Project Title. Enter the title of the exhibition.
Project Title. Project No.: Contract Number: Date: Contractor: Change Order Request No.: Description of Change Order Request (Attach additional sheets as needed) Reason for Change Order Request: Description of Work to be Performed: Requested Change to Contract Sum: ❑ No cost change: N/A ❑ Increase cost by $ ❑ Decrease cost by $ Request for Extension of Contract Time (check one): ❑ No Change to Contract Time ❑ Time Extension Requested for days* o days Excusable Delay o days Compensable Delay ❑ Decrease time by days * Include all information and documentation required by Section 8.5 of the Contract General Conditions. Basis for requested change in cost: ❑ Unit pricing ❑ Lump sum: $ _ ❑ Time and Materials not to exceed: * $ _ ❑ Compensable Delay Costs: $ ❑ Other: _ * Final value shall not exceed amount shown without additional written CO authorization. Complete Time and Materials Breakdown on following page. Reference Documents:* RFI: ASI: Field Order: Specifications: Plans: Other: (specify): * Provide specific number/section/sheet references as applicable Contract Change Order Request – continued Line Time and Materials Breakdown (Reference General Conditions, e.g. Sections 1 and 7.2, for Allowable Costs and markup) Added Credit All lines shall be filled in (zero values acceptable) CONTRACTOR’S WORK
Project Title. KNOW ALL MEN BY THESE PRESENTS: That as principal (hereinafter referred to (Legal Name and Address of the Contractor) as "Contractor"), and as surety (hereinafter referred to (Legal Title and Address of Surety) as "Surety"), are held and firmly bound unto the Board of Regents of the University System of Georgia as Obligee (hereinafter referred to as "Owner") in the amount of and No/100 Dollars ($ .00), to which payment Contractor and Surety bind Themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents.
Project Title. KNOW ALL MEN BY THESE PRESENTS: That as Principal (hereinafter referred to as the (Legal Title and Address of the Contractor) "Principal") and as Surety (hereinafter referred ( Legal Name and Address of the Surety) to as "Surety"), are held and firmly bound unto the BOARD OF REGENTS OF THE UNIVERSITY SYSTEM OF GEORGIA as Obligee (hereinafter referred to as "Owner") for the use and benefit of claimants defined, hereinafter in the amount of Dollars ($ )to which payment Principal and Surety bind themselves, their heirs, executors, administrators, successors and assigns jointly and severally, firmly by these presents.
Project Title. To be determined on a per Project Scope basis and identified in the Project Authorization letter.
Project Title. Please choose a title that explains the project. For example, “Updated Equipment for Commercial Fishing Enterprise”. Project Objective. List the expected results in two or three sentences or bullets. For example, “The project will result in increased revenue or jobs,” or “The project will add value to the product”, or “the project will result in improved fishing with new nets and gear”.
Project Title. For and in consideration of the mutual covenants herein contained, the parties hereto agree as follows:
Project Title. [Insert title and summary details of Project] The Project is further detailed in Schedule 1, including the requirements for achievement of each Milestone.
Project Title. [Provide a concise title for the project] Requesting Entity: [Name of the WRESA or Coop Member entity requesting the services] Requestor Contact Information: [Name, E-mail and Phone Number for WRESA or Coop Member contact person requesting facilitating the request for services] Proposal Submission Deadline: [Indicate the deadline by which proposals are due]
Project Title. [Title of Project] (hereinafter “the Project”)
