Compliance with Federal and State Work Authorization and Immigration Laws The Contractor and all subcontractors, suppliers and consultants must comply with all federal and state work authorization and immigration laws, and must certify compliance using the form set forth in Section 7 (“Georgia Security and Immigration Compliance Act Affidavits”). The required certificates must be filed with the Owner and copied maintained by the Contractor as of the beginning date of this contract and each subcontract, supplier contract, or consultant contract, and upon final payment to the subcontractor or consultant. State officials, including officials of the Georgia Department of Audits and Accounts, officials of the Owner, retain the right to inspect and audit the Project Site and employment records of the Contractor, subcontractors and consultants without notice during normal working hours until Final Completion, and as otherwise specified by law and by Rules and Regulations of the Georgia Department of Audits and Accounts.
Limitation on Out-of-State Litigation - Texas Business and Commerce Code § 272 This is a requirement of the TIPS Contract and is non-negotiable. Texas Business and Commerce Code § 272 prohibits a construction contract, or an agreement collateral to or affecting the construction contract, from containing a provision making the contract or agreement, or any conflict arising under the contract or agreement, subject to another state’s law, litigation in the courts of another state, or arbitration in another state. If included in Texas construction contracts, such provisions are voidable by a party obligated by the contract or agreement to perform the work. By submission of this proposal, Vendor acknowledges this law and if Vendor enters into a construction contract with a Texas TIPS Member under this procurement, Vendor certifies compliance.
Compliance with Federal and State Laws All work performed by the Contractor, pursuant to this contract, shall be done in accordance with applicable all Federal, State, and local laws, regulations, codes, and ordinances.
ACCORDANCE WITH FEDERAL AND STATE LAW All services provided by the Agent shall comply with federal, State, or local law requiring the delivery of agreements, reports, notices, and/or the posting of signage or notices.
Compliance with Federal Law The Credit Parties shall: (i) ensure that no Person who owns a controlling interest in or otherwise controls the Credit Parties is or shall be listed on the Specially Designated Nationals and Blocked Person List or other similar lists maintained by the Office of Foreign Assets Control (“OFAC”), the Department of the Treasury, included in any Executive Orders or any other similar lists from any Governmental Authority; (ii) not use or permit the use of the proceeds of the Loans to violate any of the foreign asset control regulations of OFAC or any enabling statute or Executive Order relating thereto, or any other similar national or foreign governmental regulations; and (iii) comply with all applicable Lender Secrecy Act (“BSA”) laws and regulations, as amended. As required by federal law and Lender’s policies and practices, Lender may need to obtain, verify and record certain customer identification information and documentation in connection with opening or maintaining accounts or establishing or continuing to provide services.
Concerning Applicable Provisions of Law, etc This Agreement shall be subject to all applicable provisions of law, including the applicable provisions of the 1940 Act and to the extent that any provisions herein contained conflict with any such applicable provisions of law, the latter shall control.
Compliance with Federal Law, Regulations, and Executive Orders This is an acknowledgement that FEMA financial assistance will be used to fund all or a portion of the contract. The contractor will comply with all applicable Federal law, regulations, executive orders, FEMA policies, procedures, and directives.
