Underground Tanks If underground or other storage tanks storing Hazardous Materials located on the Premises or the Project are used by Tenant or are hereafter placed on the Premises or the Project by Tenant, Tenant shall install, use, monitor, operate, maintain, upgrade and manage such storage tanks, maintain appropriate records, obtain and maintain appropriate insurance, implement reporting procedures, properly close any underground storage tanks, and take or cause to be taken all other actions necessary or required under applicable state and federal Legal Requirements, as such now exists or may hereafter be adopted or amended in connection with the installation, use, maintenance, management, operation, upgrading and closure of such storage tanks.
Building Access The authorized representatives of the Union shall upon request have access to the District’s premises at any reasonable time for the purpose of adjusting grievances, investigating working conditions, or ascertaining that provisions of this Agreement are being adhered to; provided the representatives check in with the front office, following school protocol to receive a visitor’s badge, they do not interfere with employees in the performance of their duties. The Union shall furnish the District with the names of its authorized representatives.
Landlord Improvements (a) On the Commencement Date, Landlord will deliver the Leased Premises to Tenant in a broom clean condition, and, along with the lighting, electrical (excluding the UPS system and the diesel generator), mechanical and plumbing fixtures, plumbing systems, dock doors and HVAC servicing the Leased Premises, hot water, doors and plate-glass, will be delivered to Tenant in good condition and repair, as defined in Section 5.05 above. (b) After receipt of the Letter of Credit and any required building permit, Landlord will commence and diligently pursue to completion, the construction of the improvements to the Leased Premises (the “Landlord Improvements”), in accordance with plans and specifications as shown in Exhibit B, subject to approval by local regulatory authorities (the “Plans”), which Plans are made a part of this Lease by reference. Any changes or modifications to the Plans must be made and accepted by written change order or agreement signed by Landlord and Tenant and will constitute an amendment to this Lease. Any Landlord Improvements made by Landlord are the property of Landlord and must be surrendered to Landlord upon the termination of this Lease without credit to Tenant. Upon completion of any Landlord Improvements and issuance of a final certificate of occupancy (to be applied for by Landlord’s general contractor) and certification from Landlord’s general contractor certifying to Tenant that all Landlord Improvements have been completed in accordance with the Plans (the “General Contractor’s Certificate”), thereafter Landlord shall provide and Tenant shall acknowledge receipt and acceptance of “as-built plans” of all work done in accordance with this Section 6.01. (c) Landlord shall furnish an allowance of up to $172,800.00 (One hundred seventy-two thousand, eight hundred dollars) (“Landlord Improvement Allowance”) to be credited against the cost of the construction of the Landlord Improvements. If the actual cost of construction of the Landlord Improvements is less than the Landlord Improvement Allowance (“Allowance Overage”), Tenant shall have no right or claim to such difference; provided however, that if there is an Allowance Overage, Landlord, upon submission of supporting documentation by Tenant, will reimburse Tenant for any third party costs of low voltage wiring and laboratory benches for the Leased Premises, but such reimbursement shall not exceed the lesser of the Allowance Overage or 69,120.00 (Sixty-nine thousand, one hundred twenty & xx/100 dollars). If the actual cost of construction of the Landlord Improvements exceeds the Landlord Improvement Allowance, Tenant shall pay such excess cost to Landlord within ten (10) business days after receipt of supporting documentation and the General Contractor’s Certificate,. (d) Notwithstanding anything contained in Section 6.01 (c) above, within 30 days after the issuance of the General Contractor’s Certificate, Landlord will determine the sum of (i) the actual cost of the Landlord Improvements, plus (ii) if any, the actual costs submitted by Tenant towards the Contingent Allowance, and the product of the calculation shall be rounded to the next $1,000.00 (One Thousand Dollars). If the resultant amount is less than the Landlord Improvement Allowance, Landlord shall reduce the monthly Base Rent by $20.25 (“Base Rent Reduction Factor”) for each whole $1,000.00 (One Thousand Dollars) of