Development of the Project The Board of Managers shall take such actions as shall be required to cause either the Company or the Management Company (as defined in Section 9(b) below) to perform and complete the construction and other development work as contemplated and/or required under the NVR Purchase and Sale Agreements, or any other construction company selected by the Board of Managers (the “Development Work”), substantially in accordance with the Project Plan, at a cost to the Company not exceeding the total cost set forth in the Budget, in a manner consistent with this Agreement and all applicable laws, ordinances, rules, regulations or requirements (including, without limitation, those with respect to discrimination) of governmental authorities, and in compliance with any covenants, conditions or restrictions affecting all or any portion of the Property.
Completion of Project The Project shall have been completed per the Plans and Specifications and a Completion Certificate shall have been obtained;
Completion of Improvements Landlord, through its general contractor (“Contractor”), shall furnish and install within the Premises those items of general design, engineering and construction, shown on the final plans and specifications approved by Landlord and Tenant pursuant to the Schedule of Approvals below, in compliance with all applicable laws, ordinances, codes, rules and regulations and matters of record, and complete any construction required in the Common Areas of the Building when such construction is required by or arises out of completion of such work (collectively the “Improvements”). The contractor constructing the Improvements in the Premises shall be selected pursuant to a procedure whereby the final Plans and Specifications (as such term is defined in this Exhibit B) are submitted to Xxxxxxx Xxxxxx Builders, Inc. (“XXX”) and Pinnacle Contracting Corporation (collectively, the “Approved Contractors”), who shall be requested to each submit to Landlord and to Tenant a sealed contract bid using such forms reasonably acceptable to Landlord in order to provide an “apples to apples” bidding process. The sealed bids shall be delivered to Tenant and Landlord and opened jointly by Landlord and Xxxxxx. Tenant, in Tenant’s sole and absolute discretion, shall select the Contractor from the two Approved Contractors (regardless of which has the lower bid). Each bid from the contractors shall specify any allowances for exclusions and shall further provide that said bids are without overtime premiums or bonuses necessary to complete the Improvements in accordance with the terms hereof. The architect engaged by Xxxxxx to prepare the Space Plan and Plans and Specifications and related design work for the Improvements shall be Xxxxxxx (the “Architect”). Landlord shall disburse amounts of the Allowance (up to the maximum specified below) to Architect within thirty (30) days after receipt of paid invoices from Architect or Tenant for Architect’s services; provided, however, notwithstanding the foregoing, Landlord shall pay $[***] for the Architect’s preparation of the Space Plan (as evidenced by the Architect’s invoice number 68045 dated October 15, 2010), at Landlord’s sole cost and expense (and without using the Allowance or any portion thereof). The definition of Improvements shall include all costs associated with completing the Improvements, including but not limited to, fees payable to Xxxxxxx, space planning, design, architectural, and engineering fees, contracting, labor and material costs, municipal fees, plan check and permit costs, and document development and/or reproduction, and all costs and expenses for any construction manager(s) engaged by Xxxxxx (provided such soft costs for architectural and engineering services charged against the Allowance shall not exceed $[***] per square feet of Usable Area in the Premises) at Tenant’s sole option. The Space Plan and the Plans and Specifications (each as defined in Section 3 of this Exhibit B) shall be subject to Landlord’s prior review and approval, which approval shall not be unreasonably withheld, conditioned or delayed. Landlord’s approval of any iteration of a Space Plan or Plans and Specifications shall be deemed granted unless Landlord provides a reasonable disapproval or approval to Tenant prior to the sixth (6th) business day after Landlord’s receipt of the Space Plan or Plans and Specifications. Without limiting Landlord’s discretion to reasonably withhold its approval, Tenant agrees that it shall be reasonable for Landlord to withhold its approval of any aspect of Tenant’s Space Plan or Plans and Specifications (or, in either case, any proposed changes thereto) which (i) adversely affect Building systems, the structure of the Building or the safety of the Building and/or its occupants, (ii) would violate any governmental laws, rules or ordinances; (iii) would require any changes that adversely impact the base, shell and core of the Building, and/or (iv) are inconsistent with the standards of first class office buildings in the vicinity of the Building, as reasonably determined by Landlord and the Contractor. Landlord shall provide a written statement of any disapproval of any Space Plan or Plans and Specifications stating the reasons for Xxxxxxxx’s disapproval. Tenant acknowledges and agrees that any change in the scope of work or details of construction after Xxxxxx’s and Landlord’s approval of the Plans and Specifications shall constitute a “Change Order”, the costs of which may be charged against any available amounts of the Allowance under this Exhibit B. To the extent the Change Order delays construction of the Improvements, the same shall be a Tenant Delay. [***] = CONFIDENTIAL INFORMATION HAS BEEN OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION. CONFIDENTIAL TREATMENT HAS BEEN REQUESTED WITH RESPECT TO THIS OMITTED INFORMATION.
Project Completion Within five (5) days after the delivery by Supplier to Purchaser of a Commissioning Certificate for the Project’s final Turbine, Supplier shall also deliver to Purchaser a completion certificate for all Turbines in the Project (the “Project Completion Certificate”), in the form attached hereto as Exhibit N, together with a list of any remaining Punch List Work on any Turbine, a schedule for completing the Punch List Work and an estimate of the cost of each item of Punch List Work. Supplier shall thereafter promptly complete all Punch List Work.
