Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).
Performance Excused The Affected Party, to the extent rendered unable to perform its obligations or part thereof under this Agreement as a consequence of the Force Majeure Event shall be excused from performance of the obligations. Provided that, the excuse from performance shall be of no greater scope and of no longer duration than is reasonably warranted by the Force Majeure Event. Provided further, nothing contained herein shall absolve the Affected Party from any payment obligations accrued prior to the occurrence of the underlying Force Majeure Event.
Termination for Non-Performance Should a party to this Agreement fail to materially perform in accordance with the terms and conditions of this Agreement, this Agreement may be terminated by the performing party if the performing party first provides written notice to the non-performing party which notice shall specify the non-performance, provide both a demand to cure the non-performance and reasonable time to cure the non-performance, and state a date upon which the Agreement shall be terminated if there is a failure to timely cure the non- performance. For purpose of this Section 4.4, “reasonable time” shall be not less than five (5) business days. In the event of a failure to timely cure a non- performance and upon the date of the resulting termination for non-performance, the Contractor shall prepare a final accounting and final invoice of charges for all performed but unpaid Services and authorized reimbursable expenses. Such final accounting and final invoice shall be delivered to the Town within fifteen (15) days of the date of termination; thereafter, no other invoice, xxxx, or other form of statement of charges owing to the Contractor shall be submitted to or accepted by the Town. Provided that notice of non-performance is provided in accordance with this Section 4.4, nothing in this Section 4.4 shall prevent, preclude, or limit any claim or action for default or breach of contract resulting from non-performance by a Party.
Performance Delay Time is of the essence in the Vendor’s performance of this Agreement. If at any time it appears to Vendor that it may not meet any of the performance schedules or the scheduled completion date of the services to be performed for any reason, including labor disputes, Vendor shall immediately by verbal means (to be confirmed in writing) notify Customer of the reasons for and the estimated duration of such delay. If requested by Customer, Vendor shall make every effort to avoid or minimize the delay to the maximum extent possible including the expenditure of premium time. Any additional cost caused by these requirements of Customer shall be borne by Vendor, unless the delay in performance arises out of causes beyond the control and without the fault or negligence of Vendor or its subcontractors within the meaning of the Cancellation- Default clause herein. The foregoing requirements are in addition to any of Customer’s other rights and remedies as may be provided by law or this Agreement.
Excuse from Performance The Parties shall be excused from performing their respective obligations hereunder if they are prevented from so performing by reason of floods, earthquakes, other acts of nature, war, civil insurrection, riots, acts of any government (including judicial action), and other similar catastrophic events which are beyond the control of and not the fault of the Party claiming excuse from performance hereunder. Labor unrest, including but not limited to strike, work stoppage or slowdown, sick-out, picketing, or other concerted job action conducted by Contractor's employees or directed at Contractor is not an excuse from performance and Contractor shall be obligated to continue to provide service notwithstanding the occurrence of any or all of such events. The Party claiming excuse from performance shall, within two (2) Business Days after such Party has notice of such cause, give the other Party notice of the facts constituting such cause and asserting its claim to excuse under this Section. If either Party validly exercises its rights under this Section, the Parties hereby waive any claim against each other for any damages sustained thereby. The partial or complete interruption or discontinuance of Contractor's services caused by one or more of the events described in this Section shall not constitute a default by Contractor under this Agreement. Notwithstanding the foregoing, however, if Contractor is excused from performing its obligations hereunder for any of the causes listed in this Section for a period of thirty (30) calendar days or more, the SCWMA shall nevertheless have the right, in its sole discretion, to terminate this Agreement by giving ten (10) calendar days notice to Contractor unless Contractor has demonstrated, by the thirtieth (30th) calendar day, to the satisfaction of the SCWMA that the Contractor will resume services no later than the sixtieth (60th) day following the date service was interrupted or discontinued by Contractor.
CONTRACTOR PERFORMANCE AUDIT The Contractor shall allow the Authorized User to assess Contractor’s performance by providing any materials requested in the Authorized User Agreement (e.g., page load times, response times, uptime, and fail over time). The Authorized User may perform this Contractor performance audit with a third party at its discretion, at the Authorized User’s expense. The Contractor shall perform an independent audit of its Data Centers, at least annually, at Contractor expense. The Contractor will provide a data owner facing audit report upon request by the Authorized User. The Contractor shall identify any confidential, trade secret, or proprietary information in accordance with Appendix B, Section 9(a), Confidential/Trade Secret Materials.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Attainment on Performance Indicators The District will be responsible for overseeing the academic programs offered in its schools and ensuring that those programs meet or exceed state and local expectations for levels of attainment on the statewide performance indicators, as specified in 1 CCR 301-1.
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Non-Performance The obligation of ECOLOGY to the RECIPIENT is contingent upon satisfactory performance by the RECIPIENT of all of its obligations under this Agreement. In the event the RECIPIENT unjustifiably fails, in the opinion of ECOLOGY, to perform any obligation required of it by this Agreement, ECOLOGY may refuse to pay any further funds, terminate in whole or in part this Agreement, and exercise any other rights under this Agreement. Despite the above, the RECIPIENT shall not be relieved of any liability to ECOLOGY for damages sustained by ECOLOGY and the State of Washington because of any breach of this Agreement by the RECIPIENT. ECOLOGY may withhold payments for the purpose of setoff until such time as the exact amount of damages due ECOLOGY from the RECIPIENT is determined.
