Equipment Requirements No Equipment is provided to Customer as part of this Service.
Payment Requirements If funding levels are significantly affected by state or federal budget and funds are not allocated and available for the continuance of the function performed by Subrecipient, the Contract may be terminated by the County at the end of the period for which funds are available. The County shall notify Subrecipient at the earliest possible time of any service, which will or may be affected by a shortage of funds. No penalty shall accrue to the County in the event this provision is exercised and the County shall not be obligated nor liable for any damages as a result of termination under this provision of this Contract, and nothing herein shall be construed as obligating the County to expend or as involving the County in any Contract or other obligation for future payment of money in excess of appropriations authorized by law.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Trunk Forecasting Requirements 14.2.1 Initial trunk forecast requirements. At least ninety (90) days before initiating interconnection in a LATA, Alltel shall provide Verizon a two (2)-year traffic forecast that complies with the Verizon Interconnection Trunking Forecast Guide, as revised from time to time. This initial traffic forecast will provide the amount of traffic to be delivered to and from Verizon over each of the Interconnection Trunk groups in the LATA over the next eight (8) quarters.
Agreement Requirements This agreement will be issued to cover the Janitorial Service requirements for all State Agencies and shall be accessible to any School District, Political Subdivision, or Volunteer Fire Company.
Management Requirements Procedures for managing equipment (including replacement equipment), whether acquired in whole or in part under a Federal award, until disposition takes place will, as a minimum, meet the following requirements:
Minimum System Requirements The following summarizes the minimum office system requirements for all Contractors and Architect/Engineer to possess in order to participate. It is the responsibility of all Contractors and Architect/Engineer to possess these minimum requirements at no additional cost to Princeton University.
Project Requirements Failure to comply with the following requirements will result in a suspension of all other operations:
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
