Directed Changes Sample Clauses

Directed Changes. The Buyer’s Authorized Procurement Representative may from time to time direct changes, in writing, within the general scope of any Contract or Statement of Work. Seller shall comply immediately with such direction and avoid unnecessary costs related thereto.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Directed Changes. In the event that, under the Turnkey Contract, the Aggregate Price is increased as a result of Directed Changes (as those terms are defined in the Turnkey Contract), the Parties shall negotiate in good faith an amendment to this Agreement to increase the Commitment Amount accordingly.
Sample 1Sample 2
Directed Changes. The Buyer’s Authorized Procurement Representative may from time to time direct changes, in writing, within the general scope of any Contract in one or more of the following: (i) Specifications, technical requirements and descriptions, specifications, statements of work, drawings or designs; (ii) shipment or packing methods; (iii) place of delivery, inspection, or acceptance; (iv) reasonable adjustments in quantities or delivery schedules or both; and (v) amount of any Buyer-furnished property. Seller shall comply immediately with such direction and avoid unnecessary costs related thereto.
Sample 1Sample 2
Directed Changes. The Authorized Boeing Representative may from time to time direct changes, in writing, within the general scope of any Purchase Contract in one or more of the following: (i) technical requirements and descriptions, specifications, statements of work, drawings, or designs; (ii) shipment or packing methods; (iii) place of delivery, inspection, or acceptance; (iv) reasonable adjustments in quantities or delivery schedules or both; and (v) amount of any Boeing furnished property. Supplier shall comply immediately with such direction and avoid unnecessary costs related thereto.
Sample 1
Directed Changes. If the NTP is issued for changes prior to settlement of price and/or time, submit proposed schedule revisions to the Contracting Officer within 2 weeks of the NTP being issued. The Contracting Officer will approve proposed revisions to the schedule prior to inclusion of those changes within the project schedule. If the Contractor fails to submit the proposed revisions, the Contracting Officer may furnish the Contractor with suggested revisions to the project schedule. Include these revisions in the project schedule until revisions are submitted, and final changes and impacts have been negotiated. If the Contractor has any objections to the revisions furnished by the Contracting Officer, advise the Contracting Officer within 2 weeks of receipt of the revisions. Regardless of the objections, continue to update the schedule with the Contracting Officer's revisions until a mutual agreement in the revisions is reached. If the Contractor fails to submit alternative revisions within 2 weeks of receipt of the Contracting Officer's proposed revisions, the Contractor will be deemed to have concurred with the Contracting Officer's proposed revisions. The proposed revisions will then be the basis for an equitable adjustment for performance of the work.
Sample 1

Related to Directed Changes

  • Product Changes Vocera shall have the right, in its absolute discretion, without liability to End User, to update to provide new functionality or otherwise change the design of any Product or to discontinue the manufacture or sale of any Product. Vocera shall notify End User at least 90 days prior to the delivery of any Product which incorporates a change that adversely affects form, fit or function (“Material Change”). Vocera shall also notify End User at least 90 days prior to the discontinuance of manufacture of any Product. Notification will be made as soon as reasonably practical for changes associated with regulatory or health and safety issues.

  • Program Changes Contractor agrees to inform the County of any alteration in program or service delivery at least thirty (30) days prior to the implementation of the change, or as soon as reasonably feasible.

  • Staffing Changes The Director’s prior written approval is required for the Consultant to remove, replace or add to any of its staffing identified in Attachment B of an Approved Service Order.

  • Project Changes 1.8.1. All changes shall be administered per the UGC. 1.8.2. Upon authorization by the Owner, the Owner or Architect/Engineer will prepare and issue all changes to the Contract affecting cost, scope and/or time as a formal Change Order to the Contract on the standard University of Texas MD Xxxxxxxx Cancer Center Change Order form. The Change Order may include separate change issues, identified as Change Proposals and field orders. 1.8.3. Upon authorization by the Owner, Change Proposals may be issued to the Architect/Engineer for pricing by the Contractor. Contractor shall submit pricing to the Owner within twenty-one (21) days and pricing shall be indicated on the standard Owner "Change in Work Cost Analysis" ("Cost Analysis") form provided in the Pre-Construction Conference Brochure. Contractor may not include a Change Proposal within a Change Order unless the Owner has accepted the Change Proposal. 1.8.3.1. The Contractor shall summarize all costs for each change at each level of subcontractor and supplier by preparing the "Cost Analysis" form, and shall provide each subcontractor's cost summary on separate "Cost Analysis" forms as backup. Additional support documentation from both the Contractor and Contractor’s subcontractors is encouraged, but such will not replace use of the standard form. 1.8.3.2. When the Contractor believes it is entitled to a time extension, Contractor shall so state as part of Contractor’s response to the Change Proposal, including a justifica- tion for a time extension. Owner may grant time extensions only if a Change Proposal affects the activities on the Longest Path of an Owner approved Work Progress Schedule; i.e., when the Work impacts the "Contract Substantial Completion Date". 1.8.3.3. If the Owner’s Project Manager and Contractor cannot mutually agree upon a fair and reasonable cost and time settlement, the Owner’s Project Manager may: 1) Reject the quotation and void the Change Proposal, 2) Issue instructions to the Contractor to proceed on a time and material basis for a price to be determined later not to exceed a fixed maximum dollar and time, or 3) Issue a Unilateral Change Order. 1.8.3.4. The Owner’s Construction Inspector and/or Owner’s Project Manager may issue field orders directly to the Contractor for minor changes to the Contract, which can be negotiated in the field. Pricing backup is at the discretion of the Owner’s Construction Inspector, but pricing backup is required for any field order, the pricing backup is to be outlined on the "Cost Analysis" form. When the Owner and Contractor have signed the field order, the Work is authorized and the field order may be included in the next Change Order. 1.8.4. Request for payment for Change Order work may be submitted only after the Change Order has been fully executed.

  • Shift Changes When an employee is assigned to a specific shift and that assignment is changed, the employee shall be given seven (7) calendar days’ notice prior to the change.

  • Business Changes Change in any material respect the nature of the business of the Borrower or its Subsidiaries as conducted on the Effective Date.

  • Interim Changes Since the date of its balance sheets, except as set forth in Exhibit C, there have been no (1) changes in financial condition, assets, liabilities or business of Amalgamated which, in the aggregate, have been materially adverse; (2) damages, destruction or losses of or to property of Amalgamated, payments of any dividend or other distribution in respect of any class of stock of Amalgamated, or any direct or indirect redemption, purchase or other acquisition of any class of any such stock; or (3) increases paid or agreed to in the compensation, retirement benefits or other commitments to its employees.

  • Contract Changes Changes may not be made in the terms and conditions of this contract without the agreement and written permission of the Director of Residence Life or the Director’s designee.

  • Benchmark Replacement Conforming Changes In connection with the use, administration, adoption or implementation of a Benchmark Replacement, the Administrative Agent will have the right to make Conforming Changes from time to time and, notwithstanding anything to the contrary herein or in any other Loan Document, any amendments implementing such Conforming Changes will become effective without any further action or consent of any other party to this Agreement or any other Loan Document.

  • Service Changes PBI may modify its Service by giving written notice to you (a “Service Change Notice”), which will state whether the change is material. After receiving a Service Change Notice, if the change is material, you may terminate Service by giving us a termination notice at the address indicated in Section 21 or you may create a case at xxxxxxxxxxx.xxx/xx/xxxxxxx-xx.xxxx (follow the instructions under “how to create a case”).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!