GENERAL COMPLIANCE WITH RESPECT TO THE APARTMENT Subject to Clause 12 above, the Allottee shall, after taking possession, be solely responsible to maintain the [Apartment/Plot] at his/her own cost, in good repair and condition and shall not do or suffer to be done anything in or to the Building, or the [Apartment/Plot], or the staircases, lifts, common passages, corridors, circulation areas, atrium or the compound which may be in violation of any laws or rules of any authority or change or alter or make additions to the [Apartment/Plot] and keep the [Apartment/Plot], its walls and partitions, sewers, drains, pipe and appurtenances thereto or belonging thereto, in good and tenantable repair and maintain the same in a fit and proper condition and ensure that the support, shelter etc. of the Building is not in any way damaged or jeopardized. The Allottee further undertakes, assures and guarantees that he/she would not put any sign-board / name-plate, neon light, publicity material or advertisement material etc. on the face / facade of the Building or anywhere on the exterior of the Project, buildings therein or Common Areas. The Allottees shall also not change the colour scheme of the outer walls or painting of the exterior side of the windows or carry out any change in the exterior elevation or design. Further the Allottee shall not store any hazardous or combustible goods in the [Apartment/Plot] or place any heavy material in the common passages or staircase of the Building. The Allottee shall also not remove any wall, including the outer and load bearing wall of the [Apartment/Plot]. The Allottee shall plan and distribute its electrical load in conformity with the electrical systems installed by the Promoter and thereafter the association of allottees and/or maintenance agency appointed by association of allottees. The Allottee shall be responsible for any loss or damages arising out of breach of any of the aforesaid conditions.
COMPLIANCE WITH RESPECT TO THE APARTMENT 15.1 Subject to Para 12 above, the Allottee(s) shall, after taking possession, be solely responsible to maintain the said [Apartment] at his/her own cost, in good repair and condition and shall not do or suffer to be done anything in or to the said building [Apartment], or the staircases, lifts, common passages, corridors, circulation areas, atrium or compound which may be in violation of any laws or rules of any authority or change or alter or make additions to the said Apartment, and keep the said Apartment,, its walls and partitions, sewers, drains, pipes and appurtenances thereto or belonging thereto in good and tenantable repair and maintain the same in a fit and proper condition and ensure that the support, shelter etc. of the building is not in any way damaged or jeopardized.
15.2 The Allottee further undertakes, assures and grantees that he/ she would not put any sign-board/ name-plate, neon light, publicity material or advertisement material etc. on the façade of the building or anywhere on the exterior of the Project, building therein or common areas. The Allottee also not change the color scheme of outer wall or painting of the exterior side of windows or carry out any change in the exterior elevation or design. Further the Allottee shall store any hazardous or combustible goods in the [Apartment] or place any heavy material in the common passages or staircase of the building. The Allottee shall also not remove any wall, including the outer and load wall of the [Apartment].
15.3 The Allottee shall plan and distribute its electric load in conformity with the electric systems installed by the Promoter and thereafter the Association of allottees and/or maintenance agency appointed by the association of allottees. The Allottee shall be responsive for any loss or damages arising out of breach of any of the aforesaid conditions.
