We use cookies on our site to analyze traffic, enhance your experience, and provide you with tailored content.

For more information visit our privacy policy.

Flag State Sample Clauses

Flag State not later than thirty (30) days prior to the Delivery Date of a Ship, obtain the Agent’s written approval of the Flag State for such Ship; and
AutoNDA by SimpleDocs
Flag State. 35.1 The Vessel shall on the Delivery Date be registered in the name of the Owners under the laws and flag of the Flag State and the Head-Charterers and the Sub-Charterers shall provide the Owners with all such assistance as the Owners may reasonably require in obtaining and maintaining such registration and shall not during the Charter Period do or suffer anything to be done which might imperil such registration. Initial registration costs shall be for Owners’ account but thereafter all registration, tonnage and other taxes, imposts, dues and payments from time to time payable in connection with maintaining such registration shall be for the Sub-Charterers’ account and be payable on demand. No change shall be made to the Vessel’s Flag State without Sub-Charterers’ consent in writing (such consent not to be unreasonably withheld, delayed or conditioned) and the costs of any change (unless requested by Sub-Charterers) shall be for Owners’ account. 35.2 The Sub-Charterers shall have the right, subject to the prior approval of the Owners and the Approved Mortgagee (which the Head-Charterers shall procure is not unreasonably withheld, conditioned or delayed), and subject to the Sub-Charterers paying all costs associated therewith to require that the Owners register their title in another Flag State of the Sub-Charterers’ choice. 35.3 The Sub-Charterers acknowledge that it shall be reasonable for the Owners, the Head-Charterers and the Approved Mortgagee to withhold their approval if the Owners’ title to the Vessel or the Approved Mortgagee’s security would be adversely affected, or if either of them would become subject to additional taxes or other costs, unless indemnified by the Sub-Charterers, by reason of such change. 35.4 The name of the Vessel shall be chosen by the Sub-Charterers subject to the Owners’ and Head-Charterers’ consent which shall not be unreasonably withheld. Neither the Owners nor the Head-Charterers shall have any right to change the name of the Vessel, without the Sub-Charterers’ consent which shall not be unreasonably withheld or delayed. 35.5 The Sub-Charterers shall have the right to paint the Vessel in their own colours, install and display their funnel insignia and fly their own house flag provided that painting, re-painting, installation and re-installation shall be for the Sub-Charterers’ account.
Flag State the Flag State of a Ship becomes involved in hostilities or civil war or there is a seizure of civil power in the Flag State of a Ship by unconstitutional means if, in any such case such event could in the opinion of the Bank reasonably be expected to have a material adverse effect on the security constituted by any of the Security Documents; or
Flag State not later than thirty (30) days prior to the Delivery Date of a Ship, obtain the Agent’s written approval of the Flag State for such Ship (if other than Liberia, Xxxxxxxx Islands or Panama); and
Flag State the registration of a Ship or a Mortgage under the laws and flag of the relevant Flag State is cancelled or terminated without the prior written consent of the Security Trustee; or
Flag State not later than thirty (30) days prior to the Delivery Date of each Newbuilding, obtain the Bank’s written approval of the Flag State for such Newbuilding; and
Flag State the Borrower shall ensure that at all times the Ships are registered in the name of the relevant Owner under the laws and flag of the relevant Flag State and are free from Encumbrances other than the relevant Mortgage; and
AutoNDA by SimpleDocs
Flag State the Flag State becomes involved in hostilities or civil war or there is a seizure of civil power in the Flag State by unconstitutional means if, in any such case such event could in the opinion of the Bank reasonably be expected to have a material adverse effect on the security constituted by any of the Security Documents; or

Related to Flag State

  • Organisation The statutes, membership, procedures, and other matters relating to the Court of Justice shall be determined by the Assembly in a protocol relating to the Court of Justice.

  • Registry Lock Registry Operator may offer the Registry Lock service, which is a registry service that allows an authorized representative from the sponsoring Registrar, request the activation or deactivation of any of the following EPP statuses: serverUpdateProhibited, serverDeleteProhibited and⁄or serverTransferProhibited.

  • Safety; Security Contractor’s failure to comply with any of the requirements in this Section shall be cause for termination.

  • Clean Air Act and Federal Water Pollution Control Act The contractor agrees to comply with all applicable standards, orders or regulations issued pursuant to the Clean Air Act, as amended, 42 U.S.C. § 7401 et seq.

  • Contracting authority The contracting authority of this public contract is Enabel, the Belgian development agency, public-law company with social purposes, with its registered office at Xxx Xxxxx 000, 0000 Xxxxxxxx xx Xxxxxxx (enterprise number 0264.814.354, RPM/RPR Brussels). Enabel has the exclusive competence for the execution, in Belgium and abroad, of public service tasks of direct bilateral cooperation with partner countries. Moreover, it may also perform other development cooperation tasks at the request of public interest organisations, and it can develop its own activities to contribute towards realisation of its objectives. For this procurement contract, Xxxxxx is represented by person(s) who shall sign the award letter and are mandated to represent the organisation towards third parties.

  • Subsequent Legislation If the General Corporation Law of Delaware is amended after adoption of this Agreement to expand further the indemnification permitted to directors or officers, then the Corporation shall indemnify Indemnitee to the fullest extent permitted by the General Corporation Law of Delaware, as so amended.

  • Federal Water Pollution Control Act The contractor agrees to comply with all applicable standards, orders, or regulations issued pursuant to the Federal Water Pollution Control Act, as amended, 33 U.S.C. 1251 et seq.

  • Airport Security The Contractor shall be familiar with and conduct its operations in accordance with all regulations and directives of the Authority and the Transportation Security Administration, and any other federal, state or local government having jurisdiction over the airport, with respect to the maintenance of airport security.

  • OF CLEAN AIR ACT AND FEDERAL WATER POLLUTION CONTROL ACT This provision is applicable to all Federal-aid construction contracts and to all related subcontracts. By submission of this bid/proposal or the execution of this contract, or subcontract, as appropriate, the bidder, proposer, Federal-aid construction contractor, or subcontractor, as appropriate, will be deemed to have stipulated as follows: 1. That any person who is or will be utilized in the performance of this contract is not prohibited from receiving an award due to a violation of Section 508 of the Clean Water Act or Section 306 of the Clean Air Act. 2. That the contractor agrees to include or cause to be included the requirements of paragraph (1) of this Section X in every subcontract, and further agrees to take such action as the contracting agency may direct as a means of enforcing such requirements.

  • Safety and Security Procedures Contractor shall maintain and enforce, at the Contractor Work Locations, industry-standard safety and physical security policies and procedures. While at each JBE Work Location, Contractor shall comply with the safety and security policies and procedures in effect at such JBE Work Location.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!