such amount effective January 1, 2012. If it is determined that the monthly Base Rent is to be reduced and if Tenant has already paid Base Rent in a pre-reduction amount, Landlord shall give Tenant credit for any such excess payment, and reduction in monthly Base Rent shall be memorialized in an amendment to this Lease. In the event that the monthly Base Rent is reduced in accordance with this Section 6.01(d), there shall be no reduction in the Security Deposit Amount or in the requirements set forth for the Letter of Credit. The following example illustrates the intentions of the parties hereto as to computation of any reduction of the monthly Base Rent: Assumptions: 1. Actual cost of the Landlord Improvements: $100,000.00 2. Actual cost of qualifying costs for Contingent Allowance: $50,500.00 Total cost of Landlord Improvements and Contingent Allowance Costs: ($100,000.00 + $50,500.00) = $150,500.00 Determination of reduction in monthly Base Rent: Total Landlord Improvement Allowance $ 172,800.00 Less total cost of Landlord Improvements and contingent costs 150,500.00 $ 22300.00 Rounded to next $1,000.00 (One Thousand Dollars) $ 23,000.00 Divided by $1,000.00 (One Thousand Dollars) 1,000.00 Base Rent Reduction Factor 20.25 Reduction in monthly Base Rent $ 465.75 (e) In addition to the Landlord Improvements, Landlord, at Landlord’s sole cost and expense, shall have the following additional work performed on the Leased Premises prior to delivery of possession to Tenant, such work to be coordinated with the construction of the Landlord Improvements: (i) Replace all stained, damaged or missing ceiling tiles, (ii) Paint all walls in the Leased Premises, the color to be designated by Tenant, (iii) Replace all vinyl floor tiles in the open laboratory area as shown in Exhibit C, (iv) Shampoo all carpets in the office areas and hallways and (v) Any existing water supply or drainage pipes in the open lab area that are not initially utilized by Tenant shall be capped and made reasonably flush with the floor, but such capping shall allow for those pipes to be tapped by Tenant for future use. (vi) Re-caulk all perimeter flashing; install new pads under all gas line blocking; repair any loose or open curb or wall flashing; repack all pitch pans; repair any open joints on gravel guard; repair any loose scupper flashing; clean, prime and install EPDM peel and stick tape to all roof side tilt wall joints; clean all debris from around drains and entire roof; install Xxxxxx 97 asbestos free aluminum coating to entire roof surface (vii) Repair any existing alligator or pothole areas.
Tenant Improvements Landlord shall cause the Core and Shell Contractor or another Contractor designated by Landlord and approved by Tenant, such consent not to be unreasonably withheld or delayed (“TI Contractor”, and together with Core and Shell Contractor, “Contractor”) to commence and thereafter diligently prosecute the construction of the tenant improvements in the Premises pursuant to the Work Letter (the “Tenant Improvements”); provided, however, that before performing the Tenant Improvements, Landlord shall prepare in good faith an estimated budget for the construction of the Tenant Improvements and deliver such budget to Tenant for Tenant’s written approval prior the start of construction (the “Budget”). Landlord and Tenant shall work together cooperatively and in good faith to achieve a mutually acceptable Budget. Landlord shall update the Budget for Tenant’s review and approval at reasonable intervals and shall notify Tenant in writing if the Budget is likely to be exceeded. If there is an indication that the Budget is likely to be exceeded, Landlord and Tenant shall work together cooperatively, if required by Tenant, to modify the scope of the Tenant Improvements to bring the same in line with a budget reasonably acceptable to Tenant. The Tenant Improvements shall be performed in a workmanlike manner and shall substantially conform with Applicable Laws and the Approved TI Plans (as defined in the Work Letter). Tenant shall pay all TI Costs, except that Landlord shall pay for TI Costs that do not exceed the TI Allowance. The “TI Allowance” shall mean (a) One Hundred Twenty Five Dollars ($125.00) per rentable square foot of the Premises (the “Initial TI Allowance”), together with (b) the Additional Allowance. The “TI Costs” shall mean all Tenant Core and Shell Costs (as defined in the Work Letter) and all costs and expenses of performing the TI Work, including without limitation the hard and soft costs of (i) construction, (ii) the Construction Management Fee (as such term is defined in the Work Letter) and any Project or construction management fees paid by Tenant to an unaffiliated third