Disputed payment amount Sample Clauses

Disputed payment amount. If COUNTY pays a lesser amount than the amount requested, and if CONTRACTOR submits a written notice of protest to COUNTY within twenty (20) days after CONTRACTOR's receipt of the certification, then the parties shall promptly meet to review the dispute and resolve it on a mutually acceptable basis. No court action may be taken on such dispute until the parties have met and attempted to resolve the dispute in person.
AutoNDA by SimpleDocs
Disputed payment amount. If COUNTY certifies for payment a lesser amount than the amount requested, COUNTY shall immediately notify CONTRACTOR in writing of such certification and shall specify the reason for the modification. If CONTRACTOR desires to contest the certification, CONTRACTOR must submit a written notice of protest to COUNTY within twenty (20) days after CONTRACTOR's receipt of the COUNTY's notice. The parties shall thereafter promptly meet to review the dispute and resolve it on a mutually acceptable basis. No court action may be taken on such dispute until the parties have met and attempted to resolve the dispute in person.

Related to Disputed payment amount

  • Payment Amount Payment for the Services shall be as follows: (choose one) ☐ - $______________________ for the Services (“Payment”). ☐ - At an hourly rate of $____ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!