Construction of Project 11.1.1 Developer agrees to cause the Project to be developed, constructed, and installed in accordance with the terms hereof and the Construction Provisions set forth in Exhibit D, including those things reasonably inferred from the Contract Documents as being within the scope of the Project and necessary to produce the stated result even though no mention is made in the Contract Documents.
SCOPE, WAIVER AND ALTERATION OF AGREEMENT (1) No agreement, alteration, understanding, variation, waiver or modification of any of the terms and conditions or covenants herein shall be made by any employee or group of employees with the Board unless executed in writing between the parties hereto and the same has been ratified by the Union and the Board. (2) The waiver of any breach or condition of this Agreement by either party shall not constitute a precedent in the future enforcement of the terms and conditions herein. (3) If any Article or Section of this Agreement or any supplement thereto should be held invalid by operation of law or by any tribunal of competent jurisdiction, or if compliance with or enforcement of any Article or Section should be restrained by such tribunal, the remainder of this Agreement and supplements shall not be affected thereby and the parties shall enter into immediate collective bargaining negotiations for the purpose of arriving at a mutually satisfactory replacement for such Article or Section.
Disbursement of Tenant Improvement Allowance During the construction of the Tenant Improvements, Landlord shall make monthly disbursements of the Tenant Improvement Allowance for Tenant Improvement Allowance Items for the benefit of Tenant and shall authorize the release of monies for the benefit of Tenant as follows.
Extension of Agreement Prior to the original expiration date of this Agreement, the Parties mutually agree to extend this Agreement to the February 15 extension date identified in Paragraph VIII(A). The Parties acknowledge that no further extensions of this Agreement are authorized.
Expansion of Premises (a) Effective as of the Expansion Date the Premises (and the definition of the “Premises”) shall be modified to mean and include both the Initial Premises and the Expansion Premises. As a result of such expansion, effective upon the Expansion Date, the deemed square footage of the Premises shall be and become 31,684 square feet and Tenant’s Prorata Share and Tenant’s Share of Expenses and Real Estate Taxes shall be one hundred percent (100.00%). (b) If Landlord, for any reason whatsoever, cannot deliver possession of the Expansion Premises to Tenant on before August 1, 2012 for the purpose specified in Section 3(c), this Amendment shall not be void or voidable, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and Tenant shall have no obligation to pay monthly Base Rent or Additional Charges with respect to the Expansion Premises until the day following the date on which possession of the Expansion Premises is delivered to Tenant (such date thereupon becoming the “Expansion Date” for purposes of this Amendment). Notwithstanding the foregoing, if Landlord is unable to deliver the Expansion Premises by August 1, 2012 (as extended day-for-day for each day of Force Majeure Delay) (the “Expansion Premises Outside Delivery Date”), then Tenant shall have the right, as its sole remedy, to terminate this Amendment to Lease by providing written notice to Landlord within fifteen (15) business days following the Expansion Premises Outside Delivery Date, in which event the Lease shall continue in full force and effect as if the parties had not entered into this Amendment and Landlord shall promptly return to Tenant the August, 2012 Base Rent for the Expansion Premises paid by Tenant pursuant to the provisions of Section 6(d). For purposes hereof, the failure of the existing tenant of the Expansion Premises to vacate the Expansion Premises shall not be an event of Force Majeure Delay. (c) Notwithstanding the above, Tenant shall be entitled to early occupancy of the Expansion Premises at any time after the Expansion Premises Delivery Date for the sole purposes of (1) installing Tenant’s furniture and telephone and other communications cabling and (2) performing Tenant’s Expansion Work (defined below), provided that (i) Tenant covenants and agrees that Tenant and Tenant’s employees, agents or contractors will cooperate with Landlord to coordinate the performance and completion of the Landlord’s Expansion Work concurrently with Tenant’s Expansion Work, (ii) Landlord shall have no liability to Tenant for delays in completing the Landlord’s Expansion Work which result from, are caused by or arise out of the interference by Tenant or Tenant’s employees, agents or contractors in the performance of the Landlord’s Expansion Work, (iii) Tenant and Tenant’s employees, agents and contractors shall promptly comply with any and all requests made by Landlord or Landlord’s contractor(s) that Tenant remove its property from those areas in or around which Landlord is performing the Landlord’s Expansion Work, and (iv) Landlord shall not be liable for, Tenant hereby waives all claims which Tenant may have against the Landlord Parties, and Tenant shall indemnify and hold harmless Landlord from and defend Landlord against any and all claims or liability for any injury or damage to any person or property in or about the Expansion Premises resulting from or arising out of or in connection with the performance of Tenant’s Expansion Work (except to the extent arising from the negligence or willful misconduct of Landlord). Tenant’s early occupancy of the Expansion Premises for the sole purpose provided in this Section shall be subject to all of the terms and conditions of the Lease, provided that (x) the Premises shall not include the Expansion Premises until the Expansion Date, and (y) Tenant shall not be obligated to pay monthly Base Rent or Additional Charges with respect to the Expansion Premises for the period from the Expansion Premises Delivery Date until the Expansion Date. (d) Within five (5) business days after the Expansion Date, the parties shall execute a letter confirming the Expansion Date and certifying that Tenant has accepted delivery of the Premises, in form substantially similar to EXHIBIT “D” attached to the Lease (the “Expansion Date Memorandum”). Either party’s failure to request execution of, or to execute, the Expansion Date Memorandum shall not in any way alter the Expansion Date.
