Authority; Compliance With Other Agreements and Instruments and Government Regulations The execution, delivery and performance by Borrower and the Subsidiary Guarantors of the Loan Documents to which it is a Party have been duly authorized by all necessary corporate action, and do not and will not:
(a) Require any consent or approval not heretofore obtained of any partner, director, stockholder, security holder or creditor of such Party;
(b) Violate or conflict with any provision of such Party's charter, articles of incorporation or bylaws, as applicable;
(c) Result in or require the creation or imposition of any Lien (other than pursuant to the Loan Documents) or Right of Others upon or with respect to any Property now owned or leased or hereafter acquired by such Party;
(d) Violate any Requirement of Law applicable to such Party;
(e) Result in a breach of or constitute a default under, or cause or permit the acceleration of any obligation owed under, any material indenture or loan or credit agreement or any other Contractual Obligation to which such Party is a party or by which such Party or any of its Property is bound or affected; and such Party is not in violation of, or default under, any Requirement of Law or Contractual Obligation, or any material indenture, loan or credit agreement described in Section 4.2(e), in any respect that constitutes a Material Adverse Effect.
Environmental Audits and Reports as soon as practicable following receipt thereof, copies of all environmental audits and reports, whether prepared by personnel of Lessee or any of its Subsidiaries or by independent consultants, with respect to significant environmental matters at any facility or which relate to an Environmental Claim which could result in a Material Adverse Effect; and
Personnel Requirements and Documentation Grantee will;
1. maintain current personnel documentation on each employee. All documents must be factual and accurate. Health-related information must be stored separately with restricted access as appropriate under Tex. Gov. Code §552.102. Training records may be stored separately from the main personnel file but must be easily accessible upon request. Required documentation includes the following, as applicable:
i. A copy of the current job description signed by the employee;
ii. Application or resume with documentation of required qualifications and verification of required credentials;
iii. Verification of work experience;
iv. Annual performance evaluations;
v. Personnel data that includes date hired, rate of pay, and documentation of all pay increases and bonuses;
vi. Documentation of appropriate screening and/or background checks, to include probation or parole documentation;
vii. Signed documentation of initial and other required training; and
viii. Records of any disciplinary actions.
2. document authentication must include signature, credentials when applicable, and date. If the document relates to past activity, the date of the activity must also be recorded. Documentation must be permanent and legible. When it is necessary to correct a required document, the error must be marked through with a single line, dated, and initialed by the writer.
Compliance with Other Agreements and Applicable Laws Borrower is not in default in any material respect under, or in violation in any material respect of any of the terms of, any agreement, contract, instrument, lease or other commitment to which it is a party or by which it or any of its assets are bound and Borrower is in compliance in all material respects with all applicable provisions of laws, rules, regulations, licenses, permits, approvals and orders of any foreign, Federal, State or local governmental authority.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Inspection of Property; Books and Records; Discussions Keep proper books of records and account in which full, true and correct entries in conformity with GAAP and all Requirements of Law shall be made of all dealings and transactions in relation to its business and activities; and permit representatives of any Lender (upon reasonable advance notice coordinated through the Administrative Agent) to visit and inspect any of its properties and examine and make abstracts from any of its books and records at any reasonable time and as often as may reasonably be desired and to discuss the business, operations, properties and financial and other condition of the Borrower and its Subsidiaries with officers and employees of the Borrower and its Subsidiaries and with its independent certified public accountants.
SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State.
4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor.
4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor.
4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto.
4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project.
4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.
Inspection of Properties and Books The Borrower and the Guarantors will, and will cause their respective Subsidiaries to, permit the Agent and the Lenders, at the Borrower’s expense (to the extent provided for below) and upon reasonable prior notice, to visit and inspect any of the properties of the Borrower, each Guarantor or any of their respective Subsidiaries (subject to the rights of tenants under their Leases), to examine the books of account of the Borrower, any Guarantor and their respective Subsidiaries (and to make copies thereof and extracts therefrom) and to discuss the affairs, finances and accounts of the Borrower, any Guarantor and their respective Subsidiaries with, and to be advised as to the same by, their respective officers, partners or members, all at such reasonable times and intervals as the Agent or any Lender may reasonably request, provided that so long as no Default or Event of Default shall have occurred and be continuing, the Borrower shall not be required to pay for such visits and inspections more often than once in any twelve (12) month period. The Lenders shall use good faith efforts to coordinate such visits and inspections so as to minimize the interference with and disruption to the normal business operations of such Persons.
Preparation of Environmental Reports At the request of the Administrative Agent from time to time if the Administrative Agent reasonably suspects the presence of any Hazardous Materials on any property of the Borrower or its Subsidiaries, provide to the Administrative Agent within sixty (60) days after such request, at the expense of the Borrower, an environmental site assessment report for any Specified Real Estate described in such request, prepared by a nationally recognized environmental consulting firm (or other environmental consulting firm reasonably acceptable to the Administrative Agent), indicating the presence or absence of Hazardous Materials and the estimated cost of any compliance, removal or remedial action in connection with any Hazardous Materials on such properties; without limiting the generality of the foregoing, if the Administrative Agent determines at any time that a material risk exists that any such report will not be provided within the time referred to above, the Administrative Agent may retain an environmental consulting firm to prepare such report at the expense of the Borrower, and such Loan Party hereby grants and agrees to cause any Subsidiary that owns any property described in such request to grant at the time of such request to the Administrative Agent, such firm and any agents or representatives thereof an irrevocable non-exclusive license, subject to the rights of tenants, to enter onto their respective properties to undertake such an assessment.
Inspection; Compliance with Law Lessor, Lessor's agents, employees, contractors and designated representatives, and the holders of any mortgages, deeds of trust or ground leases on the Premises ("Lenders") shall have the right to enter the Premises at any time in the case of an emergency, and otherwise at reasonable times, for the purpose of inspecting the condition of the Premises and for verifying compliance by Lessee with this Lease and all Applicable Requirements (as defined in Paragraph 6.3), and Lessor shall be entitled to employ experts and/or consultants in connection therewith to advise Lessor with respect to Lessee's activities, including but not limited to Lessee's installation, operation, use, monitoring, maintenance, or removal of any Hazardous Substance on or from the Premises. The costs and expenses of any such inspections shall be paid by the party requesting same, unless a Default or Breach of this Lease by Lessee or a violation of Applicable Requirements or a contamination, caused or materially contributed to by Lessee, is found to exist or to be imminent, or unless the inspection is requested or ordered by a governmental authority as the result of any such existing or imminent violation or contamination. In such case, Lessee shall upon request reimburse Lessor or Lessor's Lender, as the case may be, for the costs and expenses of such inspections.
