Maintenance during Construction Period (i) During the Construction Period, the Contractor shall maintain, at its cost, the existing lane(s) of the Project Highway so that the traffic worthiness and safety thereof are at no time materially inferior as compared to their condition on Appointed Date, and shall undertake the necessary repair and maintenance works for this purpose; provided that the Contractor may, at its cost, interrupt and divert the flow of traffic if such interruption and diversion is necessary for the efficient progress of Works and conforms to Good Industry Practice; provided further that such interruption and diversion shall be undertaken by the Contractor only with the prior written approval of the Authority’s Engineer which approval shall not be unreasonably withheld. For the avoidance of doubt, it is agreed that the Contractor shall at all times be responsible for ensuring safe operation of the Project Highway. It is further agreed that in the event the Project includes construction of a bypass or tunnel and realignment of the existing carriageway, the Contractor shall maintain the existing highway in such sections until the new Works are open to traffic.
(ii) Notwithstanding anything to the contrary contained in this Agreement, in the event of default by the Contractor in discharging the obligations specified in Clause 10.4 (i) above, the Authority shall get these maintenance works completed in the manner recommended by the Authority’s Engineer to avoid public inconvenience at the risk and cost of the Contractor in order to keep the road in traffic worthy condition.
Delays during construction Without prejudice to the provisions of Clause 10.3 (ii), in the event the Contractor does not achieve any of the Project Milestones or the Authority’s Engineer shall have reasonably determined that the rate of progress of Works is such that Completion of the Project Highway is not likely to be achieved by the end of the Scheduled Completion Date, it shall notify the same to the Contractor, and the Contractor shall, within 15 (fifteen) days of such notice, by a communication inform the Authority’s Engineer in reasonable detail about the steps it proposes to take to expedite progress and the period within which it shall achieve the Project Completion Date.
During Construction Upon request of the Owner the Contractor shall submit written proposals for unit prices to be applied in the event Change Order Work is authorized by the Owner to be performed under Case (b).
Withdrawals during Concession Period 27.3.1 The Concessionaire shall, at the time of opening the Escrow Account, give irrevocable instructions, by way of an Escrow Agreement, to the Escrow Bank instructing, inter alia, that deposits in the Escrow Account shall be appropriated in the following order every month, or at shorter intervals as necessary, and if not due in a month then appropriated proportionately in such month and retained in the Escrow Account and paid out therefrom in the month when due:
(a) all taxes due and payable by the Concessionaire for and in respect of the Project;
(b) all payments relating to construction of the Project, subject to and in accordance with the conditions, if any, set forth in the Financing Agreements;
(c) O&M Expenses, subject to the ceiling, if any, set forth in the Financing Agreements;
(d) O&M Expenses and other costs and expenses incurred by the Authority in accordance with the provisions of this Agreement, and certified by the Authority as due and payable to it;
(e) Concession Fee or Annual Concession Fee, as the case may be, due and payable to the Authority;
(f) monthly proportionate provision of Debt Service due in an Accounting Year;
(g) all payments and Damages certified by the Authority as due and payable to it by the Concessionaire;
(h) monthly proportionate provision of debt service payments due in an Accounting Year in respect of Subordinated Debt;
(i) any reserve requirements set forth in the Financing Agreements; and
(j) balance, if any, in accordance with the instructions of the Concessionaire.
27.3.2 The Concessionaire shall not in any manner modify the order of payment specified in Clause 27.3.1, except with the prior written approval of the Authority.
PRE-CONSTRUCTION PHASE FEE The Pre-Construction Phase Fee is the total compensation payable to Contractor for the performance of Pre-Construction Phase Services, except for Additional Pre-Construction Phase Services approved in advance and in writing by Owner. The Pre-Construction Phase Fee shall be a lump sum amount based on the AACC established in this Agreement.
6.1 Except as specifically allowed by Owner, Contractor shall not be entitled to any increase in the Pre-Construction Phase Fee for any costs, expenses, liabilities or other obligations arising from the performance of Pre-Construction Phase Services.
6.2 Costs associated with the following items are specifically, but not exclusively, included in the establishment of the Pre-Construction Phase Fee: profit and profit sharing; general overhead; salaries and labor; housing and relocation; estimating, scheduling and information management systems and software; contract administration; office expenses; printing and copying; consulting fees; legal or accounting fees; cost of money; taxes; insurance premiums and deductibles; bond costs; purchase or rental of equipment; utilities; travel; per diem; fines or penalties; and damage awards.
