Safety Requirements The Contractor shall comply with all Federal, State, and local safety laws and regulations applicable to the Work performed under this Agreement.
Quality Requirements Performance Indicator Heading Indicator (specific) Threshold Method of Measurement Frequency of monitoring Consequence of Breach
Child Abuse Reporting Requirements A. Grantees shall comply with child abuse and neglect reporting requirements in Texas Family Code Chapter 261. This section is in addition to and does not supersede any other legal obligation of the Grantee to report child abuse.
B. Grantee shall use the Texas Abuse Hotline Website located at xxxxx://xxx.xxxxxxxxxxxxxx.xxx/Login/Default.aspx as required by the System Agency. Grantee shall retain reporting documentation on site and make it available for inspection by the System Agency.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Personnel Requirements a. The CONTRACTOR shall secure, at the CONTRACTOR'S own expense, all personnel required to perform this Contract.
b. The CONTRACTOR shall ensure that the CONTRACTOR'S employees or agents are experienced and fully qualified to engage in the activities and perform the services required under this Contract, and that all applicable licensing and operating requirements imposed or required under federal, state, or county law, and all applicable accreditation and other standards of quality generally accepted in the field of the activities of such employees and agents are complied with and satisfied.
Functional Requirements Applications must implement controls that protect against known vulnerabilities and threats, including Open Web Application Security Project (OWASP) Top 10 Risks and denial of service (DDOS) attacks.
CONTRACT WORK HOURS AND SAFETY STANDARDS As per the Contract Work Hours and Safety Standards Act (40 U.S.C. 3701-3708), where applicable, all Customer Purchase Orders in excess of ,000 that involve the employment of mechanics or laborers must include a provision for compliance with 40 U.S.C. 3702 and 3704, as supplemented by Department of Labor regulations (29 CFR Part 5). Under 40 U.S.C. 3702 of the Act, each contractor must be required to compute the wages of every mechanic and laborer on the basis of a standard work week of 40 hours. Work in excess of the standard work week is permissible provided that the worker is compensated at a rate of not less than one and a half times the basic rate of pay for all hours worked in excess of 40 hours in the work week. The requirements of 40 U.S.C. 3704 are applicable to construction work and provide that no laborer or mechanic must be required to work in surroundings or under working conditions which are unsanitary, hazardous or dangerous. These requirements do not apply to the purchases of supplies or materials or articles ordinarily available on the open market, or contracts for transportation or transmission of intelligence.
Health Requirements A. Provider shall remain in compliance with all applicable federal, state, county, and municipal, statutes, laws, ordinances, regulations, and guidelines, as well as any Board guidelines, policies, and rules in effect now or later, and as amended from time to time related to COVID-19.
B. Provider shall comply with evolving requirements to protect the health and safety of Student Participants and staff, as expressed in local, and state guidance from various government agencies. This includes, but is not limited to, adhering to all health and safety guidelines issued by CPS, IDPH, and CDPH related to COVID-19. Provider acknowledges these health and safety guidelines are subject to change.
C. Required health and safety practices may vary across age groups and settings. Provider shall comply, at a minimum, with all health and safety mandates issued by the State of Illinois and the City of Chicago and guidance from the Illinois State Board of Education (“ISBE”).
D. Under Chicago’s March 19 Public Health Order, congregate facilities (such as long-term care facilities, childcare settings, correctional facilities, etc.) must immediately report to CDPH clusters of COVID-19 patients, defined as two or more confirmed cases of COVID-19 occurring within 14 calendar days of each other at a facility. To report positive cases, Provider must complete the COVID-19 Online Case Report Form found at the following website: xxxxx://xxxxxx.xxx.xxxxxxxx.xxx/surveys/?s=FR7MAJAY84. A copy of the current COVID-19 Online Case Report Form is attached and incorporated into this Supplemental Scope as Attachment A. Provider must also comply with additional operational, reporting and tracing requirements established by CPS.
E. As of July 13, 2020, interim guidance issued by CDPH encourages notification for every COVID-19 case. For more information, see CDPH Interim Guidance on Management of COVID 19 Cases in Childcare Settings (“CDPH Guidance”) at the following link: https://xxx.xxxxxxx.xxx/content/dam/city/depts/cdph/HealthProtectionandResponse/Interim% 20Guidance%20on%20Management%20of%20COVID 19%20Cases%20in%20Childcare%20Settings%2007.13.
Export Requirements The Program, Documentation and all related technical information or materials are subject to export controls and U.S. Government export regulations. You will comply strictly with all legal requirements established under these controls and will not, in connection with its limited evaluation rights hereunder, export, re-export, divert, transfer or disclose, directly or indirectly the Program, Documentation and any related technical information or materials without the prior approval of the U.S.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