Completion of Project This Grant Agreement shall terminate upon completion of the project and payment of the last invoice.
Alterations, Additions, and Improvements Subject to the provisions of this Article IV, Lessee may make any alterations, additions, improvements or other changes to the Premises and the Relevant Assets as may be necessary or useful in connection with the operation of the Relevant Assets (collectively, the “Additional Improvements”). If such Additional Improvements require alterations, additions or improvements to the Premises or any of the Shared Access Facilities, Lessee shall notify Lessor in writing in advance and the parties shall negotiate in good faith any increase to the fees paid by Lessee under the Site Services Agreement by Lessee or otherwise provide for reimbursement of any material increase in cost (if any) to Lessor under the Site Services Agreement that results from any modifications to the Premises or the Shared Access Facilities necessary to accommodate the Additional Improvements, or as otherwise mutually agreed by the parties. Any alteration, addition, improvement or other change to the Premises, Relevant Assets or Additional Improvements (and, if agreed by Lessee and Lessor, to the Shared Access Facilities) by Lessee shall be made in a good and workmanlike manner and in accordance with all applicable Laws. The Relevant Assets and all Additional Improvements shall remain the property of Lessee and shall be removed by Lessee within one (1) year after termination of this Lease (provided that such can be removed by Lessee without unreasonable damage or harm to the Premises) or, at Lessee’s option exercisable by notice to Lessor, surrendered to Lessor upon the termination of this Lease. Lessee shall not have the right or power to create or permit any lien of any kind or character on the Premises by reason of repair or construction or other work. In the event any such lien is filed against the Premises, Lessee shall cause such lien to be discharged or bonded within thirty (30) days of the date of filing thereof.
MAINTENANCE, REPAIRS, OR ALTERATIONS The Tenant shall, at their own expense and at all times, maintain premises in a clean and sanitary manner, and shall surrender the same at termination hereof, in as good condition as received, normal wear and tear excepted. The Tenant may not make any alterations to the leased premises without the consent in writing of the Landlord. The Landlord shall be responsible for repairs to the interior and exterior of the building. If the Premises includes a washer, dryer, freezer, dehumidifier unit and/or air conditioning unit, the Landlord makes no warranty as to the repair or replacement of units if one or all shall fail to operate. The Landlord will place fresh batteries in all battery-operated smoke detectors when the Tenant moves into the premises. After the initial placement of the fresh batteries it is the responsibility of the Tenant to replace batteries when needed. A monthly "cursory" inspection may be required for all fire extinguishers to make sure they are fully charged.
