ADDITIONAL SPECIAL CONTRACT CONDITIONS Special Contract Conditions revisions: the corresponding subsections of the Special Contract Conditions referenced below are replaced in their entirety with the following:
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Number Resources, Rate Center Areas and Routing Points 8.1 Nothing in this Agreement shall be construed to limit or otherwise adversely affect in any manner either Party’s right to employ or to request and be assigned any Central Office Codes (“NXX”) pursuant to the Central Office Code Assignment Guidelines and any relevant FCC or Commission orders, as may be amended from time to time, or to establish, by Tariff or otherwise, Rate Center Areas and Routing Points corresponding to such NXX codes.
8.2 It shall be the responsibility of each Party to program and update its own switches and network systems pursuant to information provided in the LERG in order to recognize and route traffic to the other Party’s assigned NXX codes. Except as expressly set forth in this Agreement, neither Party shall impose any fees or charges whatsoever on the other Party for such activities.
8.3 Unless otherwise required by Commission order, the Rate Center Areas will be the same for each Party. During the term of this Agreement, Onvoy shall adopt the Rate Center Area and Rate Center Points that the Commission has approved for Frontier within the LATA and Tandem serving area. Onvoy shall assign whole NPA-NXX codes to each Rate Center Area unless otherwise ordered by the FCC, the Commission or another governmental entity of appropriate jurisdiction, or the LEC industry adopts alternative methods of utilizing NXXs.
8.4 Onvoy will also designate a Routing Point for each assigned NXX code. Onvoy shall designate one location for each Rate Center Area in which the Onvoy has established NXX code(s) as the Routing Point for the NPA-NXXs associated with that Rate Center Area, and such Routing Point shall be within the same LATA as the Rate Center Area but not necessarily within the Rate Center Area itself. Unless specified otherwise, calls to subsequent NXXs of Onvoy will be routed in the same manner as calls to Xxxxx’s initial NXXs.
8.5 Notwithstanding anything to the contrary contained herein, nothing in this Agreement is intended, and nothing in this Agreement shall be construed, to in any way constrain Onvoy’s choices regarding the size of the local calling area(s) that Onvoy may establish for its Customers, which local calling areas may be larger than, smaller than, or identical to Frontier’s local calling areas.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Service Delivery Requirements The following sections describe in detail the work activity required by this program. All CONTRACTORS will be expected to fulfill the work activity requirements in these areas.
A. Staff Requirements & Policies CONTRACTOR shall provide the necessary management and administrative personnel whose expertise will ensure efficient operation of SNEMT services. OoA recognizes that a high quality operation begins with key personnel. Therefore, a minimum level of required staffing is described for the positions and functions described below.
1. Program Manager/Director The program manager/director will be in charge of all management and day- to-day operations of the CONTRACTOR’s SNEMT program. The position will maintain consistent and sufficient contact and communication with the OoA and be responsible for all CONTRACT obligations.
DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
Data Universal Number System (DUNS) number Requirement Grantee will provide their valid DUNS number contemporaneous with execution of this Agreement.
JOC - PRICING OF Regular Hours Coefficient What is your regular hours coefficient for the RS Means Price Book? (FAILURE TO RESPOND PROHIBITS PART 2 JOC EVALUATION)
– OTHER SPECIAL CONDITIONS I.
12.1 Exchange rate applicable for the conversion of currencies into euro Payments shall be made by the Commission in euro. The co-ordinator shall submit the payment requests in accordance with article I.5.3, including the underlying financial statements, in euro. By way of derogation from article II.16.1, any conversion of actual costs into euro shall be made by the beneficiary at the monthly accounting rate established by the Commission and published on its website applicable on the day when the cost was incurred.
STS-1 Loop STS-1 Loop is a high-capacity digital transmission path with SONET VT1.5 mapping that is dedicated for the use of the ordering customer for the purpose of provisioning local exchange and associated exchange access services. It is a two-point digital transmission path which provides for simultaneous two-way transmission of serial bipolar return-to-zero synchronous digital electrical signals at a transmission rate of 51.84 Mbps. It may provide transport for twenty-eight (28) DS1 channels, each of which provides the digital equivalent of twenty-four (24) analog voice grade channels. The interface to unbundled dedicated STS-1 transport is a metallic-based electrical interface.