Regulatory Requirements and Governing Law 43 14.1 Regulatory Requirements. 43 14.2 Governing Law 44 ARTICLE 15. NOTICES 44 15.1 General. 44 15.2 Xxxxxxxx and Payments. 44 15.3 Alternative Forms of Notice 44 15.4 Operations and Maintenance Notice 44 ARTICLE 16. FORCE MAJEURE 45 16.1 Force Majeure 45 ARTICLE 17. DEFAULT 45 17.1 Default. 45 ARTICLE 18. INDEMNITY, CONSEQUENTIAL DAMAGES AND INSURANCE 46 18.1 Indemnity. 46 18.2 No Consequential Damages. 47 18.3 Insurance 47 ARTICLE 19. ASSIGNMENT 49 19.1 Assignment. 49 ARTICLE 20. SEVERABILITY 49 20.1 Severability. 49 ARTICLE 21. COMPARABILITY 50 21.1 Comparability. 50 ARTICLE 22. CONFIDENTIALITY 50 22.1 Confidentiality. 50 ARTICLE 23. ENVIRONMENTAL RELEASES 53 23.1 Developer and Connecting Transmission Owner Notice 53 ARTICLE 24. INFORMATION REQUIREMENT 53 24.1 Information Acquisition. 53 24.2 Information Submission by Connecting Transmission Owner 54 24.3 Updated Information Submission by Developer 54 24.4 Information Supplementation 54 ARTICLE 25. INFORMATION ACCESS AND AUDIT RIGHTS 55 25.1 Information Access. 55 25.2 Reporting of Non-Force Majeure Events. 55 25.3 Audit Rights. 56 25.4 Audit Rights Periods. 56 25.5 Audit Results. 56 ARTICLE 26. SUBCONTRACTORS 56 26.1 General. 56 26.2 Responsibility of Principal. 57 26.3 No Limitation by Insurance 57 ARTICLE 27. DISPUTES 57 27.1 Submission 57 27.2 External Arbitration Procedures. 57 27.3 Arbitration Decisions. 58 27.4 Costs. 58 27.5 Termination 58 ARTICLE 28. REPRESENTATIONS, WARRANTIES AND COVENANTS 58 28.1 General. 58 ARTICLE 29. MISCELLANEOUS 59 29.1 Binding Effect. 59 29.2 Conflicts. 59 29.3 Rules of Interpretation 59 29.4 Compliance 60 29.5 Joint and Several Obligations. 60 29.6 Entire Agreement. 60 29.7 No Third Party Beneficiaries. 60 29.8 Waiver 60 29.9 Headings. 61 29.10 Multiple Counterparts. 61 29.11 Amendment. 61 29.12 Modification by the Parties. 61 29.13 Reservation of Rights. 61 29.14 No Partnership 62 29.15 Other Transmission Rights. 62 Appendices STANDARD LARGE GENERATOR INTERCONNECTION AGREEMENT THIS STANDARD LARGE GENERATOR INTERCONNECTION AGREEMENT
Provisions of General Application (a) All accounting terms not specifically defined herein shall be construed in accordance with GAAP. (b) The terms defined in this Article include the plural as well as the singular. (c) The words "herein," "hereof" and "hereunder" and other words of similar import refer to this Agreement as a whole. All references to Articles and Sections shall be deemed to refer to Articles and Sections of this Agreement.
Consents and Requisite Governmental Approvals; No Violations (a) No consent, approval or authorization of, or designation, declaration or filing with, any Governmental Entity is required on the part of a Parent Party with respect to such Parent Party’s execution, delivery or performance of its obligations under this Agreement or the Ancillary Documents to which it is or will be party or the consummation of the transactions contemplated by this Agreement or by the Ancillary Documents, except for (i) the filing with the SEC of (A) the Registration Statement / Proxy Statement and the declaration of the effectiveness thereof by the SEC and (B) such reports under Section 13(a), 15(d) or 16 of the Exchange Act as may be required in connection with this Agreement, the Ancillary Documents or the transactions contemplated hereby or thereby, (ii) such filings with and approvals of Nasdaq to permit the Parent Common Stock to be issued in connection with the transactions contemplated by this Agreement and the other Ancillary Documents to be listed on Nasdaq, (iii) filing of the Certificates of Merger, (iv) the approvals and consents to be obtained by each Merger Sub pursuant to Section 5.9, or (v) the Parent Stockholder Approval. (b) Subject to the receipt of the Consents, approvals, authorizations and other requirements set forth in Section 4.3(a), neither the execution, delivery or performance by a Parent Party of this Agreement nor the Ancillary Documents to which a Parent Party is or will be a party nor the consummation by a Parent Party of the transactions contemplated hereby or thereby will, directly or indirectly (with or without due notice or lapse of time or both) (i) result in any breach of any provision of the Governing Documents of a Parent Party, (ii) result in a violation or breach of, or constitute a default or give rise to any right of termination, cancellation, amendment, modification, suspension, revocation or acceleration under, any of the terms, conditions or provisions of any Contract to which a Parent Party is a party, (iii) violate, or constitute a breach under, any Order or applicable Law to which any such Parent Party or any of its properties or assets are bound or (iv) result in the creation of any Lien upon any of the assets or properties (other than any Permitted Liens) of a Parent Party, except, in the case of any of clauses (ii) through (iv) above, as would not, individually or in the aggregate, reasonably be expected to be material or prevent, materially delay or materially impair the ability of a Parent Party to consummate the Transactions.