6.3 If the scope of the Pre-Construction Phase Services is changed materially, the Pre- Construction Phase Fee shall be equitably adjusted. If the AACC is changed materially before acceptance of the GMP Proposal, the Pre-Construction Phase Fee shall be adjusted in writing in proportion to the change in the AACC. There shall be no adjustments in the Pre-Construction Phase Fee following acceptance of the GMP Proposal.
6.4 For Additional Pre-Construction Phase Services that are approved in advance and in writing by Owner, Contractor shall be entitled to additional compensation computed as follows:
6.4.1 A pre-established lump sum amount; or
6.4.2 The hourly cost of Contractor’s employees or consultants who actually perform the Additional Services based on the employee’s Worker Wage Rate or prorated Monthly Rate plus the actual cost of allowable expenses incurred in the performance of the Additional Pre-Construction Phase Services, plus an overhead and profit markup of ten percent (10%) of the total cost; or
6.4.3 As otherwise agreed in advance and in writing.
Disbursements from Replacement Reserve Account (a) Lender shall make disbursements from the Replacement Reserve Account to pay Borrower only for the costs of the Replacements. Lender shall not be obligated to make disbursements from the Replacement Reserve Account to reimburse Borrower for the costs of routine maintenance to the Property or for costs which are to be reimbursed from the Required Repair Fund (if any).
(b) Lender shall, upon written request from Borrower and satisfaction of the requirements set forth in this Section 7.3.2, disburse to Borrower amounts from the Replacement Reserve Account necessary to pay for the actual approved costs of Replacements or to reimburse Borrower therefor, upon completion of such Replacements (or, upon partial completion in the case of Replacements made pursuant to Section 7.3.2(f)) as determined by Lender. In no event shall Lender be obligated to disburse funds from the Replacement Reserve Account if a Default or an Event of Default exists.
(c) Each request for disbursement from the Replacement Reserve Account shall be in a form specified or approved by Lender and shall specify (i) the specific Replacements for which the disbursement is requested, (ii) the quantity and price of each item purchased, if the Replacement includes the purchase or replacement of specific items, (iii) the price of all materials (grouped by type or category) used in any Replacement other than the purchase or replacement of specific items, and (iv) the cost of all contracted labor or other services applicable to each Replacement for which such request for disbursement is made. With each request Borrower shall certify that all Replacements have been made in accordance with all applicable Legal Requirements of any Governmental Authority having jurisdiction over the Property to which the Replacements are being provided and, unless Lender has agreed to issue joint checks as described below, each request shall include evidence of payment of all such amounts. Each request for disbursement shall include copies of invoices for all items or materials purchased and all contracted labor or services provided. Except as provided in Section 7.3.2(e), each request for disbursement from the Replacement Reserve Account shall be made only after completion of the Replacement for which disbursement is requested. Borrower shall provide Lender evidence of completion satisfactory to Lender in its reasonable judgment.
(d) Borrower shall pay all invoices in connection with the Replacements with respect to which a disbursement is requested prior to submitting such request for disbursement from the Replacement Reserve Account or, at the request of Borrower, Lender will issue joint checks, payable to Borrower and the contractor, supplier, materialman, mechanic, subcontractor or other party to whom payment is due in connection with a Replacement. In the case of payments made by joint check, Lender may require a waiver of lien from each Person receiving payment prior to Lender's disbursement from the Replacement Reserve Account. In addition, as a condition to any disbursement, Lender may require Borrower to obtain lien waivers from each contractor, supplier, materialman, mechanic or subcontractor who receives payment in an amount equal to or greater than $100,000 for completion of its work or delivery of its materials. Any lien waiver delivered hereunder shall conform to the requirements of applicable law and shall cover all work performed and materials supplied (including equipment and fixtures) for the Property by that contractor, supplier, subcontractor, mechanic or materialman through the date covered by the current reimbursement request (or, in the event that payment to such contractor, supplier, subcontractor, mechanic or materialmen is to be made by a joint check, the release of lien shall be effective through the date covered by the previous release of funds request).