Additions and Alterations After Substantial Completion of the Facility and Leased Premises, Lessee shall have the right to make, at Lessee’s sole cost and expense, additions, alterations, and changes ("Alterations"), in or to the Leased Premises or the Improvements, provided Lessee shall not then be in default in the performance of any of Lessee's covenants or agreements in this Lease, subject, however, in all cases to the following: (1) No Alterations of any kind shall be made without the prior written consent of Lessor if the Alterations would tend to: (a) change the general character or structure of the Improvements on the Leased Premises, or (b) reduce or impair the value, rental, rental value, rentability, or usefulness of the Leased Premises or the Improvements or any part of same; (2) No Alterations shall be undertaken until Lessee shall have procured and paid for, to the extent the same may be required from time to time, all permits and authorizations of all municipal departments and governmental subdivisions having jurisdiction, and complied with all other laws, statutes, codes, ordinances, orders, rules, regulations, permits, or licenses relating to the Alterations; (3) Any structural Alterations involving in the aggregate an estimated cost of more than $ shall be conducted under the supervision of an architect or engineer selected by Lessee and approved in advance and in writing by Lessor (which approval shall not be unreasonably withheld or delayed). No such structural Alterations shall be made, except in accordance with detailed plans and specifications and cost estimates prepared and approved in writing by such architect or engineer and approved in advance and in writing by Lessor (which approval shall not be unreasonably withheld or delayed). In the event of Lessor's disapproval, Lessor shall give to Lessee an itemized statement of reasons for the disapproval. If Lessor does not disapprove the plans and specifications provided for in this paragraph within fifteen (15) days after they have been submitted to Lessor, the plans and specifications shall be deemed to have been approved by Lessor. Prior to commencing any work under this Section 11, Lessee shall furnish Lessor, on demand, with a good and sufficient surety bond insuring the completion of the work and the payment of all bills in connection with the work. (4) Any Alterations shall be made promptly, subject to Force Majeure Delay, and in a good and workmanlike manner and in compliance with all applicable laws, statutes, codes, ordinances, orders, rules, regulations, permits, or licenses, and all insurance policy provisions and requirements; (5) The cost of any such alterations shall be paid solely by Lessee in cash or its equivalent, including the cost of labor and materials supplied to the Leased Premises or the Improvements; (6) Workers' compensation insurance covering all persons employed in connection with the Alteration work and with respect to whom death or bodily injury claims could be asserted against Lessor, Lessee, or the Leased Premises or the Improvements, and commercial general liability insurance for the mutual benefit of Lessor and Lessee with limits of not less than $ in the event of bodily injury or death to one person and not less than $ in the event of bodily injury or death to any number of persons in any one accident, and with limits of not less than $ for damages or injury to property, with not more than a $ deductible, shall be maintained by Lessee at Lessee's sole cost and expense at all times when any substantial work is in progress in connection with any Alterations. All such insurance, if readily obtainable, shall be effected under standard form policies issued by insurers of recognized responsibility, which are duly licensed to issue such insurance in the State of Oklahoma and well rated by national rating organizations. SECTION TWELVE INSPECTIONS Lessee shall permit Lessor, Lessor’s agents, employees, and contractors to enter all parts of the Leased Premises and the Improvements during Lessee's regular business hours to inspect the same and to enforce or carry out any provisions of this Lease, provided Lessee is given reasonable advance notice, which may be verbal (except in an emergency, in which case no notice shall be necessary), and Lessee's Permitted Use shall not be unreasonably interfered with by Lessor during any entry authorized in this Section 12.
Maintenance Repairs and Alterations 7.1 Lessee's Obligations. -------------------- (a) Subject to Lessor's obligations under Paragraphs 6.2(b), 6.3(a), 7.3, 9 and 40, Lessee shall keep in good order, condition and repair the non- structural elements of the Premises and every part thereof, (whether or not the need for such repairs occurs as a result of Lessee's use, any prior use, the elements or the age of such portion of the Premises) including, without limiting the generality of the foregoing, all exposed plumbing, heating and air conditioning, ventilating, electrical, lighting facilities and equipment within the Premises, fixtures, walls (interior and nonstructural elements of exterior), ceilings, floors, windows, doors, plate glass and skylights located within the Premises, and all driveways, parking lots and striping thereon, landscaping, exterior lighting, fences and signs located on the Premises and sidewalks and parkways adjacent to the Premises. If the cost of repairing an element of the Premises is covered by a warranty obtained by Lessor from a third party contractor, subcontractor, consultant or material supplier in connection with construction work performed on the Premises prior to the Effective Date, Lessor shall make available such warranty to Lessee and shall assign to Lessee Lessor's rights thereunder, provided that Lessee shall not take any action which shall invalidate any such warranty or derogate from Lessor's remedies or recourse thereunder. (b) Lessee shall maintain the Premises as provided in Paragraph 7. I (a) and in accordance with the requirements of all Laws and any covenants or restrictions as may from time to time be applicable to Lessee's specific manner of use of the Premises and the conduct and operation of Lessee's business. Lessee, in keeping the Premises in good order, condition and repair, shall exercise and perform good maintenance practices and any damage or deterioration shall not be deemed "ordinary wear and tear" if the same could have been prevented by good maintenance practice. Lessee's obligations shall include restorations, replacements or renewals when determined not to be due to ordinary wear and tear or when made necessary due to failure to perform proper maintenance. (c) If the term of this Lease, as the same may be extended or renewed, exceeds five (5) years, Lessor shall have the right to require Lessee to repaint the exterior of THE improvements. but not more often than once every five (5) years, as reasonably necessary. (d) Lessee's obligations under this Paragraph 7.1 shall not apply to replacement, repair or restoration of items which are Lessor's obligation to replace, repair or restore pursuant to the terms of Paragraph 6.3(a) (relating to Existing Defects) Paragraph 7.3(a) relating to structural repairs and certain replacements) Paragraph 9 (relating to destruction of the Premises) or Paragraph 14 (relating to condemnation of the Premises).