General Operating Obligations Sample Clauses

General Operating Obligations. Subject to the provisions of this Agreement, Live Nation shall have the authority and responsibility to take all actions necessary or appropriate for the operation, management, promotion and maintenance of the Facility at the Applicable Standard, including but not limited to the following: a. Employ or contract for such workers, mechanics, laborers, clerks, legal counsel, consultants, accountants and other employees and contractors as are reasonably necessary or appropriate in the management, maintenance and operation of the Facility; b. Procure and pay for such materials, services, public utility services, supplies and equipment as are reasonably necessary or appropriate in the management, maintenance and operation of the Facility, consistent with the terms of this Agreement; c. Procure and maintain in force and effect the policies of insurance required of Live Nation by this Agreement; d. Use or permit the use of all or any part of the Facility for events consistent with the terms of this Agreement; e. Operate or grant concession privileges for the vending and sale of food and beverages, including alcoholic beverages, programs, souvenirs, novelties, retail merchandise and similar articles, and other articles, or for the renting of any such articles, consistent with the terms of this Agreement; f. Take and omit such other actions, enter into such other agreements, documents, and instruments, and engage in such other transactions, as are reasonably necessary or appropriate in connection with the management, operation, maintenance, improvement and administration of the Facility, consistent with the terms of this Agreement; g. Administer all business operations and activities related to the Facility, except as otherwise specifically provided herein; and h. Provide for all necessary on-site security at the Facility.
Sample 1
AutoNDA by SimpleDocs

Related to General Operating Obligations

  • General Operations Tenant covenants and agrees to furnish to Landlord, within thirty (30) days after receipt or modification thereof, copies of: (a) all licenses authorizing Tenant or any Manager to operate any Facility for its Primary Intended Use; (b) all Medicare and Medicaid certifications, together with provider agreements and all material correspondence relating thereto with respect to any Facility (excluding, however, correspondence which may be subject to any attorney client privilege); (c) if required under Applicable Law with respect to any Facility, a license for each individual employed as administrator with respect to such Facility; (d) all reports of surveys, statements of deficiencies, plans of correction, and all material correspondence relating thereto, including, without limitation, all reports and material correspondence concerning compliance with or enforcement of licensure, Medicare/Medicaid, and accreditation requirements, including physical environment and Life Safety Code survey reports (excluding, however, correspondence which may be subject to any attorney client privilege); and (e) with reasonable promptness, such other confirmation as to the licensure and Medicare and Medicaid participation of Tenant as Landlord may reasonably request from time to time.

  • Your General Obligations 6.1 Full information You must give us any information we reasonably require for the purposes of this contract. The information must be correct, and you must not mislead or deceive us in relation to any information provided to us. 6.2 Updating information You must tell us promptly if information you have provided to us changes, including if your billing address changes or if your use of energy changes (for example, if you start running a business at the premises).

  • General Overview 2.1.1 If DTI requires maintenance for its local service customers, DTI will initiate a request for repair (sometimes referred to as a "trouble report") by calling GTE's Customer Care Repair Center. During this call, GTE service representatives will verify that the end-user is DTI customer and will then obtain the necessary information from DTI to process the trouble report. While DTI representatives are still on the line, GTE personnel will perform an initial analysis of the problem and remote line testing for resale services. If engineered services are involved, the call will be made to the GTE SSCC for handling. If no engineering is required and the line testing reveals that the trouble can be repaired remotely, GTE personnel will correct the problem and close the trouble report while DTI representatives are still on the line. If on-line resolution is not possible, GTE personnel will provide DTI representatives a commitment time for repair, and the GTE personnel then will enter the trouble ticket into the GTE service dispatch queue. DTI's repair service commitment times will be within the same intervals as GTE provides to its own end users. Maintenance and repair of GTE facilities is the responsibility of GTE and will be performed at no incremental charge to DTI. If, as a result of DTI-initiated trouble report, trouble is found to be the responsibility of DTI (e.g., non-network cause) GTE will charge DTI for trouble isolation. DTI will have the ability to report trouble for its end users to appropriate trouble reporting centers 24 hours a day, 7 days a week. DTI will be assigned a customer contact center when initial service agreements are made.

