Product Data Illustrations, standard schedules, performance charts, instructions, brochures, diagrams, and other information furnished by Developer to illustrate a material, product, or system for some portion of the Work.
Licensed Products Lessee will obtain no title to Licensed Products which will at all times remain the property of the owner of the Licensed Products. A license from the owner may be required and it is Lessee's responsibility to obtain any required license before the use of the Licensed Products. Lessee agrees to treat the Licensed Products as confidential information of the owner, to observe all copyright restrictions, and not to reproduce or sell the Licensed Products.
Licensed Product The term “Licensed Product” shall mean any product (a) the manufacture, use, importation, sale or offer for sale of which would, in the absence of the license granted by this Agreement, infringe a Valid Claim of any of the Licensed Patent Rights, or (b) that is comprised of, utilizes or incorporates Licensed Biological Materials, or (c) that is discovered, developed or made using a Licensed Process.
SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work.
4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work.
4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged.
4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents.
4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents.
4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof.
4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals.
4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Product Labeling The labeling of all Licensed Products sold or offered for sale under this Agreement shall expressly state that the Licensed Product is manufactured under a license from the Medicines Patent Pool.
SOURCE CODE ESCROW FOR LICENSED PRODUCT If Source Code or Source Code escrow is offered by either Contractor or Product manufacturer or developer to any other commercial customers, Contractor shall either: (i) provide Licensee with the Source Code for the Product; or (ii) place the Source Code in a third party escrow arrangement with a designated escrow agent who shall be named and identified to the State, and who shall be directed to release the deposited Source Code in accordance with a standard escrow agreement acceptable to the State; or (iii) will certify to the State that the Product manufacturer/developer has named the State, acting by and through the Authorized User, and the Licensee, as a named beneficiary of an established escrow arrangement with its designated escrow agent who shall be named and identified to the State and Licensee, and who shall be directed to release the deposited Source Code in accordance with the terms of escrow. Source Code, as well as any corrections or enhancements to such source code, shall be updated for each new release of the Product in the same manner as provided above and such updating of escrow shall be certified to the State in writing. Contractor shall identify the escrow agent upon commencement of the Contract term and shall certify annually that the escrow remains in effect in compliance with the terms of this clause. The State may release the Source Code to Licensees under this Contract who have licensed Product or obtained services, who may use such copy of the Source Code to maintain the Product.
PRODUCT MANUFACTURER'S SUPPLIERS Only those dealers/distributors listed by the manufacturer will be considered authorized to act on behalf of the Product Manufacturer.
Regulatory Materials (a) On a Program-by-Program basis, commencing on the Effective Date until the Regulatory Transfer Date, Prothena shall have the right, in consultation with Celgene, to prepare, file and maintain all Regulatory Materials (including any Regulatory Approvals) necessary for the Development and Manufacture of any Collaboration Candidates and Collaboration Products for such Program (collectively, the “Program Regulatory Materials”), and to interact with Regulatory Authorities in connection with the Development and Manufacture of any Collaboration Candidates and Collaboration Products for such Program. Prothena will provide Celgene with a reasonable opportunity to comment substantively on all material Regulatory Materials prior to filing or taking material action, and will reasonably and in good faith consider any comments and actions recommended by Celgene, including with respect to filing strategy. In addition, Prothena will allow Celgene or its representative to attend any and all meetings with Regulatory Authorities to the extent such attendance is not prohibited or limited by such Regulatory Authority.
(b) If Celgene exercises its Phase 1 Portion Participation Right for a given Program, then immediately after such exercise, Prothena shall initiate the transfer of all Program Regulatory Materials, including for clarity any IND for the relevant Collaboration Candidates and/or Collaboration Products that are the subject of such Program to Celgene. The date on which such Program Regulatory Materials are transferred to Celgene shall be the “Regulatory Transfer Date” for such Program. Thereafter, Celgene shall have the right, in consultation with Prothena, to prepare, file, and maintain such Program Regulatory Materials, and to interact with Regulatory Authorities in connection with the Development and, as applicable, Manufacture of such Collaboration Candidates and Collaboration Products for such Program in accordance with the terms and conditions of Section 2.5. Additionally, with respect to any Phase 1 Clinical Trial conducted by Celgene pursuant to Section 2.5, Celgene will provide Prothena with a reasonable opportunity to comment substantively on all material Program Regulatory Materials prior to filing or taking material action, and will reasonably and in good faith consider any comments and actions recommended by Prothena, including with respect to filing strategy. In addition, with respect to any Phase 1 Clinical Trial conducted by Celgene pursuant to Section 2.5, Celgene will allow Prothena or its representative to attend any and all meetings with Regulatory Authorities to the extent such attendance is not prohibited or limited by such Regulatory Authority. For clarity, if the Regulatory Transfer Date does not occur prior to the expiration of the Option Term for such Program, Section 2.6.1(a) (and not this Section 2.6.1(b)) shall apply.
Licensed Technology (a) LICENSOR is not aware of any interference, infringement, misappropriation, or other conflict with any intellectual property rights of third parties, and LICENSOR has never received any charge, complaint, claim, demand, or notice alleging any such interference, infringement, misappropriation, or violation (including any claim that LICENSOR must license or refrain from using any intellectual property rights of any third party). To the knowledge of LICENSOR, no third party has interfered with, infringed upon, misappropriated, or otherwise come into conflict with any of the LICENSED TECHNOLOGY.
(b) Exhibit A identifies each patent or registration which has been issued to LICENSOR with respect to any of the LICENSED TECHNOLOGY and identifies each pending patent application or application for registration which LICENSOR has made with respect to any of the LICENSED TECHNOLOGY. LICENSEE acknowledges that LICENSOR has previously made available to LICENSEE correct and complete copies of all such patents, registrations and applications (as amended to-date) in LICENSOR’s possession and has made available to LICENSEE correct and complete copies of all other written documentation in LICENSOR’s possession evidencing ownership and prosecution (if applicable) of each such item.
(c) Exhibit A identifies each item of LICENSED TECHNOLOGY that is assigned to LICENSOR or that LICENSOR uses pursuant to license, sublicense, agreement, or permission. LICENSOR has made available to LICENSEE correct and complete copies of all such licenses, sublicenses, agreements, patent prosecution files and permissions (as amended to-date) in LICENSOR’s possession. With respect to each item of LICENSED TECHNOLOGY required to be identified in Exhibit A and to the knowledge of LICENSOR: (i) the license, sublicense, agreement, or permission covering the item is legal, valid, binding, enforceable, and in full force and effect; (ii) the license, sublicense, agreement, or permission will continue to be legal, valid, binding, enforceable, and in full force and effect on identical terms following the consummation of the transactions contemplated hereby; (iii) no Party to the license, sublicense, agreement, or permission is in breach or default, and no event has occurred which with notice or lapse of time would constitute a breach or default or permit termination, modification, or acceleration thereunder; (iv) no party to the license, sublicense, agreement, or permission has repudiated any provision thereof; (v) the underlying item of LICENSED TECHNOLOGY is not subject to any outstanding lien or encumbrance, injunction, judgment, order, decree, ruling, or charge; (vi) no action, suit, proceeding, hearing, investigation, charge, complaint, claim, or demand is pending or is threatened which challenges the legality, validity, or enforceability of the underlying item of LICENSED TECHNOLOGY; and (vii) except as provided in Exhibit A, LICENSOR has not granted any license or similar right to the LICENSED TECHNOLOGY within the GENERAL FIELD or PARTHENOGENESIS FIELD.
