Expansion of Premises Provided that the demising wall is erected in the location specified on Exhibit A attached hereto, for purposes of calculating Fixed Monthly Rent and Tenant’s Share the parties hereby stipulate that the Expansion Premises contains approximately 9,271 square feet of Rentable Area and approximately 7,836 square feet of Usable Area. As of the Expansion Date, the definition of the Premises shall be revised to include both the Existing Premises and the Expansion Space, and wherever in the Lease the word “Premises” is found, it shall thereafter refer to both the Existing Premises and the Expansion Space together, as if the same had been originally included in said Lease, subject to the terms and conditions of this First Amendment. Landlord and Tenant agree that a recalculation of the Usable Area of the Expansion Space shall be made after the Expansion Date by Xxxxxxxxx Systems, Inc., an independent planning firm, using the 2010 ANSI/BOMA Standard set forth collectively by the American National Standards Institute and the Building Owners and Managers Association (“ANSI/BOMA Standard”), as a guideline, and that Landlord is utilizing a deemed add-on factor of 18.31% to compute the Rentable Area of the Expansion Space. Tenant and Landlord agree to document the revised Usable Area as documented by Xxxxxxxxx Systems, and the other matters specified below that will be determined upon such Usable Area being confirmed, in the Memorandum (as defined in Section 4 below). Landlord and Tenant further agree that the Rentable Area of the Expansion Space shall be calculated on the basis of 1.1831 times the estimated Usable Area, regardless of what actual common areas of the Building may be, or whether they may be more or less than 18.31% of the total estimated Usable Area of the Building, and is provided solely to give a general basis for comparison and pricing of this space in relation to other spaces in the market area. Landlord and Tenant further agree that once the Rentable Area and Usable Area of the Expansion Space have been determined as specified hereinabove, even if later either party alleges that the actual Rentable Area or Usable Area of the Expansion Space is more or less than the figures stated herein; and whether or not such figures are inaccurate, for all purposes of the Lease, the Rentable and Usable figures agreed upon shall be conclusively deemed to be the Rentable Area, or Usable Area of the Expansion Space, as the case may be. Notwithstanding any adjustment in the Usable Area and/or Rentable Area as determined pursuant to this Section 4, and provided the demising wall is erected in the location indicated on Exhibit A attached hereto and the Expansion Space plan as depicted on Exhibit A is not modified after this First Amendment is executed, there shall be no change in the Fixed Monthly Rent due for the Expansion Space as set forth in Section 5.2, below or in Tenant’s Share as set forth in Section 6, below. As of the Expansion Date, the total Usable Area of the Premises shall be 27,983 square feet and the total Rentable Area of the Premises shall be 31,338 square feet, subject to confirmation of the Usable Area and Rentable Area as provided above. [***] = CONFIDENTIAL INFORMATION HAS BEEN OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION. CONFIDENTIAL TREATMENT HAS BEEN REQUESTED WITH RESPECT TO THIS OMITTED INFORMATION. If the demising wall is erected in a location different from that as indicated on Exhibit A attached hereto, or if the Expansion Space plan as depicted on Exhibit A is otherwise modified after this First Amendment is executed, and if as a result the Rentable Area of the Expansion Space is increased or decreased pursuant to this Section 4 then (a) the Fixed Monthly Rent commencing on the first calendar day of the thirteenth (13th) calendar month after the Expansion Date shall be recalculated based on $2.13 per square foot of Rentable Area of the Expansion Space, per month; (b) thereafter, the Fixed Monthly Rent shall be adjusted to result in an increase of three percent (3%) per annum, cumulative over the Expansion Term; (c) as of the Expansion Date, Security Deposit for the Expansion Space shall be adjusted to an amount equal to one month’s Fixed Monthly Rent for the Expansion Space due during the last year of the Term; (d) as of the Expansion Date, if the Usable Area of the Expansion Space is increased or decreased pursuant to this Section 4, then “Tenant’s Share” as set forth herein for the Expansion Space shall be increased or decreased equally, by dividing the newly calculated Usable Area of the Expansion Space by the Usable Area of the Building; (e) the Allowance shall equal $32.50 per square foot of Rentable Area within Expansion Space; and (f) all other amounts based on the Usable Area of the Expansion Space or Rentable Area of the Expansion Space shall be adjusted appropriately. Landlord and Tenant shall promptly execute a memorandum (the “Memorandum”) confirming the finalized Delivery Date, Expansion Date, the Fixed Monthly Rent escalation dates as described in Section 5.b. below, and the other matters specified above as soon as they are determined. Tenant shall execute the Memorandum and return it to Landlord within fifteen (15) business days after receipt thereof. Failure of Tenant to timely execute and deliver the Memorandum shall constitute an acknowledgement by Tenant that the statements included in such Memorandum are true and correct.