Prior Notice to Owners with Respect to Certain Matters Subject to the provisions and limitations of Section 4.04, with respect to the following matters, the Owner Trustee shall not take action unless at least 30 days before the taking of such action, the Owner Trustee shall have notified the Certificateholders in writing of the proposed action and the Owners shall not have notified the Owner Trustee in writing prior to the 30th day after such notice is given that such Owners have withheld consent or provided alternative direction:
(a) the initiation of any claim or lawsuit by the Issuer (except claims or lawsuits brought in connection with the collection of the Receivables) and the compromise of any action, claim or lawsuit brought by or against the Issuer (except with respect to the aforementioned claims or lawsuits for collection of the Receivables);
(b) the election by the Issuer to file an amendment to the Certificate of Trust (unless such amendment is required to be filed under the Statutory Trust Statute);
(c) the amendment of the Indenture by a supplemental indenture in circumstances where the consent of any Noteholder is required;
(d) the amendment of the Indenture by a supplemental indenture in circumstances where the consent of any Noteholder is not required and such amendment materially adversely affects the interests of the Owners;
(e) the amendment, change or modification of the Administration Agreement, except to cure any ambiguity or to amend or supplement any provision in a manner or add any provision that would not materially adversely affect the interests of the Owners; or
(f) the appointment pursuant to the Indenture of a successor Note Registrar, paying agent for the Notes or Indenture Trustee or pursuant to this Agreement of a successor Certificate Registrar, or the consent to the assignment by the Note Registrar, Paying Agent, Indenture Trustee or Certificate Registrar of its obligations under the Indenture or this Agreement, as applicable.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Action by Owners with Respect to Certain Matters The Owner Trustee shall not have the power, except upon the direction of the Owners, to (a) remove the Administrator under the Administration Agreement pursuant to Section 8 thereof, (b) appoint a successor Administrator pursuant to Section 8 of the Administration Agreement, (c) remove the Servicer under the Sale and Servicing Agreement pursuant to Section 8.01 thereof or (d) except as expressly provided in the Basic Documents, sell the Receivables after the termination of the Indenture. The Owner Trustee shall take the actions referred to in the preceding sentence only upon written instructions signed by the Owners.
Amendments, Etc. With Respect to the Obligations Each Guarantor shall remain obligated hereunder notwithstanding that, without any reservation of rights against any Guarantor and without notice to or further assent by any Guarantor, any demand for payment of any of the Obligations made by the Purchasers may be rescinded by the Purchasers and any of the Obligations continued, and the Obligations, or the liability of any other Person upon or for any part thereof, or any collateral security or guarantee therefor or right of offset with respect thereto, may, from time to time, in whole or in part, be renewed, extended, amended, modified, accelerated, compromised, waived, surrendered or released by the Purchasers, and the Purchase Agreement and the other Transaction Documents and any other documents executed and delivered in connection therewith may be amended, modified, supplemented or terminated, in whole or in part, as the Purchasers may deem advisable from time to time, and any collateral security, guarantee or right of offset at any time held by the Purchasers for the payment of the Obligations may be sold, exchanged, waived, surrendered or released. The Purchasers shall have no obligation to protect, secure, perfect or insure any Lien at any time held by them as security for the Obligations or for the guarantee contained in this Section 2 or any property subject thereto.
Agreement with Respect to Leased Data Processing Equipment (a) The Receiver hereby grants to the Assuming Bank an exclusive option for the period of ninety (90) days commencing the day after Bank Closing to accept an assignment from the Receiver of any or all Data Processing Leases to the extent that such Data Processing Leases can be assigned.
(b) The Assuming Bank shall (i) give written notice to the Receiver within the option period specified in Section 4.7(a) of its intent to accept or decline an assignment or sublease of any or all Data Processing Leases and promptly accept an assignment or sublease of such Data Processing Leases, and (ii) give written notice to the appropriate lessor(s) that it has accepted an assignment or sublease of any such Data Processing Leases.
(c) The Receiver agrees to facilitate the assignment or sublease of Data Processing Leases or the negotiation of new leases or license agreements by the Assuming Bank; provided, that neither the Receiver nor the Corporation shall be obligated to engage in litigation or make payments to the Assuming Bank or to any third party in connection with facilitating any such assumption, assignment, sublease or negotiation.
(d) The Assuming Bank agrees, during its period of use of any property subject to a Data Processing Lease, to pay to the Receiver or to appropriate third parties at the direction of the Receiver all operating costs with respect thereto and to comply with all relevant terms of the applicable Data Processing Leases entered into by the Failed Bank, including without limitation the timely payment of all rent, taxes, fees, charges, utilities, insurance and assessments.
(e) The Assuming Bank shall, not later than fifty (50) days after giving the notice provided in Section 4.7(b), (i) relinquish and release to the Receiver all property subject to the relevant Data Processing Lease, in the same condition as at Bank Closing, normal wear and tear excepted, or (ii) accept an assignment or a sublease thereof or negotiate a new lease or license agreement under this Section 4.7.