party (such fees not to exceed three percent (3%) of the TI Allowance), (iii) space planning, design, architect, engineering, data and phone cabling and other related services, (iv) costs and expenses for labor, material, equipment, data and phone cabling and fixtures (including, without limitation, any of the Attached Property (as defined in Section 18.5), (v) building permits and other taxes, fees, charges and levies by governmental and quasi-governmental agencies for permits or for inspections of the Tenant Improvements, and (vi) the Warm Shell Costs. In no event shall the TI Allowance be used for: (w) the purchase of any furniture, personal property or other non-building system equipment, (x) costs resulting from a Tenant Delay, (y) costs resulting from any default by Tenant of its obligations under this Lease, or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). In the event the estimated total TI Costs (as set forth in the Budget) exceed the TI Allowance, Tenant shall deposit with Landlord such overage (the “TI Allowance Excess”), within five (5) business days of receiving the Budget (the “TI Deposit”). In the event Landlord determines the estimate of the TI Costs set forth in the Budget underestimates the amount of TI Costs so that the TI Deposit will not be sufficient to cover the TI Allowance Excess, then Landlord shall communicate the same to Tenant and, if required by Tenant, the parties shall discuss revisions to the Budget and Tenant may make a TI Tenant Change Order Request to reduce TI Costs, and unless the TI Costs are reduced to be within the Budget and previously paid TI Deposit, Tenant shall promptly pay the additional amount to Landlord, and such additional amount shall be added to the TI Deposit. If the sum of the TI Allowance plus the TI Deposit is not sufficient to cover the TI Costs, Tenant shall reimburse Landlord the difference between (a) the TI Costs and (b) the sum of the TI Allowance and the TI Deposit. However, Landlord shall be solely responsible for any costs related to the Tenant Improvements to the extent the same result from Landlord’s gross negligence, intentional misconduct or breach of Lease. Landlord and Tenant shall work together cooperatively at no cost or risk to Landlord to maximize Tenant’s ability, to the extent reasonably possible, to obtain the benefit of any applicable research and development tax credits with respect to the Tenant Improvements.
Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
Building Renovations It is specifically understood and agreed that Landlord has made no representation or warranty to Tenant and has no obligation and has made no promises to alter, remodel, improve, renovate, repair or decorate the Premises, Building, or any part thereof and that no representations respecting the condition of the Premises or the Building have been made by Landlord to Tenant except as specifically set forth herein or in the Work Letter Agreement. However, Tenant hereby acknowledges that Landlord is currently renovating or may during the Lease Term renovate, improve, alter, or modify (collectively, the "Renovations") the Project, the Building and/or the Premises including without limitation the parking structure, common areas, systems and equipment, roof, and structural portions of the same, which Renovations may include, without limitation, (i) installing sprinklers in the Building common areas and tenant spaces, (ii) modifying the common areas and tenant spaces to comply with applicable laws and regulations, including regulations relating to the physically disabled, seismic conditions, and building safety and security, and (iii) installing new floor covering, lighting, and wall coverings in the Building common areas, and in connection with any Renovations, Landlord may, among other things, erect scaffolding or other necessary structures in the Building, limit or eliminate access to portions of the Project, including portions of the common areas, or perform work in the Building, which work may create noise, dust or leave debris in the Building. Tenant hereby agrees that such Renovations and Landlord's actions in connection with such Renovations shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of Rent. Landlord shall have no responsibility or for any reason be liable to Tenant for any direct or indirect injury to or interference with Tenant's business arising from the Renovations, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the whole or any part of the Premises or of Tenant's personal property or improvements resulting from the Renovations or Landlord's actions in connection with such Renovations, or for any inconvenience or annoyance occasioned by such Renovations or Landlord's actions.
