Compensation for Basic Services A. Owner shall make payment for Part I and Part II services monthly. The payments shall be in proportion to the progress of Engineer's work. Final payment for each phase shall become due and payable upon completion and approval by Owner of that phase of Engineer's work. B. Owner shall make payment for Construction Phase services not more frequently than monthly in proportion to the amount of the gross progress payments to Contractor(s). C. Owner shall make no deduction from Engineer's compensation on account of penalties, liquidated damages or other sums withheld from Contractor(s) through no fault of Engineer. D. Owner shall make payment for Construction Completion Phase services upon completion of the requirements set forth in subsections II. F. 1, 2 and 3. E. Engineer shall submit requests for payment monthly on forms provided and in a manner prescribed by Owner.
Subcontracting for Medicaid Services Notwithstanding any permitted subcontracting of services to be performed under this Agreement, Party shall remain responsible for ensuring that this Agreement is fully performed according to its terms, that subcontractor remains in compliance with the terms hereof, and that subcontractor complies with all state and federal laws and regulations relating to the Medicaid program in Vermont. Subcontracts, and any service provider agreements entered into by Party in connection with the performance of this Agreement, must clearly specify in writing the responsibilities of the subcontractor or other service provider and Party must retain the authority to revoke its subcontract or service provider agreement or to impose other sanctions if the performance of the subcontractor or service provider is inadequate or if its performance deviates from any requirement of this Agreement. Party shall make available on request all contracts, subcontracts and service provider agreements between the Party, subcontractors and other service providers to the Agency of Human Services and any of its departments as well as to the Center for Medicare and Medicaid Services.
Basic Services The Architect/Engineer’s Basic Services include all disciplines identified in Article 15 and all related usual and customary design, consultant, and other services necessary and reasonably inferable to complete the Project, or any phase of the Project, in accordance with the Owner’s requirements and the terms of this Agreement.
Web Services Our Web Services are designed to enable you to easily establish a presence on the Internet. Our Web Hosting and Design is composed of our Web Hosting and Design Publishing Component and other miscellaneous components. These components may be used independently or in conjunction with each other.
REGULATORY ADMINISTRATION SERVICES BNY Mellon shall provide the following regulatory administration services for each Fund and Series: Assist the Fund in responding to SEC examination requests by providing requested documents in the possession of BNY Mellon that are on the SEC examination request list and by making employees responsible for providing services available to regulatory authorities having jurisdiction over the performance of such services as may be required or reasonably requested by such regulatory authorities; Assist with and/or coordinate such other filings, notices and regulatory matters and other due diligence requests or requests for proposal on such terms and conditions as BNY Mellon and the applicable Fund on behalf of itself and its Series may mutually agree upon in writing from time to time; and
Standard Services As long as Tenant is not in default under any of the provisions of this Lease, Landlord shall cause the Leased Premises (in accordance with Section 10.3 below) and the public and common areas of the Building, (and the Project Common Areas), including the lobbies, elevators, stairs, corridors and rest rooms, to be maintained in reasonably good order and condition consistent with the operation and maintenance of the Building as a first-class office building in downtown Bellevue, except for damage occasioned by any act or omission of Tenant or Tenant's officers, contractors, agents, invitees, licensees or employees, the repair of which shall be paid for by Tenant ,so long as damage occasioned by other tenants and their officers, contractors, agents, invitees, licensees or employees, is paid for by such other tenants. From 7:00 a.m. to 6:00 p.m. on weekdays, excluding legal holidays, and from 8:00 a.m. to noon on Saturdays ("Regular Business Hours"), Landlord shall furnish the Leased Premises with electricity for lighting and operation of low power usage office machines, water, heat, air conditioning and elevator service as is customary and anticipated by tenants in a first-class office building (the "Standard Services"). During all other hours, Landlord shall furnish the Standard Services, including elevator service as reasonably required to provide access to the Leased Premises, except for heat and air conditioning and lighting. If requested by Tenant, Landlord shall furnish heat and air conditioning and lighting at times other than Regular Business Hours and the cost of such services, as established by Landlord (which in no event shall exceed Landlords' actual cost of such services), shall be paid by Tenant in the same manner as provided in Section 4.1 above. Landlord also shall provide lamp replacement service for Building Standard fluorescent light fixtures (but not for any specialty lighting installed by Tenant), toilet room supplies, window washing at reasonable intervals and customary building janitorial service in the Leased Premises consistent with those services in other first-class office buildings as part of the Standard Services, although no janitorial service shall be provided for Saturdays, Sundays or legal holidays. The cost and expense of any janitorial or other services provided or caused to be provided by Landlord to Tenant in addition to the services ordinarily provided Building tenants or is excessive relative to services provided to other tenants in the Building generally, Tenant shall reimburse Landlord upon demand for the additional cost resulting from such services, which shall be paid by Tenant in the same manner as provided for payment in Section 4.1 above. Standard Services shall not include any security services exclusively for Tenant within the Leased Premises. General security services will be provided in a manner consistent with the nature of the Project, and its cost will be allocated as a Building and/or Project Operating Cost. Landlord has not and does not make any representations to Tenant and assumes no responsibility to Tenant that the security services that are provided by Landlord will be effective in preventing any harm, both physical and economic, to Tenant or any of Tenant's employees or invitees. The HVAC system that Landlord shall install in the Building is generally described in Schedule D-1 and, among other things, shall allow temperature adjustments to be made in the Leased Premises on a zone by zone basis on each floor. Tenant shall pay any and all costs required to implement the features of the system by which Tenant may make temporary adjustments on a zone by zone basis on each floor . Any services provided by Landlord under this Section 6.4 shall be applied consistently and in a nondiscriminatory manner.
Support Services Rehabilitation, counselling and EAP’s. Support is strictly non- punitive, and can be accessed at anytime (self-identification of the need for help is strongly encouraged).
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Voice Services In lieu of any other rates and discounts, Customer will pay fixed per-minute rates ranging from $0.000 to $0.000 for the following Voice Services: Domestic Voice Service: Domestic Outbound Voice Service, including Calling Card and Domestic Inbound Voice Service based on origination and termination type. Data Services:
Administration Services When a medical prescription drug is administered by infusion, the administration of the prescription drug may be covered separately from the prescription drug. See Infusion Therapy - Administration Services in the Summary of Medical Benefits for benefit limits and the amount you pay. Prescription drugs that are self-administered are not covered as a medical benefit but may be covered as a pharmacy benefit. Please see Pharmacy Prescription Drugs and Diabetic Equipment or Supplies – Pharmacy Benefits section above for additional information. For some medical prescription drugs, after the first administration, coverage may be limited to certain locations (for example, a designated outpatient or ambulatory service facility, physician’s office, or your home), provided the location is appropriate based on your medical status. For a list of medical prescription drugs that are subject to this Site of Care Program, visit our website. Preauthorization may be required to determine medical necessity as well as appropriate site of care. If we deny your request for preauthorization, or you disagree with our determination for the appropriate site of care, you can submit a medical appeal. See Appeals in Section 5 for information on how to file a medical appeal.