Prior Notice with Respect to Certain Matters With respect to the following matters, the Owner Trustee shall not take action unless at least 30 days before the taking of such action, the Owner Trustee shall have notified the Servicer of record as of the preceding Record Date in writing of the proposed action and such Servicer shall not have notified the Owner Trustee in writing prior to the 30th day after such notice is given that such Servicer has withheld consent or provided alternative direction:
(a) the initiation of any claim or lawsuit by the Trust (except claims or lawsuits brought in connection with the collection of the Receivables) and the compromise of any action, claim or lawsuit brought by or against the Trust (except with respect to the aforementioned claims or lawsuits for collection of the Receivables);
(b) the election by the Trust to file an amendment to the Certificate of Trust (unless such amendment is required to be filed under the Statutory Trust Act);
(c) the amendment of the Indenture by a supplemental indenture or any other change to this Agreement or any Basic Document in circumstances where the consent of any Noteholder is required;
(d) the amendment of the Indenture by a supplemental indenture or any other change to this Agreement or any Basic Document in circumstances where the consent of any Noteholder is not required and such amendment would materially adversely affect the interests of the Certificateholders;
(e) the amendment, change or modification of the Administration Agreement, except to cure any ambiguity or to amend or supplement any provision in a manner or add any provision that would not materially adversely affect the interests of the Certificateholders;
(f) the appointment pursuant to the Indenture of a successor Note Registrar, Paying Agent or Indenture Trustee or pursuant to this Agreement of a successor Certificate Registrar, or the consent to the assignment by the Note Registrar, Paying Agent or Indenture Trustee or Certificate Registrar of its obligations under the Indenture or this Agreement, as applicable;
(g) the consent to the calling or waiver of any default of any Basic Document;
(h) the consent to the assignment by the Indenture Trustee or Servicer of their respective obligations under any Basic Document, unless permitted in the Basic Documents;
(i) except as provided in Article 9 hereof, dissolve, terminate or liquidate the Trust in whole or in part;
(j) merge or consolidate the Trust with or into any other entity, or convey or transfer all or substantially all of the Trust’s assets to any other entity;
(k) cause the Trust to incur, assume or guaranty any indebtedness other than as set forth in this Agreement or the Basic Documents;
(l) do any act that conflicts with any other Basic Document;
(m) do any act that would make it impossible to carry on the ordinary business of the Trust as described in Section 2.03 hereof;
(n) confess a judgment against the Trust;
(o) possess Trust assets, or assign the Trust’s right to property, for other than a Trust purpose;
(p) cause the Trust to lend any funds to any entity, unless permitted in the Basic Documents; or
(q) change the Trust’s purpose and powers from those set forth in this Agreement. In addition, the Trust shall not commingle its assets with those of any other entity. The Trust shall maintain its financial and accounting books and records separate from those of any other entity. Except as expressly set forth herein, the Trust shall not pay the indebtedness, operating expenses and liabilities of any other entity. The Trust shall maintain appropriate minutes or other records of all appropriate actions and shall maintain its office separate from the offices of the Depositor and the Servicer. The Owner Trustee shall not have the power, except upon the direction of the Servicer and to the extent otherwise consistent with the Basic Documents, to (i) remove or replace the Indenture Trustee, (ii) institute proceedings to have the Trust declared or adjudicated a bankrupt or insolvent, (iii) consent to the institution of bankruptcy or insolvency proceedings against the Trust, (iv) file a petition or consent to a petition seeking reorganization or relief on behalf of the Trust under any applicable federal or state law relating to bankruptcy, (v) consent to the appointment of a receiver, liquidator, assignee, trustee, sequestrator (or any similar official) of the Trust or a substantial portion of the property of the Trust, (vi) make any assignment for the benefit of the Trust’s creditors, (vii) cause the Trust to admit in writing its inability to pay its debts generally as they become due or (viii) take any action, or cause the Trust to take any action, in furtherance of any of the foregoing (any of the above, a “Bankruptcy Action”). So long as the Indenture remains in effect, to the extent permitted by applicable law, no Certificateholder shall have the power to take, and shall not take, any Bankruptcy Action with respect to the Trust or direct the Owner Trustee to take any Bankruptcy Action with respect to the Trust.
Award Subject to Acceptance of Agreement The Award shall be null and void unless the Holder accepts this Agreement by executing it in the space provided below and returning such original execution copy to the Company, or by approving this Agreement by electronic means in a manner that has been approved by the Company.
