TRANSNET’S OBLIGATIONS 8.1 Transnet undertakes to promptly comply with any reasonable request by the Supplier/Service Provider for information, including information concerning Transnet's operations and activities, that relates to the Goods/Services as may be necessary for the Supplier/Service Provider to provide the Goods/Services, but for no other purpose. However, Transnet's compliance with any request for information is subject to any internal security rules and requirements and subject to the observance by the Supplier/Service Provider of its confidentiality obligations under this Agreement.
8.2 The Supplier/Service Provider shall give Transnet reasonable notice of any information it requires.
8.3 Transnet agrees to provide the Supplier/Service Provider or its Personnel such access to and use of its facilities as is necessary to allow the Supplier/Service Provider to perform its obligations under this Agreement.
Student’s Obligations The Student agrees:
Client’s Obligations 4.1 The Client shall:
(a) ensure that the terms of the Order and any other information it provides in the Order Form are complete and accurate;
(b) co-operate with the Company in all matters relating to the Services;
(c) provide the Company, its employees, agents, consultants and subcontractors, with access to the Client’s premises, office accommodation and other facilities as reasonably required by the Company to provide the Services;
(d) provide the Company with such information and materials as the Company may reasonably require in order to supply the Services, and ensure that such information is complete and accurate in all material respects;
(e) prepare the Client’s premises for the supply of the Services;
(f) obtain and maintain all necessary licences, permissions and consents which may be required for the Services before the date on which the Services are to start;
(g) comply with all applicable laws, including health and safety laws; and
(h) keep all materials, equipment, documents and other property of the Company (Company Materials) at the Client’s premises in safe custody at its own risk, maintain the Company Materials in good condition until returned to the Company, and not dispose of or use the Company Materials other than in accordance with the Company’s written instructions or authorisation; and
(i) comply with any additional obligations as set out in the Order Form.
4.2 If the Company’s performance of any of its obligations under the Contract is prevented or delayed by any act or omission by the Client or failure by the Client to perform any relevant obligation (Client Default):
(a) without limiting or affecting any other right or remedy available to it, the Company shall have the right to suspend performance of the Services until the Client remedies the Client Default, and to rely on the Client Default to relieve it from the performance of any of its obligations in each case to the extent the Client Default prevents or delays the Company’s performance of any of its obligations;
(b) the Company shall not be liable for any costs or losses sustained or incurred by the Client arising directly or indirectly from the Company’s failure or delay to perform any of its obligations as set out in this Clause 4.2; and
(c) the Client shall reimburse the Company on written demand for any costs or losses sustained or incurred by the Company arising directly or indirectly from the Client Default.
4.3 The Client shall provide any Client Requirements to the Company in a timely manner in order to enable the Company to provide the Services, including, without limitation, all materials, assets, information and/or documentation of the Client which the Client has agreed to provide or which subsequently becomes necessary to provide in order to allow the Company to provide the Services.
4.4 In the event that the Client should fail to supply the Client Requirements at the time specified or in a timely manner as set out in the above clause 4.3, the Company shall not be held responsible for any consequences of such delays, and the Clients hereby holds harmless the Company from and against all claims, liabilities, losses, costs or expenses arising out of or in connection with such delays.
City’s Obligations A. Following the execution of this Agreement, the CITY shall begin efforts to implement the activities described in Article I of this Agreement. The failure by the CITY to develop and implement the activities described in Article I of this Agreement shall constitute a breach of this Agreement. The CITY understands and agrees that, in the event termination of this Agreement by CITY, or pursuant to Article V of this Agreement, the CITY shall reimburse the IDC the full amount of money paid by the IDC to the CITY.
B. In accordance with Chapter 2264 of the Texas Government Code, the CITY agrees not to knowingly employ an undocumented worker. During the term of this Agreement, the CITY shall notify the IDC of any complaint brought against CITY alleging that it has employed undocumented workers. If the CITY, or any branch, division or department of the CITY is convicted of a violation under 8 U.S.C. Section 1324a (f), the total amount of economic development grants it has received, together with interest at the rate of five percent (5%), shall be repaid by the CITY to the IDC not later than the one hundred twentieth (120th) day after the date the IDC becomes aware of and notifies the CITY of the violation. The CITY shall not be liable for a violation of Chapter 2264 by a subsidiary, affiliate, or franchisee, or by any person with whom the CITY contracts. The CITY shall reimburse the IDC the required amount within thirty (30) days of the termination of this Agreement. The CITY further certifies that CITY is following Texas Government Code Chapter 2252 (foreign terrorist organizations prohibited), Texas Government Code Chapter 2270 (boycott-Israel), and Texas Government Code Chapter 2274, (boycotts-energy company; discrimination – firearms entity or trade association).
C. The CITY shall keep and maintain complete and accurate records relating to its hiring and employment of persons, which is separate and identifiable from its other records, and shall make such records available for not less than three (3) years following termination of this Agreement. The IDC and its representatives shall be entitled to inspect said records during the term of this Agreement and for three (3) years thereafter, upon reasonable notice to the CITY. The CITY’s failure to comply with this provision will constitute a breach of the Agreement.
