Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
REQUIRED FOR PART 2 JOC - PRICING OF Regular Hours Coefficient What is your regular hours coefficient for the RS Means Price Book? (FAILURE TO RESPOND PROHIBITS PART 2 JOC EVALUATION)
Compliance with Xxxxx-Xxxxx and Related Act requirements All rulings and interpretations of the Xxxxx-Xxxxx and Related Acts contained in 29 CFR parts 1, 3, and 5 are herein incorporated by reference in this contract.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Compliance with Xxxxxxxx Act requirements The contractor shall comply with the requirements of 29 CFR part 3, which are incorporated by reference in this contract.
Compliance with Withholding Requirements Notwithstanding any other provision of this Agreement, the Trustee shall comply with all federal withholding requirements respecting payments to Certificateholders of interest or original issue discount that the Trustee reasonably believes are applicable under the Code. The consent of Certificateholders shall not be required for such withholding. In the event the Trustee does withhold any amount from interest or original issue discount payments or advances thereof to any Certificateholder pursuant to federal withholding requirements, the Trustee shall indicate the amount withheld to such Certificateholders.
Certification of Meeting or Exceeding Tobacco-Free Workplace Policy Minimum Standards A. Grantee certifies that it has adopted and enforces a Tobacco-Free Workplace Policy that meets or exceeds all of the following minimum standards of: i. Prohibiting the use of all forms of tobacco products, including but not limited to cigarettes, cigars, pipes, water pipes (hookah), bidis, kreteks, electronic cigarettes, smokeless tobacco, snuff and chewing tobacco; ii. Designating the property to which this Policy applies as a "designated area,” which must at least comprise all buildings and structures where activities funded under this Grant Agreement are taking place, as well as Grantee owned, leased, or controlled sidewalks, parking lots, walkways, and attached parking structures immediately adjacent to this designated area; iii. Applying to all employees and visitors in this designated area; and iv. Providing for or referring its employees to tobacco use cessation services. B. If Grantee cannot meet these minimum standards, it must obtain a waiver from the System Agency.
Reporting Covenant Required Complies Quarterly consolidating financial statements Quarterly within 45 days Yes No Annual financial statement (CPA Audited) FYE within 150 days Yes No 10‑Q, 10‑K and 8-K Within 5 days after filing with SEC Yes No Quarterly Compliance Certificate Contemporaneously with delivery ofthe 10-Q and 10-K Yes No Annual operating budgets and annual financial projections FYE within 45 days Yes No
Coverage Minimum Requirement Commercial General Liability Insurance, including Bodily Injury, Personal Injury, Property Damage, Advertising Injury, and Medical Payments Each Occurrence General Aggregate $ 1,000,000 $ 2,000,000 Automobile Liability Insurance - Any Auto Each Occurrence General Aggregate $ 1,000,000 $ 2,000,000 Professional Liability $ 1,000,000 Workers Compensation Statutory Limits Employer’s Liability $ 1,000,000
Coverage Minimum Limits Commercial General Liability $1,000,000 per occurrence $2,000,000 aggregate Automobile Liability including coverage for owned, non-owned and hired vehicles $1,000,000 per occurrence
