Annual Certification The Contractor is required to submit an annual certification demonstrating compliance with the Warranty of Security to the Department by December 31 of each Contract year.
Additional Certifications Any certificate signed by any director or officer of the Corporation and delivered to an Agent or to counsel for such Agent in connection with an offering of Notes or the sale of Notes to an Agent as principal shall be deemed a representation and warranty by the Corporation to such Agent as to the matters covered thereby on the date of such certificate and at each Representation Date subsequent thereto.
Institutional Certification Certification by the Submitting Institution that delineates, among other items, the appropriate research uses of the data and the uses that are specifically excluded by the relevant informed consent documents. Further information may be found here.
Federal Certifications Grantee further certifies that, to the extent federal certifications are incorporated into the Grant Agreement, the Grantee has reviewed the federal certifications and that Grantee is in compliance with all requirements. In addition, Grantee certifies that it is in compliance with all applicable federal laws, rules, and regulations, as they may pertain to this Grant Agreement.
Annual Certificate The Custodian shall have received the initial or annual certificate, as the case may be, required by Article 13 hereof; 6)
OFAC Certification Company certifies that (i) it is not acting on behalf of any person, group, entity, or nation named by any Executive Order or the United States Treasury Department, through its Office of Foreign Assets Control (“OFAC”) or otherwise, as a terrorist, “Specially Designated Nation”, “Blocked Person”, or other banned or blocked person, entity, nation, or transaction pursuant to any law, order, rule or regulation that is enforced or administered by OFAC or another department of the United States government, and (ii) Company is not engaged in this transaction on behalf of, or instigating or facilitating this transaction on behalf of, any such person, group, entity or nation.
Professional Certification The Superintendent shall at all times during the term of this Contract, and any renewal or extension thereof, hold and maintain a valid certificate required of a superintendent by the State of Texas and issued by the State Board for Educator Certification or the Texas Education Agency and any other certificates required by law.
Medical Certification (1) The University may require an employee to provide medical certification from a health care provider for FMLA leave without pay when taken for the serious health condition of the employee or the employee's family member.
(2) Medical certification may be required to affirm the employee's ability to return to work and perform one or more of the essential functions of the job within the meaning of the Americans with Disabilities Act (ADA), after being absent on FMLA leave.
New Certifications If a participating Employer is newly certified by ONA at one of its owned nursing homes for its registered nurses, the existing standard non-monetary provisions in the central ONA/RN agreements will automatically apply to the nurses effective nine (9) months after the Employer receives notice to bargain from the Union or a Memorandum of Agreement or Interest Arbitration Award is received, whichever is earlier. These provisions include: Article 1 Article 2.03 Articles 2.05, 2.07-2.12 Articles 3-8 Articles 9.01(d) only, 9.03-9.13, 9.15, 9.16, 9.17 Article 10
Provisional Certificate 12.2.1 Subject to the provisions of Clause 12.2.5, upon completion of all Works forming part of the Project Highway, save and except the Works for which Time Extension has been granted under Clause 10.5, the Authority’s Engineer shall, at the request of the Contractor, issue a provisional certificate of completion substantially in the form set forth in Schedule-L (the “Provisional Certificate”) if the Tests for and in respect of the completed Works are successful. The Provisional Certificate shall have appended thereto a list of outstanding items of work (the “Punch List”) that need to be completed in accordance with the provisions of this Agreement. The Contractor undertakes to complete the minor outstanding items of works in respect of those Sections of the Project Highway for which the Provisional Certificate has been issued, within a period of 30 (thirty) days of the date of Provisional Certificate, and those parts of the Works in respect of which Time Extension has been granted, within the extended period thereof. For the avoidance of doubt, the Parties agree that the Punch List shall include all Works for which Time Extension has been granted and shall also include any minor outstanding items of work forming part of the completed Sections if such works do not materially affect the use of the completed Sections for their intended purpose. The Parties further agree that Provisional Certificate shall not be issued if the completed Works cannot be safely and reliably placed in service of the Users thereof.
12.2.2 Upon issue of Provisional Certificate, the provisions of Articles 14 and 17 shall apply to the completed parts of the Project Highway and the property and ownership of all such completed Works shall vest in the Authority.
12.2.3 If the Authority’s Engineer determines that the Project Highway or any completed part thereof does not conform to the provisions of this Agreement and cannot be safely and reliably placed in operation, it shall forthwith make a report in this behalf and send copies thereof to the Authority and the Contractor and withhold issuance of the Provisional Certificate until the Defects or deficiencies are rectified by the Contractor and Tests are successful in accordance with this Article 12.
12.2.4 Notwithstanding anything to the contrary contained in Clause 12.2.3, the Authority may, at any time after receiving a report from the Authority’s Engineer under that Xxxxxx, direct the Authority’s Engineer to issue a Provisional Certificate under Clause 12.2.1 and such direction shall be complied forthwith.
12.2.5 No Provisional Certificate shall be issued under the provisions of this Clause 12.2 until the Contractor has submitted valid claims for payment of at least 80% (eighty per cent) of the amount arrived at after reducing the lump sum price specified in Clause 19.1.1 by the amount attributable to works which have been withdrawn under the provisions of Clause 8.3.3. For the avoidance of doubt and by way of illustration, the Parties agree that if the Contract Price specified in Clause 19.1.1 is Rs. 105 cr. (Rs. one hundred and five crore) and the works withdrawn under Clause 8.3.3 have a value of Rs. 5 cr. (Rs. five crore), a Provisional Certificate shall not be issued until valid claims for payment of an amount of Rs. 80 cr. (Rs. eighty crore) have been submitted by the Contractor in accordance with the provisions of this Agreement. It is further agreed that all price adjustments made in pursuance of Clause 19.10 shall not be reckoned for computation of the claims for payments referred to in this Clause 12.2.5.