Developer’s Obligations 7.1.1 In consideration of the Rights hereby granted, the Developer shall pay to the Authority an annual fee of Rs. /- (Rupees only) (“Fee”) commencing from the 1st (first) anniversary of Appointed Date. The Fee is exclusive of GST and all other applicable taxes and shall be payable by the Developer at actual over and above the Fee. The Fee is payable to the Authority on or before 30 (thirty) days prior to the start of every year in advance as set out in Schedule 1 throughout the Agreement Period. During the Agreement Period the Fee shall be increased by 5% (five percent) every year over the previous year’s Fee on compounded basis.
7.1.2 The Developer should pay the Fee to the Authority notwithstanding the fact that, the development of Project Facilities is not completed within the specified period or Developer does not start the commercial operation of the Project. In other words, the Developer shall not be entitled to seek any reduction of Fee, claim, damages, compensation or any other consideration from the Authority on account of any reason.
7.1.3 Any delay in payment of the Fee shall attract an interest for the delayed period at the rate of SBI PLR plus 5% per annum on the outstanding amount, which shall be due from the date of such payment till the amount is realized by the Authority. In addition to the foregoing, any delay in payment of Fee beyond a period of 60 (sixty) days from the due date of such payment will be construed to be Material Breach under this Agreement.
Third Party Obligations 3.1. The THIRD PARTY shall:-
3.1.1. not divulge the Confidential Information to any party other than as provided for in this Confidentiality Agreement;
3.1.2. use the Confidential Information only for the purposes necessary in providing the services for which he is engaged by the AUTHORITY; and
3.1.3. make no commercial use of the Confidential Information or any part thereof.
3.2. Notwithstanding the foregoing, the THIRD PARTY shall be entitled to make any disclosure required by law of the Confidential Information and shall notify the AUTHORITY of so doing in accordance with the provisions of paragraph 6.
Supplier Obligations 7.1 The Supplier shall:
7.1.1 at all times allocate sufficient resources to supply the Services in accordance with the Contract;
7.1.2 provide and fulfil any ancillary or incidental service, function or responsibility not specified in the Service Specification where such service, function or responsibility is necessary for the proper performance of the relevant Services;
7.1.3 obtain, and maintain throughout the duration of the Contract, all the consents, approvals, licences and permissions (statutory, regulatory, contractual or otherwise) it may require and which are necessary for the provision of the Services or performance of any other obligation under this Contract;
7.1.4 ensure the Supplier Assets used in the performance of the Services will be free of all encumbrances (except as agreed in writing with the Authority);
7.1.5 ensure that in the performance of its obligations under the Contract it does not disrupt the operations of each Commissioning Body and their respective Personnel;
7.1.6 ensure that any documentation, information and training provided to each Commissioning Body under this Contract (including in relation to the use of the Website) is comprehensive, accurate and prepared in accordance with Good Industry Practice;
7.1.7 co-operate with the Other Supplier(s) and provide reasonable information (including any documentation), advice and assistance in connection with the Services to the Other Supplier(s) including to enable such Other Supplier(s) to provide services to the respective Commissioning Bodies and, on the expiry or termination of this Contract for any reason, to enable the timely transition of the Services (or any of them) to the respective Commissioning Bodies and/or to any Replacement Supplier;
7.1.8 to the extent it is legally able to do so, hold on trust for the sole benefit of the Authority, all warranties and indemnities provided by third parties or any Sub- contractor in respect of any Deliverables and/or the Services and, where any such warranties are held on trust, at its cost enforce such warranties in accordance with any reasonable directions that the Authority may notify from time to time to the Supplier;
7.1.9 unless it is unable to do so, assign to the Authority on the Authority’s written request and at the cost of the Supplier any such warranties and/or indemnities as are referred to in Clause 7.1.8;
7.1.10 provide each Commissioning Body with such advice and assistance as that Commissioning Body may reasonably require during the Contract Period in respect of the supply of the Services;
7.1.11 gather, collate and provide such information and co-operation as the Authority may reasonably request for the purposes of ascertaining the Supplier’s compliance with its obligations under the Contract;
7.1.12 notify the Authority of any circumstances suggesting that a change of Control of the Supplier is planned, in contemplation or has taken place;
7.1.13 notify the Authority in writing of any material detrimental change in the financial standing and/or any change in the credit rating of the Supplier;
7.1.14 subject to Clause 33.6, notify the Authority in writing within ten (10) Working Days of their occurrence, of any actions, suits or proceedings or regulatory investigations before any court or administrative body or arbitration tribunal pending or, to its knowledge, threatened against it that might affect its ability to perform its obligations under the Contract; and
7.1.15 ensure that neither it, nor any of its Affiliates or Personnel, bring any Commissioning Body into disrepute by engaging in any act or omission which is reasonably likely to diminish the trust that the public places in that Commissioning Body, regardless of whether or not such act or omission is related to the Supplier’s obligations under this Contract.