Project Description The Project Description may be changed from time to time by, or with the consent of, the Company provided that any such change shall also be filed with the Issuer and provided further that no change in the Project Description shall materially change the function of the Project Facilities unless the Trustee shall have received (i) an Engineer's certificate that such changes will not impair the significance or character of the Project Facilities as Pollution Control Facilities and (ii) an Opinion of Bond Counsel or ruling of the Internal Revenue Service to the effect that such amendment will not adversely affect the exclusion of interest on the Bonds from gross income for federal income tax purposes.
Feasibility Study Buyer is granted the right to conduct engineering and/or market and economic feasibility studies of the Property and a physical inspection of the Property, including studies or inspections to determine the existence of any environmental hazards or conditions (collectively, the “Feasibility Study”) during the period (the “Feasibility Period”) commencing on the Effective Date and ending at 5:00 p.m., Central Time, on the June 3, 2010. With Seller’s permission, after Seller has received advance notice sufficient to permit it to schedule in an orderly manner Buyer’s examination of the Property and to provide at least 24-hours’ advance written notice to any affected tenants, Buyer or its designated agents may enter upon the Property during normal business hours for purposes of analysis or other tests and inspections which may be deemed necessary by Buyer for the Feasibility Study. Buyer or its designated representative must be accompanied by a designated representative of Seller or have received Seller’s written permission prior to entering upon the Property in connection with Buyer’s Feasibility Study; provided, however, Buyer may not enter into any space leased by any tenant without being accompanied by a designated representative of Seller. Seller agrees to make its representative reasonably available during normal business hours. Buyer will not alter the physical condition of the Property or conduct invasive testing without notifying Seller of its requested tests, and obtaining the written consent of Seller to any physical alteration of the Property or invasive testing. Buyer will utilize commercially reasonable diligence to conduct or cause to be conducted all inspections and tests in a manner and at times which will not unreasonably interfere with any tenant’s use and occupancy of the Property. If Buyer determines, in its sole judgment, that the Property is not suitable for any reason for Buyer’s intended use or purpose, or is not in satisfactory condition, then Buyer may terminate this Contract by written notice to Seller prior to expiration of the Feasibility Period, in which case the Xxxxxxx Money (other than the Option Money) will be returned to Buyer, and neither party shall have any further right or obligation hereunder other than as set forth herein with respect to rights or obligations which survive termination. If this Contract is not terminated pursuant to this Section 5(a), then after expiration of the Feasibility Period, after Seller has received advance notice sufficient to permit it to schedule in an orderly manner Buyer’s examination of the Property and to provide at least 24-hours’ advance written notice to any affected tenants, Buyer or its designated agents may enter upon the Property during normal business hours. Buyer or its designated representative must be accompanied by a designated representative of Seller or have received Seller’s written permission prior to entering upon the Property; provided, however, Buyer may not enter into any space leased by any tenant without being accompanied by a designated representative of Seller. If this Contract is not timely terminated pursuant to this Section 5(a), Buyer’s right to terminate this Contract pursuant to this Section 5(a) and any and all objections with respect to the Feasibility Study will be deemed to have been waived by Buyer for all purposes.
Completion of the Project (a) The completion of the Project shall be evidenced to the Trustee by a certificate signed by the Project Supervisor on behalf of the User stating that (1) construction of the Improvements has been completed in accordance with the plans and specifications approved by the User, (2) the Equipment has been acquired and installed in accordance with the User's instructions, (3) all Project Costs have been paid, and (4) all facilities and improvements necessary in connection with the Project have been acquired and installed and all costs and expenses incurred in connection therewith have been paid. Notwithstanding the foregoing, such certificate shall state that it is given without prejudice to any rights against any vendor, contractor, subcontractor or other person not a party to this Lease Agreement which exist at the date of such certificate or which may subsequently come into being. The Issuer and the User will cooperate in causing such certificate to be furnished to the Trustee.
Phase II The parties acknowledge that this Agreement is not exclusive and GPPC shall have the right to provide consulting services regarding the marketing of the DCC services of Member, GPPC, any of GPPC’s Affiliates, or of any third party, subject to the provisions of Section 5.4 above. During the Term of this Agreement, GPPC may choose to develop the functionality of its own processing platform, or use a third person’s processing platform to enable GPPC to support certain functions in the clearing and settlement of DCC Transactions (“Phase II”). At such time as it is ready to begin implementing Phase II, GPPC shall inform Planet Payment of its plans and the parties shall discuss how Phase II may be integrated into the Acquirer Program. Nothing herein shall prohibit GPPC from implementing Phase II, and Planet Payment agrees that it will use its commercially reasonable efforts to provide assistance to GPPC to implement Phase II, provided that Planet Payment shall not have any obligation whatsoever to assist GPPC in any way in specifying, designing or implementing functions similar to any of Planet Payment’s functions provided hereunder relating to the conversion, calculation, reporting or reconciliation of cross-currency Transactions. Nothing herein shall oblige Planet Payment to disclose, transfer or license any of its IP to GPPC for the purposes of Phase II. Planet Payment shall not charge GPPC for such assistance, unless GPPC requests modifications or enhancements to the Planet Payment Platform to facilitate Phase II, in which case Planet Payment shall only charge GPPC for its actual and out of pocket costs incurred in connection with such modifications or enhancements. The parties shall use good faith efforts to modify the parties’ respective obligations under this Agreement relating to processing of Transactions (but without any change to their respective Revenue Shares) to reflect the reallocation of their respective functions following implementation of Phase II.
PHASE Phase means any individual Phase of the Project, as more particularly described in the definition of Project.
Project The Land and all improvements thereon, including the Building, the Parking Facilities, and all Common Areas.
