Provisions of General Application (a) All accounting terms not specifically defined herein shall be construed in accordance with GAAP.
(b) The terms defined in this Article include the plural as well as the singular.
(c) The words "herein," "hereof" and "hereunder" and other words of similar import refer to this Agreement as a whole. All references to Articles and Sections shall be deemed to refer to Articles and Sections of this Agreement.
Other Provisions of General Application Section 7.1 Notices to the Rights Agent, Parent and the Stockholders’ Representative. Any notice, request, instruction or other document to be given hereunder by any party to the others shall be in writing and delivered personally or sent by registered or certified mail, postage prepaid, by electronic mail (except with respect to the Rights Agent), by facsimile transmission only with respect to the Rights Agent or overnight courier, provided that with respect to notices deliverable to the Stockholders’ Representative, such notices shall be delivered solely via electronic mail or facsimile: If to Parent or the Company: Eros International Plc First Names House Victoria Road Xxxxxxx Isle of Man IM2 4DF British Isles Attention: Xxxx Xxxxxxx, Chief Corporate and Strategy Officer Email: xxxx.xxxxxxx@xxxxxxxx.xxx with a copy (which shall not constitute notice) to: Xxxxxx, Xxxx & Xxxxxxxx LLP 000 Xxxxx Xxxxx Xxxxxx Xxx Xxxxxxx, Xxxxxxxxxx 00000-0000 Attention: Xxxxx Xxxxxx Xxxxx Xxxxxx Email: xxxxxxx@xxxxxxxxxx.xxx xxxxxxx@xxxxxxxxxx.xxx If to the Rights Agent: Computershare Trust Company, N.A., Computershare Inc. 000 Xxxxxx Xxxxxx Canton, MA 02021 Attention: Client Services Facsimile: (000) 000-0000 If to the Stockholders’ Representative: Fortis Advisors LLC Attention: Notices Department (Project World Cup) Email: xxxxxxx@xxxxxxxxx.xxx Facsimile: (000) 000-0000 with a copy (which shall not constitute notice) to: Xxxxxxxx & Xxxxx LLP 000 Xxxxx Xxxxxx Xxxxxx, Xxxxx 0000 Xxx Xxxxxxx, Xxxxxxxxxx 00000 Attention: Xxxx X. Xxxxxx, P.C. Email: xxxx.xxxxxx@xxxxxxxx.xxx or to such other persons or addresses as may be designated in writing by the party to receive such notice as provided above. Any notice, request, instruction or other document given as provided above shall be deemed given to the receiving party upon actual receipt, if delivered personally; three (3) business days after deposit in the mail, if sent by registered or certified mail; upon confirmation of successful transmission if sent by electronic mail; or on the next business day after deposit with an overnight courier, if sent by an overnight courier.
General Contract Provisions Any and all Schedules to this Agreement form a part hereof. No amendment, waiver, discharge or release of this Agreement shall be binding or enforceable unless made in writing signed by all of the parties hereto. Time is and shall remain of the essence under and pursuant to this Agreement; provided that the time for performing or completing any matter under or pursuant to this Agreement may be extended or abridged by an agreement in writing by the parties or their respective solicitors. Failure by any party to strictly enforce any provisions hereof shall not operate as a waiver or limitation of such party's rights hereunder in respect of any subsequent default. If any provision of this Agreement or the application thereof to any person or circumstance is to any extent held or rendered invalid, unenforceable or illegal, same shall be considered separate and severable herefrom and all other provisions of this Agreement shall remain in full force and effect and be binding upon the parties hereof. The headings set forth in this Agreement are inserted for convenience and reference only and shall in no way define or limit the intent or interpretation of any of the provisions hereof. Wherever in this Agreement any subject matter is described as including specifically described persons, things, events or other items, unless expressly stated to the contrary, the word “including” or any other derivation or variation of that word means, as the case may be, “including, without limitation,” or “including, without limiting the generality of the foregoing,” or such derivation or variation thereof as required by the context. This Agreement shall be read and construed with all changes of gender and number of the party or parties referred to in each case as required by the context, and the covenants and agreements of each party shall be deemed to be joint and several where such party is more than one person, firm or corporation. With respect to each party which is a partnership, each person who is presently a partner of such partnership and each person who becomes a partner of such partnership shall be and continue to be jointly and severally liable for all covenants and agreements of such party notwithstanding that any such person subsequently ceases to be a partner of such partnership, subject to and only to the extent of the limited liability of any such person that is a limited partner of such partnership.
DOMESTIC PREFERENCES FOR PROCUREMENTS To the extent applicable, Supplier certifies that during the term of this Contract will comply with applicable requirements of 2 C.F.R. § 200.322.
Concerning Applicable Provisions of Law, etc This Agreement shall be subject to all applicable provisions of law, including the applicable provisions of the 1940 Act and to the extent that any provisions herein contained conflict with any such applicable provisions of law, the latter shall control.