Construction of Project Purchaser shall (i) perform the Final Assembly Work which is set forth in Exhibit P hereto, (ii) perform all civil works (including roads, grading, maintenance facilities, meteorological towers and other items); (iii) perform all electrical works (including collection lines, Electrical Infrastructure, Transmission Facilities, Interconnection Facilities and other items); (iv) provide and install a remote terminal unit and cabling to the Substation, meteorological towers, and communications lines for the SCADA System to the Substation; and (v) provide any other items required for the operation of the Project; and
Construction of Provisions Although certain provisions of this Agreement contain express language which precludes the Servicer's recovery of, or reimbursement for, expenses incurred hereunder, no inference to the contrary shall be drawn from absence of such, or similar, language in any other provision hereof regarding expenses.
Maintenance of Properties, Etc Maintain and preserve, and cause each of its Subsidiaries to maintain and preserve, all of its properties that are used or useful in the conduct of its business in good working order and condition, ordinary wear and tear excepted.
Maintenance of Properties; Insurance The Borrower will, and will cause each of its Subsidiaries to, (a) keep and maintain all property material to the conduct of its business in good working order and condition, ordinary wear and tear excepted, and (b) maintain, with financially sound and reputable insurance companies, insurance in such amounts and against such risks as are customarily maintained by companies engaged in the same or similar businesses operating in the same or similar locations.
Maintenance of Common Areas Landlord shall maintain the Common Areas in good order, condition and repair and shall operate the Project and Park, in Landlord’s reasonable discretion, as a first-class industrial/commercial real property development. Tenant shall pay, on a monthly basis, Tenant’s Pro-Rata Share (as determined below) of the costs specified below and incurred by Landlord for the operation and maintenance of the Common Areas in the manner stated in Section 4.05(e). Common Area costs include, but are not limited to, costs and expenses for the following: the emergency generator gardening and landscaping; utilities, water, storm water and sanitary sewage charges; maintenance of signs (other than tenants’ signs); premiums for liability, property damage, fire and other types of casualty insurance on the Common Areas and all Common Area improvements; all Real Property Taxes levied on or attributable to the Common Areas and all Common Area improvements; all personal property taxes levied on or attributable to personal property used in connection with the Common Areas; straight-line depreciation on personal property owned by Landlord which is consumed or used in the operation or maintenance of the Common Areas; rental or lease payments paid by Landlord for rented or leased personal property used in the operation or maintenance of the Common Areas; fees for required licenses and permits; repairing, resurfacing and repaying, striping or restriping, maintaining, painting, lighting, cleaning, refuse removal, security and similar items; sales taxes; business and occupations taxes; and a reasonable fee to Landlord for Landlord’s supervision of the Common Areas and Project management (not to exceed three percent (3%) of the Base Rents of the Project for the calendar year). Landlord may cause any or all of such services to be provided by third parties and the cost of such services shall be included in Common Area costs. Common Area costs shall not include depreciation of real property which forms part of the Common Areas. The parties acknowledge and agree that the costs for maintaining the emergency generator shall be divided pro-rata among the four buildings to which it is connected.
CONSTRUCTION OF PREMISES Landlord will diligently perform “Landlord’s Work” and Tenant will diligently perform “Tenant’s Work” (if any) as described in the Workletter attached as Exhibit “F” in accordance with the Workletter and the rest of this Lease. Landlord’s Work will be deemed substantially completed even if Landlord has not completed “punch list” or other minor items, as long as (i) Landlord agrees to use reasonable efforts to complete these items within thirty (30) days of signing the punch-list, excluding any items which require special materials or equipment that are unavailable; and (ii) the punch-list items can be completed after Tenant’s occupancy without causing substantial interference with Tenant’s use of the Premises. Tenant’s final punch list will be submitted to Landlord with in fifteen (15) days after Landlord notifies Tenant that Landlord’s Work is substantially completed. Substantial completion of Landlord’s Work will be deemed to have occurred on the earlier of: the date as of which Landlord’s architect certifies in good faith that Landlord’s Work has been substantially completed in substantial conformance with the plans and specifications therefore (or the date as of which such substantial completion would have occurred but for any delays or Tenant’s Work for which Tenant is responsible); or the date that the applicable governmental authorities issue a temporary or final certificate of occupancy for the Premises (or the date as of which such a certificate of occupancy reasonable could have been issued but for any delays or Tenant’s Work for which Tenant is responsible). If and as long as Tenant does not interfere in any way with the construction process (by causing disharmony, scheduling or coordinating difficulties, etc.) Tenant, may, at Tenant’s sole risk and expense, enter the Premises 30 days prior to the substantial completion of Landlord’s Work (“Early Access Period”) for the purposes of installing Tenant’s decorations, movable furniture and business fixtures. The determination of such interference by Landlord shall be conclusive. The Early Access Period shall commence upon Tenant’s receipt of Landlord’s notice of same. For the time period commencing on the date that Landlord’s Work is substantially complete and ending on the date that is ten days after such substantial completion (the “Fixture Period”), Tenant shall have the right to access the Premises for the purposes of installing its furniture, fixtures, audio/visual, security, and other equipment Any access by Tenant prior to the Lease Commencement Date shall be subject to all the terms and conditions of this Lease, except that Tenant shall not be obligated to pay rent during the Fixture Period.