(e) If (i) the cost of a Replacement exceeds $100,000, (ii) the contractor performing such Replacement requires periodic payments pursuant to terms of a written contract, and (iii) Lender has approved in writing in advance such periodic payments, a request for reimbursement from the Replacement Reserve Account may be made after completion of a portion of the work under such contract, provided (A) such contract requires payment upon completion of such portion of the work, (B) the materials for which the request is made are on site at the Property and are properly secured or have been installed in the Property, (C) all other conditions in this Agreement for disbursement have been satisfied, (D) funds remaining in the Replacement Reserve Account are, in Lender's judgment, sufficient to complete such Replacement and other Replacements when required, and (E) if required by Lender, each contractor or subcontractor receiving payments under such contract shall provide a waiver of lien with respect to amounts which have been paid to that contractor or subcontractor.
(f) Borrower shall not make a request for disbursement from the Replacement Reserve Account more frequently than once in any calendar month and (except in connection with the final disbursement) the total cost of all Replacements in any request shall not be less than $5,000.00.
Additional Advances and Disbursements; Costs of Enforcement If any Event of Default exists, Mortgagee and each of the Lenders shall have the right, but not the obligation, to cure such Event of Default in the name and on behalf of Mortgagor in accordance with the Credit Agreement. All sums advanced and expenses incurred at any time by Mortgagee or any Lender under this Section, or otherwise under this Mortgage or any of the other Credit Documents or applicable law, shall bear interest from the date that such sum is advanced or expense incurred if not repaid within five (5) days after demand therefor, to and including the date of reimbursement, computed at the rate or rates at which interest is then computed on the Indebtedness, and all such sums, together with interest thereon, shall be secured by this Mortgage. Mortgagor shall pay all expenses (including reasonable attorneys’ fees and expenses) of or incidental to the perfection and enforcement of this Mortgage and the other Credit Documents, or the enforcement, compromise or settlement of the Indebtedness or any claim under this Mortgage and the other Credit Documents, and for the curing thereof, or for defending or asserting the rights and claims of Mortgagee or the Lenders in respect thereof, by litigation or otherwise.
Documents, Records and Funds in Possession of the Servicer to be Held for the Trustee The Servicer shall transmit to the Trustee or, at the direction of the Trustee, the Custodian as required by this Agreement all documents and instruments in respect of a Mortgage Loan coming into the possession of the Servicer from time to time and shall account fully to the Trustee for any funds received by the Servicer or which otherwise are collected by the Servicer as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. The documents constituting the Servicing File shall be held by the Servicer as custodian and bailee for the Trustee. All Mortgage Files and funds collected or held by, or under the control of, the Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including but not limited to, any funds on deposit in the Servicer Custodial Account, shall be held by the Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Servicer also agrees that it shall not knowingly create, incur or subject any Mortgage File or any funds that are deposited in the Servicer Custodial Account, Certificate Account or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment or other encumbrance created by the Servicer, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Servicer under this Agreement.
Construction Phase Fee Contractor’s Construction Phase Fee is the maximum amount payable to Contractor for any cost or profit expectation incurred in the performance of the Work that is not specifically identified as being eligible for reimbursement by Owner elsewhere in this Agreement. References in the UGSC to Contractor’s “overhead” and “profit” mean Contractor’s Construction Phase Fee. The Construction Phase Fee includes, but is not limited to, the following items:
9.1 All profit, profit expectations and costs associated with profit sharing plans such as personnel bonuses, incentives, and rewards; company stock options; or any other like expenses of Contractor.
Documents Records and Funds in Possession of Master Servicer to be Held for the Trustee Notwithstanding any other provisions of this Agreement, the Master Servicer shall transmit to the Trustee as required by this Agreement all documents and instruments in respect of a Mortgage Loan coming into the possession of the Master Servicer from time to time and shall account fully to the Trustee for any funds received by the Master Servicer or which otherwise are collected by the Master Servicer as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. All Mortgage Files and funds collected or held by, or under the control of, the Master Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including but not limited to, any funds on deposit in the Certificate Account, shall be held by the Master Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Master Servicer also agrees that it shall not create, incur or subject any Mortgage File or any funds that are deposited in the Certificate Account, Distribution Account or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment or other encumbrance, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Master Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Master Servicer under this Agreement.