200 Domestic Preferences for Procurements As appropriate and to the extent consistent with law, the non-Federal entity should, to the greatest extent practicable under a Federal award, provide a preference for the purchase, acquisition, or use of goods, products, or materials produced in the United States (including but not limited to iron, aluminum, steel, cement, and other manufactured products). The requirements of this section must be included in all subawards including all contracts and purchase orders for work or products under this award. For purposes of 2 CFR Part 200.322, “Produced in the United States” means, for iron and steel products, that all manufacturing processes, from the initial melting stag through the application of coatings, occurred in the United States. Moreover, for purposes of 2 CFR Part 200.322, “Manufactured products” means items and construction materials composed in whole or in part of non-ferrous metals such as aluminum, plastics and polymer-based products such as polyvinyl chloride pipe, aggregates such as concrete, glass, including optical fiber, and lumber. Pursuant to the above, when federal funds are expended by ESC Region 8 and TIPS Members, Vendor certifies that to the greatest extent practicable Vendor will provide a preference for the purchase, acquisition, or use of goods, products, or materials produced in the United States (including but not limited to iron, aluminum, steel, cement, and other manufactured products). Does vendor agree? Yes
Provisions governing staff and subcontractors A. To require any subcontractor to execute documents that binds the subcontractor to comply with the provisions of this Contract. Subcontractor means an individual or entity to which the Contractor has contracted with or delegated some of its management functions or responsibilities of providing all or a part of the services required of the Contractor under this Contract.
B. That it is responsible for the behavior of its staff and subcontractors to ensure a violence-free contractual relationship. The Contractor understands that any remarks, gestures or actions toward HHSC employees, volunteers or clients that carry an implied threat of any kind, even if intended to be in jest, will be taken seriously and may lead to corrective action, up to and including terminating this contractor.
C. To comply with the requirements of the Immigration Reform and Control Act of 1986 regarding employment verification and retention of verification forms for an individual hired on or after November 6, 1986, who will perform any labor or services under this Contract.
D. To certify and ensure that it utilizes and will continue to utilize, for the term of this Contract, the U. S. Department of Homeland Security's e- Verify system to determine the eligibility of:
1. all people employed during the Contract term to perform duties within Texas; and
2. all people (including subcontractors).
E. That representatives of HHSC, AG-MFCU and HHS may conduct interviews of Contractor personnel, subcontractors and their personnel, witnesses, and clients without a Contractor's representative present unless the person interviewed voluntarily requests that the representative be present. The Contractor must not coerce its personnel, subcontractors and their personnel, witnesses, or clients to accept representation by the Contractor, and the Contractor agrees that no retaliation will occur to a person who denies the Contractor's offer of representation. Nothing in the Contract limits a person's right to counsel of his or her choice. Requests for interviews are to be complied with in the form and the manner requested. The Contractor must ensure by contract or other means that its personnel and subcontractors cooperate fully in any investigation conducted by representatives of HHSC, AG-MFCU and HHS.
F. That if it is a Home and Community Support Services agency ("HCSSA"), the Contractor will hire Personal Assistance Services and Community Support Services providers chosen by the client or the client's legally authorized representative, if requested, and provided the individual who will provide the services:
1. meets minimum qualifications for the service;
2. is willing to be employed as an attendant by the Contractor; and
3. is willing, and determined competent by the Contractor, to deliver the service(s) according to the client's individual service plan.
Combinations and Split-ups of Receipts Upon surrender of a Receipt or Receipts at the Depositary Office or such other office as the Depositary may designate for the purpose of effecting a split-up or combination of Receipts, subject to the terms and conditions of this Deposit Agreement, the Depositary shall execute and deliver a new Receipt or Receipts in the authorized denominations requested evidencing the same aggregate number of Depositary Shares evidenced by the Receipt or Receipts surrendered.
File Naming Conventions Files will be named according to the following convention: {gTLD}_{YYYY-MM-DD}_{type}_S{#}_R{rev}.{ext} where: {gTLD} is replaced with the gTLD name; in case of an IDN-TLD, the ASCII-compatible form (A-Label) must be used; {YYYY-MM-DD} is replaced by the date corresponding to the time used as a timeline watermark for the transactions; i.e. for the Full Deposit corresponding to 2009-08-02T00:00Z, the string to be used would be “2009-08-02”; {type} is replaced by: “full”, if the data represents a Full Deposit; “diff”, if the data represents a Differential Deposit; “thin”, if the data represents a Bulk Registration Data Access file, as specified in Section 3 of Specification 4; {#} is replaced by the position of the file in a series of files, beginning with “1”; in case of a lone file, this must be replaced by “1”. {rev} is replaced by the number of revision (or resend) of the file beginning with “0”: {ext} is replaced by “sig” if it is a digital signature file of the quasi-homonymous file. Otherwise it is replaced by “ryde”.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