Maintenance of Properties and Insurance (a) The Issuer shall cause all material properties owned by or leased by it or any of its Restricted Subsidiaries used or useful to the conduct of its business or the business of any of its Restricted Subsidiaries to be maintained and kept in normal condition, repair and working order and supplied with all necessary equipment and shall cause to be made all repairs, renewals, replacements, and betterments thereof, all as in its judgment may be necessary, so that the business carried on in connection therewith may be properly and advantageously conducted at all times; provided, however, that nothing in this Section 4.05 shall prevent the Issuer or any of its Restricted Subsidiaries from discontinuing the use, operation or maintenance of any of such properties, or disposing of any of them, if such discontinuance or disposal is, in the judgment of the management of the Issuer or any such Restricted Subsidiary desirable in the conduct of the business of the Issuer or any such Restricted Subsidiary; provided, further, that nothing in this Section 4.05 shall prevent the Issuer or any of its Restricted Subsidiaries from discontinuing or disposing of any properties to the extent otherwise permitted by this Indenture.
Maintenance of Premises LESSOR will be responsible for all structural and roof maintenance of the leased premises but specifically excluding damage caused by the careless, malicious, willful, or negligent acts of LESSEE or others, chemical, water or corrosion damage from any source, and maintenance of the space heating, ventilating, and cooling units exclusively serving the leased premises (collectively, the "HVAC Unit") and of any non "building standard" leasehold improvements. LESSOR shall not be deemed to have breached its obligation to make the repairs required to be made by LESSOR unless LESSOR fails to make the same within a reasonable period (taking into consideration the type of repair involved) after receiving written notice from LESSEE of the need therefor. LESSEE agrees to maintain at its expense the HVAC Unit and all other aspects of the leased premises in the same condition as they are at the commencement of the term or as they may be put in during the term of this lease, normal wear and tear and damage by fire or other casualty only excepted, and whenever necessary, to replace light bulbs, plate glass and other glass therein, acknowledging that the leased premises are now in good order and the light bulbs and glass whole. If LESSOR so directs, LESSEE shall enter into a preventive maintenance/service contract acceptable to LESSOR with a maintenance contractor acceptable to LESSOR at LESSEE's sole cost and expense for servicing all air conditioning, heating, ventilating, and other equipment or other equipment located within or serving the leased premises. LESSEE will properly control or vent all solvents, degreasers, smoke, odors, etc. and shall not cause the area surrounding the leased premises to be in anything other than a neat and clean condition, depositing all waste in appropriate receptacles. LESSEE shall be solely responsible for any damage to plumbing equipment, sanitary lines, or any other portion of the building which results from the discharge or use of any acid or corrosive substance by LESSEE. LESSEE shall not permit the leased premises to be overloaded, damaged, stripped or defaced, nor suffer any waste, and will not keep animals within the leased premises. LESSEE will protect any carpet with plastic or masonite chair pads under any rolling chairs. Unless heat is provided at LESSOR's expense, LESSEE shall maintain sufficient heat to prevent freezing of pipes or other damage. Any increase in air conditioning equipment or electrical capacity, or any installation and/or maintenance of equipment which is necessitated by some specific aspect of LESSEE's use of the leased premises shall be at LESSEE's expense. All maintenance provided by LESSOR shall be during LESSOR's normal business hours.
Governing Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the laws of the State of New York. The section headings in this Agreement have been inserted as a matter of convenience of reference and are not a part of this Agreement.