Tenant Improvement Plans Any work proposed by Tenant (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit C; provided that it will be reasonable for Landlord to withhold its approval or consent (as and when applicable under this Exhibit C) if Landlord’s Mortgagee has not consented to the matter that is the subject of such approval or consent. All architectural, engineering and other design fees shall be paid by Tenant. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Seattle and the State of Washington; Tenant’s architect shall be approved by Landlord (“Tenant’s Architect”), which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall also be entitled to receive a copy of the agreement between Tenant and Tenant’s Architect (the “Architect Agreement”). Tenant shall cause Tenant’s Architect to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld) in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan within ten (10) business days of receipt; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld, conditioned, or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion, the work, as described in any such item: (i) is likely to adversely affect Building Systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) might impair Landlord’s ability to furnish services to Tenant or other tenants in the Building; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances; (vi) would negatively affect the appearance of the Building; (vii) is reasonably likely to adversely affect another tenant’s premises; or (viii) is prohibited by any ground lease affecting the Building or any mortgage, trust deed or other instrument encumbering the Building. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, within ten (10) business days of Landlord’s receipt of the Working Drawings; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval. Landlord may, when approving the Tenant Improvement Plans, elect to require Tenant to remove any Non-Standard Improvements which are made to the Premises. If Landlord so elects, Tenant shall, at its own cost, restore the Premises to the condition designated by Landlord in its election, before the last day of the Term. Such process shall continue until both parties have approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.
Building Signage 1. Tenant shall be entitled to the greater of: (i) one (1) exclusive tenant identification sign per Building that does not to exceed 75 square feet, or (ii) Tenant’s pro rata share of the maximum exterior signage permitted by applicable Laws that is allocated to the parcel on which the Building is located (the “Building Signage”). The exact location of the Building Signage shall be determined by Tenant, subject to all applicable Laws, any reasonable signage guidelines for the Project established by Landlord that are provided to Tenant prior to installation of the Building Signage, and Landlord’s prior written approval, which approval shall not be unreasonably withheld, conditioned or delayed. Such right to the Building Signage is personal to Tenant and is subject to the following terms and conditions: (a) Tenant shall submit plans and drawings for the Building Signage to Landlord and to the City of San Mateo and to any other public authorities having jurisdiction and shall obtain written approval from Landlord (not to be unreasonably withheld, conditioned or delayed) and, if applicable, each such jurisdiction prior to installation, and shall comply with all applicable Laws; (b) Tenant shall, at Tenant’s sole cost and expense, design, construct and install the Building Signage; (c) the size, color and design of the Building Signage shall be subject to Landlord’s prior written approval; and (d) Tenant shall maintain the Building Signage in good condition and repair, and all costs of maintenance and repair shall be borne by Tenant. Maintenance shall include, without limitation, cleaning and, if the Building Signage is illuminated, relamping at reasonable intervals. Tenant shall be responsible for any electrical energy used in connection with the Building Signage. Notwithstanding the foregoing, Tenant shall not be liable for any fee in connection with Tenant’s right to display the Building Signage in accordance with this Lease. At Landlord’s option, Tenant’s right to the Building Signage may be revoked and terminated upon occurrence of any of the following events: (i) Tenant shall be in default under this Lease beyond any applicable notice and cure periods; (ii) Tenant leases or occupies less than 75% of the Premises, or (iii) this Lease shall terminate or otherwise no longer be in effect. 2. Upon the expiration or earlier termination of this Lease or at such other time that Tenant’s signage rights are terminated pursuant to the terms hereof, if Tenant fails to remove the Building Signage and repair the Building in accordance with the terms of this Lease, Landlord shall cause the Building Signage to be removed from the Building and the Building to be repaired and restored to the condition which existed prior to the installation of the Building Signage (including, if necessary, the replacement of any precast concrete panels), all at the sole cost and expense of Tenant and otherwise in accordance with this Lease, without further notice from Landlord notwithstanding anything to the contrary contained in this Lease. Tenant shall pay all costs and expenses for such removal and restoration within fifteen (15) business days following delivery of an invoice therefor accompanied by reasonable supporting documentation. The rights provided in this Section 36.A shall be non-transferable (except with respect to a Permitted Transferee) unless otherwise agreed by Landlord in writing in its sole discretion.
Premises Building Project and Common Areas 1.1 Premises, Building, Project and Common Areas.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).