EXTENSION OF USE COMMITMENT The Contractor agrees to honor all orders from State Agencies, political subdivisions and others authorized by law (see Section 25 Extension of Use) which are in compliance with the pricing, terms, and conditions set forth in the Contract. Any unilateral limitations/restrictions imposed by the Contractor on eligible Authorized Users will be grounds for cancellation of the Contract.
C4 Contract Price During Extension of the Initial Contract Period C4.1 Subject to the Pricing Schedule and the provision in clause F6 (Variation), the Contract Price shall apply for the Initial Contract Period and following an extension pursuant to clause F8 (Extension of Initial Contract Period), to the date of expiry of the extended period, or such earlier date of termination or partial termination of the agreement in accordance with the Law or the provisions of the Contract. C5 Euro
C4 Price adjustment on extension of the Initial Contract Period C4.1 The Contract Price shall apply for the Initial Contract Period. In the event that the Client agrees to extend the Initial Contract Period pursuant to clause F8 (Extension of Initial Contract Period) the Client shall, in the 6 month period prior to the expiry of the Initial Contract Period, enter into good faith negotiations with the Contractor (for a period of not more than 30 Working Days) to agree a variation in the Contract Price.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
Service Commitment Newly hired nurses and currently employed nurses who voluntarily choose to relocate and receive a relocation allowance may be required to serve for a minimum of two years at their base before they will be considered for transfer to another base. This commitment will not apply when the employer and nurse mutually agree to waive it and when relocation occurs as a result of layoff/rehire.
Credit for Project Work In order to compensate PURCHASER for project work that PURCHASER agrees to complete under the section titled, “Project Work,” of this contract, STATE agrees to credit PURCHASER’s timber account in the sum of $46,657 upon completion of and STATE’s acceptance of all work, unless otherwise approved in writing by STATE. PURCHASER may request partial credit for project work when PURCHASER has completed and STATE has accepted project work, in accordance with the following credit schedule: Partial credit amount of $24,999 (Project No. 1 completion) Partial credit amount of $ 545 (Project No. 2 completion) Partial credit amount of $ 2,721 (Project No. 3 completion) Partial credit amount of $ 1,753 (Project No. 4 completion) Partial credit amount of $16,639 (Project No. 5 completion)
F8 Extension of Initial Contract Period F8.1 The Authority may, by giving written notice to the Contractor, extend the Contract for a further period up to the date set out in the Form of Contract. The provisions of the Contract will apply throughout any such extended period.
A2 Initial Contract Period The Contract shall take effect on the Commencement Date and shall expire automatically on 30 June 2013, unless it is otherwise terminated in accordance with the provisions of the Contract, or otherwise lawfully terminated, or extended under clause F8 (Extension of Initial Contract Period).
Extension of Initial Contract Period 31.1 Subject to clause 13 (Price Adjustment on Extension of the Initial Contract Period), the Authority may, by giving written notice to the Contractor not less than three (3) Month(s) prior to the last day of the Initial Contract Period, extend the Contract for such further period as may be specified in the notice. The provisions of the Contract will apply (subject to any Variation or adjustment to the Contract Price pursuant to clause 13) throughout any such extended period.
Application of other Rules and Special Commitments 1. Where a matter is governed simultaneously both by this Agreement and by another international agreement to which both Contracting Parties are parties, nothing in this Agreement shall prevent either Contracting Party or any of its investors who own investments in the territory of the other Contracting Party from taking advantage of whichever rules are more favourable to his case.