  • General Obligations of the Parties A. Recognition of Higher Education Partner, Promotion, Marketing, and Advertising 1) When reporting and publicizing high school students’ completion of dual credit courses, degrees, or certificates, Xxxxxxx ISD will recognize Collin College as their higher education partner awarding college credit. Both Parties agree not to use the other Party’s name, logo, or likeness in any press release, marketing materials, or other public announcements without receiving prior written approval from an authorized designee. B. Understanding of the Parties 1) Both parties understand the safety and security risks inherent with minors and agree that certain risks may be unforeseeable. Further, the Parties agree that the public safety departments from both Collin College and Xxxxxxx ISD will collaborate to develop and/or review safety and security standards and/or guidelines, including emergency response. 2) In accordance with FERPA, Collin College and Xxxxxxx ISD will protect students’ privacy and guard against the unauthorized release of identifying student information and records, and comply with all applicable requirements of FERPA.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • GENERAL WORKING CONDITIONS Section 18-1. Employment begins and ends at each project site. Section 18-2. The selection of craft foremen and/or general foremen and the number of foremen required shall be entirely the responsibility of the Employer, it being understood that in the selection of such foremen and/or general foremen the Employer will give primary consideration to the qualified individuals available in the local area. After giving such consideration, the Employer may select such individuals from other areas. All foremen shall take orders from the designated Employer representatives. Craft foremen shall be designated working foremen at the request of the Employer. Section 18-3. There shall be no limit on production by employees nor restrictions on the full use of tools or equipment. Employees using tools shall perform any of the work of the trade and shall work under the direction of the craft foremen. There shall be no restrictions on efficient use of manpower other than as may be required by safety regulations. Section 18-4. Employees shall be at their place of work at the starting time and shall remain at their place of work performing their assigned functions under the supervision of the Employer until quitting time. The parties reaffirm their policy of a fair day’s work for a fair day’s wage. Section 18-5. All equipment assigned to a project shall be under the control of the Employer. The Employer shall have the right to determine how many pieces of equipment an individual employee shall operate. In an emergency, foremen shall operate any equipment assigned by the Employer, and there shall be no restriction on foremen in the use of the tools of his or her craft in such emergency. The foremen shall be from the craft normally operating the equipment. In accordance with currently recognized craft jurisdiction, the Employer shall determine the assignment of employees to start, stop, and maintain small portable construction equipment. Such work may be assigned to craft employees within a reasonable distance of their primary duties or an employee may be assigned full time to start, stop and maintain the Employer’s small, portable equipment on the job site. There shall be no over xxxxxxx of this type of equipment. The number of employees assigned to rigging and scaffolding operations shall be at the sole discretion of the Employer. The ratio of journeyperson to welders shall be determined solely by the Employer. Section 18-6. The Employer may utilize the most efficient methods or techniques of construction, tools or other labor saving devices to accomplish the work. Practices not a part of the terms and conditions of this Agreement, stand by crews and feather bedding practices will not be recognized. Section 18-7. It is recognized that specialized or unusual equipment may be installed and/ or serviced by individuals who have special training, skill, or qualifications and are not covered by this Agreement. Testing, inspection, or service performed on plant equipment under warranty may be performed by the vendor’s personnel. Section 18-8. Neither the Union nor its local unions shall coerce or in any way interfere with the Owner’s personnel, operation or facilities at the plant site. The Owner’s right to contract directly with other companies for work at the plant site shall not be limited, and the Union shall cooperate and not interfere with the Employer’s operations. Section 18-9. It is agreed that overtime is undesirable and not in the best interest of the industry or the employees; therefore, except in unusual circumstances, overtime will not be worked. Where unusual circumstances do exist, however, the Employer will have the right to assign specific employees and/or crews to perform such overtime work as is necessary to accomplish the job. Section 18-10. There will be no rest periods, organized coffee breaks or other non-working time established during working hours. Section 18-11. Individual seniority shall not be recognized or applied to employees working on projects under this Agreement. Section 18-12. The Employer shall establish such reasonable project rules as the Employer deems appropriate. These rules will be reviewed at the pre-job conference and posted at the project site by the Employer, and may be amended thereafter as necessary.

  • Audit Rights Period for Construction-Related Accounts and Records Accounts and records related to the design, engineering, procurement, and construction of Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades shall be subject to audit for a period of twenty-four months following Connecting Transmission Owner’s issuance of a final invoice in accordance with Article 12.2 of this Agreement.

  • General Assets All amounts credited in respect of the RSUs to the book-entry account under this Agreement shall continue for all purposes to be part of the general assets of the Company. The Participant’s interest in such account shall make the Participant only a general, unsecured creditor of the Company.

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

  • General Obligation Except as permitted by Clause 14.2, all Confidential Information shall be held confidential during and after the continuance of this contract and shall not be divulged in any way to any third party without the prior written approval of the other party.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!