Customer’s Obligations The Customer shall:
(a) provide the Supplier with:
(i) all necessary co-operation in relation to this agreement; and
(ii) all necessary access to such information as may be required by the Supplier; in order to render the Services, including but not limited to Customer Data, security access information and configuration services;
(b) comply with all applicable laws and regulations with respect to its activities under this agreement;
(c) carry out all other Customer responsibilities set out in this agreement in a timely and efficient manner. In the event of any delays in the Customer's provision of such assistance as agreed by the parties, the Supplier may adjust any agreed timetable or delivery schedule as reasonably necessary;
(d) ensure that the Authorised Users use the Services and the Documentation in accordance with the terms and conditions of this agreement and shall be responsible for any Authorised User’s breach of this agreement;
(e) obtain and shall maintain all necessary licences, consents, and permissions necessary for the Supplier, its contractors and agents to perform their obligations under this agreement, including without limitation the Services;
(f) ensure that its network and systems comply with the relevant specifications provided by the Supplier from time to time; and
(g) be solely responsible for procuring and maintaining its network connections and telecommunications links from its systems to the Supplier’s data centres, and all problems, conditions, delays, delivery failures and all other loss or damage arising from or relating to the Customer's network connections or telecommunications links or caused by the internet.
SUPPLIER’S OBLIGATIONS 4.2.1 The Supplier shall be responsible for implementing all the necessary resources for the performance of its obligations under the Contract, with the exception of those specifically mentionedin the Contractas beingunder the responsibility of the Purchaser. The Supplier shall haveall of thematerials andtoolsneededfor theperformanceof the Contractandshall allocate qualified staff in sufficient numbers to perform the Contract within the contractual deadline. The Supplier shall ensureappropriatepersonneltraining andqualification andsubmitanyproof relating to such qualification upon Purchaser’s request. Within seven (7) days, at the latest, of the Contract coming into force, the Supplier shall appoint a staff member as aprojectmanager and shall inform the Purchaser accordingly. The project manager shall plan, coordinate and monitor all the Supply’sneedsin compliancewith the Contractandthe Good Industry Practices andshall be the Supplier’s contact person for the Purchaser.
4.2.2 The Supplier shall request from the Purchaser in a timely manner, any approvals and instructions needed for the correct performance of the Contract. If applicable, the Purchaser shall grant access to the site where the Supply is to be performed (the “Site”) and /or make available to the Supplier the materials and/or perform the works identified in the Contract.
4.2.3 The Supplier shall promptly remedy or shall ensure that its subcontractors promptly remedy any defects relating to the Supply noted during the abovementioned visits as well as any defect notified to it by the Purchaser concerning its performance.
4.2.4 The Supplier shall ensure that the Supply provided are fit for the purposes that may reasonablybeinferred from the Contractandinaccordancewith the timetableforperformance defined in the Contract. In any event the Supplier commitshimself toachieveperformance and results stipulated in the Contract. The performance deadlinesmay only be extended or reduced through an amendment to the Contract, in accordance with the provisions of Article
5.1. The Supply shall be delivered in a state of full completion with the complete Documentation associated therewith as well as all instructions, recommendations and other indications necessary in order for them to be used correctly and under the appropriate safety conditions. “Documentation” shall mean any operation and maintenance manuals, drawings, calculations, technical data, logic diagrams, progress reports, quality documentation, conformity certificates, test reports, bill of lading, certificates of origin, export control classification list number as per any applicable export regulation - such as (i) the European Council Regulation 428/2009 (as amended), (ii) the U.S. Export Administration Regulations (“EAR”), (iii) percentage of U.S. origin content, (iv) U.S. Export Control Classification Number (“ECCN”), (v) U.S. Munitions List category (“USML”),(vi) (if applicable) export authorizations and licenses, and/or (vii) Harmonized Tariff Code - and any such other documents required under the Contract and/or applicable laws. The Supplier shall also furnish such programme of design, manufacture and delivery as the Purchaser may reasonably require. If so required by the Purchaser, the Supplier shall submit any such Documentation to the Purchaser with sufficient time for review and approval. Where the Documentation provided by the Supplier is not compliant with Purchaser’s contractual requirements, the Supplier must make the necessary modifications, and indemnify the Purchaser for any costs, liabilities or penalties incurred by the Purchaser due to the delays or non-compliance in Documentation delivered by the Supplier and shall not be entitled to an adjustment of the delivery schedule in case of any revision.
Contractor Obligations After receipt of the Notice of Termination and except as otherwise directed by the State, the Contractor shall immediately proceed to:
a. To the extent specified in the Notice of Termination, stop work under the Contract on the date specified.
b. Place no further orders or subcontracts for materials, services, and/or facilities except as may be necessary for completion of such portion(s) of the work under the Contract as is (are) not terminated.
c. Terminate and cancel any orders or subcontracts for related to the services, except as may be necessary for completion of such portion(s) of the work under the Contract as is (are) not terminated.
d. Transfer to the State all completed or partially completed plans, drawings, information, and other property which, if the Contract had been completed, would be required to be furnished to the State.
e. Take other action as may be necessary or as directed by the State for the protection and preservation of the property related to the contract which is in the possession of the contractor and in which the State has or may acquire any interest.
f. Make available to the State all cost and other records relevant to a determination of an equitable settlement.
