Payment Amount Payment for the Services shall be as follows: (choose one) ☐ - $______________________ for the Services (“Payment”). ☐ - At an hourly rate of $____ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.
Over-Allowance Amount On the Cost Proposal Delivery Date, Landlord shall identify the amount (the "Over-Allowance Amount") equal to the difference between (i) the amount of the Cost Proposal and (ii) the amount of the Improvement Allowance. Subject to the terms of Section 2.3 of this Work Letter Agreement, the Over-Allowance Amount shall be delivered from Tenant to Landlord (on a pro-rata basis, based upon the percentage of the Tenant Improvements completed) within fifteen (15) days of Tenant's receipt of an invoice for such portion of the Over-Allowance Amount. In the event that, after the Cost Proposal Delivery Date, any revisions, changes, or substitutions shall be made to the Construction Drawings or the Improvements as the result of (i) a ratified Tenant Change, or (ii) a change requested by Landlord and reasonably approved by Tenant, then, subject to the terms of Section 2.3 of this Work Letter Agreement, any additional costs which arise in connection with such revisions, changes or substitutions or any other additional costs shall be paid by Tenant to Landlord immediately upon Landlord's request as an addition to the Over-Allowance Amount. Subject to the terms of Section 2.3 of this Work Letter Agreement, in the event that Tenant fails to deliver the Over-Allowance Amount as provided in this Section 4.3.1, then Landlord may, at its option, cease work in the Premises until such time as Landlord receives payment of the Over-Allowance Amount (and such failure to deliver shall be treated as a Tenant delay in accordance with the terms of Section 5.2 below).
