the date of Assignment to perform Services. Vendor will advise Citizens’ Contract Manager or designee if it knows of any Vendor Staff that has a criminal conviction (misdemeanor or felony), regardless of adjudication (adjudication withheld, a plea of guilty or nolo contendere, or a guilty verdict), within the last ten (10) years in any jurisdiction. Vendor shall not allow that individual to act as a Vendor Staff until Vendor determines whether that individual should be allowed to do so considering (a) the nature and gravity of the offense; (b) the amount of time that lapsed since the offense;

  • Employee Investigations (a) The Parties agree that in certain situations it may be in the best interest of both clients and employees that employees be reassigned or removed from all job sites during an investigation of conduct. In cases where an employee cannot be reassigned, then the employee shall be considered to be on leave of absence without loss of pay until the Employer has determined there is a prima facie case for imposing discipline.

Time is Money Join Law Insider Premium to draft better contracts faster.